Owner May Correct Defective Work. In the event the Architect determines that the Contractor’s work is defective, the Architect shall give the Contractor notice to correct the defective work. Contractor shall within seven (7) days after written notice from Architect correct defective Work or remove and replace rejected Work as required by Architect. If the Contractor fails to correct the defective work in accordance with this paragraph, or if Contractor fails to perform the Work in accordance with the Contract Documents within such time, or if Contractor fails to comply with any other provision of the Contract Documents, Owner may, upon seven (7) days written notice to Contractor, correct and remedy any such deficiency. In exercising the rights and remedies under this paragraph, Owner shall proceed expeditiously. In connection with such corrective and remedial action, Owner may exclude Contractor from all or part of the Site, take possession of all or part of the Work and suspend Contractor's services related thereto, and incorporate in the Work all materials and equipment stored at the Site or for which Owner has paid Contractor but which are stored elsewhere. Contractor shall allow Owner, Owner's representatives, agents and employees, Owner's other contractors, and Architect and Architect's Consultants access to the Site to enable Owner to exercise the rights and remedies under this paragraph. All Claims, costs, losses, and damages (including but not limited to all fees and charges of Architect, Architect’s Consultant, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) incurred or sustained by Owner in exercising the rights and remedies under this paragraph will be charged against Contractor, and a Change Order will be issued incorporating the necessary revisions in the Contract Documents with respect to the Work; and Owner shall be entitled to an appropriate decrease in the Contract Price. Such claims, costs, losses and damages will include but not be limited to all costs of repair, or replacement of work of others destroyed or damaged by correction, removal, or replacement of Contractor's defective Work. Contractor shall not be allowed an extension of the Contract Times (or Milestones) because of any delay in the performance of the Work attributable to the exercise by Owner of Owner's rights and remedies under this paragraph.
Owner May Correct Defective Work. In the event the Architect determines that the Contractor’s work is defective, the Architect shall give the Contractor notice to correct the defective work. Contractor shall within seven
Owner May Correct Defective Work. A. If Contractor fails within a reasonable time after written notice from Engineer to correct defective Work, or to remove and replace rejected Work as required by Engineer, or if Contractor fails to perform the Work in accordance with the Contract Documents, or if Contractor fails to comply with any other provision of the Contract Documents, then Owner may, after seven days written notice to Contractor, correct or remedy any such deficiency.
Owner May Correct Defective Work. A. If CONTRACTOR fails within a reasonable time after written notice from Owner’s Representative or ARCHITECT to correct defective Work or to remove and replace rejected Work as required by ARCHITECT or Owner’s Representative in accordance with paragraph 13.06.A, or if CONTRACTOR fails to perform the Work in accordance with the Contract Documents, or if CONTRACTOR fails to comply with any other provision of the Contract Documents, OWNER may, after seven days written notice to CONTRACTOR, correct and remedy any such deficiency.
Owner May Correct Defective Work. 11.12 If Contractor fails, within three days after written notice from Owner, to proceed to correct, or to remove and replace Defective Work as required by Owner, or if Contractor fails to perform the Work in accordance with this Contract (including any requirements of the work progress schedule), Owner may correct and remedy any such deficiency. In exercising the rights under this paragraph, Owner will proceed expeditiously. To the extent necessary to complete corrective and remedial action, Owner may: (1) exclude Contractor from all or part of the site; (2) take possession of all or part of the site; (3) suspend Contractor’s services related thereto; (4) take possession of Contractor’s tools, appliances, construction equipment and machinery at the site; and (5) incorporate in the Work material stored at the site or for which Owner has paid Contractor but which has been stored elsewhere. Contractor shall allow Owner’s representatives, contractors, agents, and employees such access to the site as may be necessary to exercise the rights under this paragraph. All direct and indirect costs in exercising such rights will be charged against Contractor. A Change Order will be executed incorporating the necessary revisions to this Contract and a reduction in the Guaranteed Maximum Price. Such direct and indirect costs will include, in particular but without limitation: (1) additional professional services required; and
Owner May Correct Defective Work. If Contractor fails, after written notice by Owner, within a reasonable time to proceed to correct or remove Defective Work, Owner may, after ten (10) days' written notice to Contractor, correct and remove any such Defective Work itself or engage another party to do so, without regard to whether the cost of correction by or on behalf of Owner is greater or less than the cost for Contractor to correct or replace the Defective Work. Contractor shall allow Owner, Owner's Representatives, agents, and employees such access to the Property as may be necessary to enable Owner to exercise its rights under this Section. All reasonable direct costs to Owner in exercising such rights shall be paid and reimbursed by Contractor and Owner shall have the right to set off any such amounts against amounts that Owner might otherwise be or become obligated to pay to Contractor.
Owner May Correct Defective Work. A. If DB Entity fails within a reasonable time after written notice from Owner to correct defective Work or to remove and replace rejected Work as required by Owner in accordance with Paragraphs
Owner May Correct Defective Work. A. Owner may remedy deficiencies in the Work after 7 days’ notice to Contractor if:
