Date for Completion definition

Date for Completion means the date for Completion specified in the Contract Specifics.
Sample 1Sample 2Sample 3
Date for Completion has the meaning given in the Sale Contract.
Sample 1Sample 2Sample 3
Date for Completion. The date set out in paragraph 6 of the Form of Agreement. Unless the Authority has not received a final report as set out in paragraph 4 of the Reports Schedule, in which case the Completion Date shall be the date on which the Authority receives such a report.
Sample 1Sample 2Sample 3

Examples of Date for Completion in a sentence

  • We agree that the Alliance Works must be executed to achieve Completion by the Date for Completion.

  • The Date for Completion (settlement) is 30 Working Days after the date First Grant Contracts are exchanged (being the date an Option is exercised), or as specified in the First Grant Contract.

  • The Supplier’s obligation to achieve Completion by the Date for Completion is paramount and this clause 23.12 is to be construed so as not to derogate from this obligation.

  • If the Contractor fails to comply with Clause21.5, the Contractor will have no entitlement to an extension of time of the Date for Completion.

  • If the Principal considers (acting reasonably) that the Contractor is not entitled to an extension of time, the Principal’s Representative must notify the Contractor within 10 Business Days (or any other period agreed in writing by the Parties) of receipt of the claim under Clause 21.5 that the Date for Completion remains unchanged.


More Definitions of Date for Completion

Date for Completion means the date for Completion specified in the Contract Details.
Sample 1Sample 2
Date for Completion means the date for the completion of the Services or any part of the Services specified in Item 4 of the Key Terms Schedule or if no such item is specified in the Key Terms Schedule, the equivalent item in the Purchase Order, or elsewhere in this Contract (including an Approved Services Program), or if none is specified, the date upon which the parties intend the Services or that part of the Services to be completed;
Sample 1Sample 2Sample 3
Date for Completion means the date set out in the Agreement or otherwise specified by Nokia for the Completion.
Sample 1Sample 2Sample 3
Date for Completion means the date specified in item 5 of Appendix A as extended by such period agreed or determined in accordance with clauses 23.6 and 25;
Sample 1Sample 2Sample 3
Date for Completion means in respect of the Works or a Portion the date, or the last day of the period of time, specified in Schedule 1 for the Works or that Portion, as adjusted under this Contract by an extension of time determined by the Principal's Representative or pursuant to any determination by an expert or any arbitration pursuant to clause 15.
Sample 1Sample 2Sample 3
Date for Completion means the date by which the Services shall be completed as set out in the Contract Agreement;
Sample 1Sample 2Sample 3
Date for Completion means the date fixed and stated in Appendix I, or any other
Sample 1Sample 2