Virtual Completion means the premise is in the opinion of the Employer fit for occupation.
Substantially Complete means that all work described in the specifications or shown on the drawings is done, with only minor items needed to fully complete the work. Typical work that should be done in order to be considered substantially complete include: all equipment installed, piped, electrically connected, and tested with any problems corrected; control systems completed, calibrated and functioning as intended, insulation installed. Equipment should be fully functional and ready for use.
Test Complete has the meaning stated in Section 3.4(c).
Outside Completion Date shall have the meaning assigned to such term in Section 6.3(d).
Target Completion Date has the meaning given such term in Section 3.3(b).
Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:
Mechanical Completion means that (a) all components and systems of the Project have been properly constructed, installed and functionally tested according to EPC Contract requirements in a safe and prudent manner that does not void any equipment or system warranties or violate any permits, approvals or Laws; (b) the Project is ready for testing and commissioning, as applicable; (c) Seller has provided written acceptance to the EPC Contractor of mechanical completion as that term is specifically defined in the EPC Contract.
Project Completion Date means the date on which the Provisional Certificate is issued and in the event no Provisional Certificate is issued, the date on which the Completion Certificate is issued;
Project Completion means the date, as determined by the Division after consultation with the Recipient, that operation of the Project is initiated or is capable of being initiated, whichever comes first.
Substantial Completion Date means the required date for Substantial Completion of the Project. The Substantial Completion Date can be adjusted only by written Change Order.
Administratively complete means an application contains all components required by statute or this Chapter to be submitted to the OPM to enable the OPM to determine whether to grant a license or approval.
Substantially Completed means: (i) the Company and the Contractor have issued a certificate of substantial completion in form and substance satisfactory to Buyer certifying that the Hotel has been constructed substantially in accordance with the Plans and Specifications and the Legal Requirements, (ii) a certificate of occupancy authorizing the opening of the Hotel for business to the public and for operation under the Brand has been issued by the local governing authority and is in full force and effect, (iii) all other final and unconditional consents, approvals, licenses and operating permits necessary or appropriate for the Hotel to open for business to the public and to operate under the Brand have been issued by and obtained from all applicable governmental and regulatory authorities, subject to Punch List Items; (iv) the Hotel is fully furnished, fitted and equipped and ready to open for business to the public and operate under the Brand, subject to Punch List Items; (iii) all contractors, subcontractors, suppliers, mechanics, materialmen and other persons or entities providing labor or materials for the construction and development of the Hotel shall have been paid (or adequate provision for payment of such persons or entities, which is not required to be an actual escrow of funds, has been made to Buyer’s reasonable satisfaction), subject to Punch List Items and (iv) the Franchisor has approved the completion, furnishing and equipping of the Hotel and is prepared to commence (or authorize the commencement of) operation of the Hotel, and all of the other conditions set forth in the Management Agreement and the Franchise Agreement have been satisfied, subject to Punch List Items.
The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.
project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;
Time for Completion means the time for completing the Works as stated in the Contract Data (or as extended under Sub-Clause 7.3), calculated from the Commencement Date.
Scheduled Completion Date has the meaning ascribed in Article 9 of this Contract.
Phase 1 means the time period beginning upon the date this Change Order is executed and ending on the date a Facility is turned over to Owner.
Study Completion means the database for the Study has been locked and all Essential Documents have been provided to the Sponsor, including a copy of the letter from the Reviewing HREC acknowledging receipt of the final report and/or closure letter from the Principal Investigator.
Project Completion Schedule means the progressive Project Milestones for completion of the Work on or before the Scheduled Completion Date;
Landlord’s Work means the work of constructing the Tenant Improvements.
Project Description means the document that describes the Project's Reduction activities and that uses either the VCS Project Description Template or the project description template specified by the relevant Approved GHG Program;
Substantial compliance means a level of compliance with the requirements of participation such that any identified deficiencies pose no greater risk to resident health or safety than the potential for causing minimal harm.
Tenant Delays means any delay in the completion of the Tenant Improvements resulting from any or all of the following: (a) Tenant's failure to timely perform any of its obligations pursuant to this Work Letter Agreement, including any failure to complete, on or before the due date therefor, any action item which is Tenant's responsibility pursuant to the Work Schedule delivered by Landlord to Tenant pursuant to this Work Letter Agreement; (b) Tenant's changes to Space Plans or Final Plans after Landlord's approval thereof; (c) Tenant's request for materials, finishes, or installations which are not readily available or which are incompatible with the Standards; (d) any delay of Tenant in making payment to Landlord for Tenant's share of the Work Cost; or (e) any other act or failure to act by Tenant, Tenant's employees, agents, architects, independent contractors, consultants and/or any other person performing or required to perform services on behalf of Tenant.
Date for Completion means the date for Completion specified in the Contract Specifics.
Ready for Occupancy means the date upon which (i) the Leased Premises are available for Tenant's occupancy in a broom clean condition and (ii) the improvements, if any, to be made to the Leased Premises by Landlord as a condition to Tenant's obligation to accept possession of the Leased Premises have been substantially completed and the appropriate governmental building department (i.e., the City building department, if the Property is located within a City, or otherwise the County building department) shall have approved the construction of such improvements as substantially complete or is willing to so approve the construction of the improvements as substantially complete subject only to compliance with specified conditions which are the responsibility of Tenant to satisfy or is willing to allow Tenant to occupy subject to its receiving assurances that specified work will be completed.
Commissioning test means tests applied to the Generating Facility, after completion of the construction of the Generating Facility, in order to verify that the Generating Facility may be released for Operation.