Declaration of Completion definition

Declaration of Completion means a declaration in the form substantially prescribed in Schedule E (Declaration of Completion).
Sample 1Sample 2Sample 3
Declaration of Completion means a document with its own unique identifier issued to a student who has successfully completed a mandatory entry-level training course in accordance with section 27.06(4.1) of the MVAR, B.C. Reg. 26/58, means ICBC form number MV2970.
Sample 1Sample 2
Declaration of Completion means a declaration of Project Completion executed by an authorized senior official of the Recipient for Projects in the Fiscal Year in which a Project is completed, in the form set out in Annex “E” of this Agreement;
Sample 1Sample 2

Examples of Declaration of Completion in a sentence

  • Allow a Driver Training School approved to deliver the Approved Course to conduct required MELT Course Assessments as determined by ICBC, toward issuance of a Declaration of Completion to each student who successfully completes the Approved Course.

  • A driver training school must be approved to deliver the Class 1 MELT course, and will be required to issue an MV2970 - Class 1 MELT Declaration of Completion (DoC) to each student who has met the assessment requirements and successfully completed the course.

  • A Declaration of Completion may only be issued to a student who starts and completes the Approved Course during the term of this Agreement, or to a student who started the Approved Course during the term of a previous agreement between ICBC and the Driver Training School authorizing the Driver Training School to offer the Approved Course, and who completes the Approved Course during the term of this Agreement.

  • Issue a Declaration of Completion to an individual who has successfully completed the Approved Course as set out in this Agreement, in accordance with the provisions of this Agreement, and in keeping with requirements in Division 27 of the MVAR, B.C. Reg.

  • The Owner shall retain the services of the engineer(s) until the installation, extension and improvement of services is complete and a Declaration of Completion has been submitted and prior to the Owner giving notice of the completion of the building pursuant to the Building Code Act, as may be amended from time to time.

  • It may also include a Declaration of Substantial Completion and a Declaration of Completion.

  • A Project or Step will be considered complete on the date specified in the Statutory Declaration of Completion executed by the Project Proponents in the form described under Schedule B, submitted to and received by the Administrator.

  • A Project or Step will be considered complete on the date specified in the Statutory Declaration of Completion executed by the Project Proponent in the form described under Schedule B, submitted to and received by the Administrator.

  • In the event that the Owner fails to comply with any terms and conditions of the Approvals, or fails to make modifications or changes required by the Approvals, the Municipality shall have the right to enter onto said land to conduct all works necessary to comply with the terms and conditions of the Approvals, or to effect modifications and changes up to and including the date of the submission of the Declaration of Completion as certified by the consulting engineer.

  • Forthwith after development of the Land, and prior to giving a Declaration of Completion, the Owner shall, at its expense, reinstate all boulevard areas to the satisfaction of the Municipality’s Director of Public works.


More Definitions of Declaration of Completion

Declaration of Completion means a declaration in the form as described in Section 7.6 of this Agreement.
Sample 1
Declaration of Completion means a declaration in the form substantially prescribed in Schedule D (Declaration of Completion).
Sample 1

Related to Declaration of Completion

  • Certificate of Completion means the certificate of completion given by the Engineer-in-charge pursuant to clause 40 of these conditions;

  • Time of Completion means the time for completing the execution of and passing the Tests on Completion of the Works of any section or part thereof as stated in the Contract (or as extended under Clause...) calculated from the Commencement Date

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Date of Completion with respect to a Project shall mean: (i) the date upon which such Project and all components thereof have been acquired or constructed and are capable of performing the functions for which they were intended, as evidenced by an Engineers’ Certificate filed with the Trustee and the Issuer; or (ii) the date on which the Issuer determines, upon the recommendation of or in consultation with the Consulting Engineer, that it cannot complete such Project in a sound and economical manner within a reasonable period of time as evidenced by an Engineers’ Certificate filed with the Trustee and the Issuer; provided that in each case such certificate of the Consulting Engineer shall set forth the amount of all Costs of such Project which have theretofore been incurred, but which on the Date of Completion is or will be unpaid or unreimbursed.

  • Notice of Completion means a document issued by the Department or Delegated Agency at the end of project construction when all items and conditions of the approved Sediment and Stormwater Management Plan have been satisfied, post construction verification documents demonstrate that the stormwater management systems have been constructed in accordance with the approved Sediment and Stormwater Management Plan, and final stabilization of disturbed areas on the site has been achieved.

  • The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.

  • Project Completion means completion of the Redevelopment in accordance with this Agreement to the state where the whole of the Morley Shopping Centre, as so redeveloped, is capable of occupation for its intended purpose;

  • Improvement completion assurance means a surety bond, letter of credit,

  • Practical Completion means that stage in the execution of a Named Project when the Works have been completed in accordance with the terms of the relevant Building Contract and/or the terms of this Agreement such that the AHP Dwellings comprised within the Named Project are fit for beneficial occupation as a residential development in accordance with applicable NHBC or equivalent requirements current at the date of inspection subject only to the existence of minor defects and/or minor omissions at the time of inspection which are capable of being made good or carried out without materially interfering with the beneficial use and enjoyment of the Named Project and which would be reasonable to include in a snagging list, and Practically Complete shall be construed accordingly; Process has the meaning ascribed to it in the DPA; Procurement Law means (as the case may be):

  • Substantial Completion Date means the date on which Substantial Completion occurs.

  • Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.

  • Time for Completion means the time for completing the Works as stated in the Contract Data (or as extended under Sub-Clause 7.3), calculated from the Commencement Date.

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Tests on Completion means the tests which are specified in the Contract or agreed by both Parties or instructed as a Variation, and which are carried out under Clause 9 [Tests on Completion] before the Works or a Section (as the case may be) are taken over by the Procuring Entity.

  • Virtual Completion means the premise is in the opinion of the Employer fit for occupation.

  • Phase 1 means the phase of the ATP comprised of: (1) improvements to the State Street Substation; (2) construction of the Proposed Line; (3) the rebuilding of NYSEG’s existing Lines 971 and 000 xxxxx xx Xxxxxxxx Xxxx xx the NYSEG ROW to allow for construction of the Proposed Line as intended; (4) improvements to the Elbridge Substation to accept the Proposed Line; and (5) National Grid’s conveyance to NYSEG of the NYSEG Acquired ROW and such other land interests as contemplated by the Purchase and Sale Agreement.

  • Date for Completion means the date for Completion specified in the Contract Specifics.

  • Milestone Schedule means Seller’s milestone schedule, the form of which is attached to this Agreement as Exhibit Q.

  • Certificate of Compliance means a certificate issued in terms of the Regulations in respect of an electrical installation or part of an electrical installation by an accredited person;

  • Certificate of approval means a certificate of approval obtained from the