Disputes with Subcontractors Sample Clauses
The "Disputes with Subcontractors" clause establishes the procedures and responsibilities for handling disagreements that arise between the main contractor and any subcontractors involved in a project. Typically, this clause outlines steps such as notification requirements, escalation processes, and possible involvement of mediation or arbitration to resolve issues efficiently. By clearly defining how disputes are to be managed, the clause helps prevent project delays and ensures that conflicts are addressed in a structured manner, thereby minimizing disruption and protecting the interests of all parties involved.
POPULAR SAMPLE Copied 1 times
Disputes with Subcontractors. Wherever any provision of any section of the Plans and Specifications conflicts with any agreement or regulation of any kind at any time in force among members of any Trade Associations, Unions or Councils which regulate or distinguish what Work shall or shall not be included in the Work of any particular trade, the Contractor shall make all necessary arrangements to reconcile any such conflict without delay, damage, increase to the Contract Sum or recourse to the University. The University will not arbitrate disputes among subcontractors nor between the Contractor and one or more subcontractors concerning responsibility for performing any part of the Project. In case the progress of the Work is affected by any undue delay in furnishing or installing any items of material or equipment required under the Contract Documents because of conflict involving any agreement or regulation of the type described above, the University’s Representative may require that other material or equipment of equal kind and quality be provided at no additional cost to the University.
Disputes with Subcontractors. Applications for Payment may not include requests for payment of amounts the Contractor does not intend to pay to a Subcontractor because of a dispute or other reason.
Disputes with Subcontractors. Contractor shall inform ComEd of any material dispute arising between Contractor and any of its Subcontractors or between any Subcontractor and another Subcontractor that may cause a delay in the performance of Services. Contractor shall use its best efforts to avoid disputes regarding the Work and shall resolve such disputes as they arise. Contractor shall comply with Article 19 regarding any Subcontractor labor disputes.
Disputes with Subcontractors. If a Managing Contractor has a dispute with a subcontractor in respect of any aspect of the Services and either the Managing Contractor or the subcontractor pursues any court action, arbitration or adjudication application under the SOP Act, then:
(a) the Managing Contractor will be responsible for carriage of the dispute, provided it must:
(i) keep the Principal's Representative fully informed of all aspects of the dispute; and
(ii) act in accordance with the reasonable instructions of the Principal's Representative (including in respect of lodging any appeals against any decisions made in respect of the dispute);
(b) subject to the Principal's Representative prior written approval (which may be given or withheld at the Principal’s Representative's absolute discretion), any external legal, expert or consultants costs incurred by the Managing Contractor arising out of the defence of any court action, arbitration or adjudication will form part of the Actual Reimbursable Costs; and
(c) the Managing Contractor's own internal costs of administering the court action, arbitration or adjudication application will not form part of the Actual Reimbursable Costs.