SEPARATE CONTRACTUAL RIGHTS Sample Clauses

SEPARATE CONTRACTUAL RIGHTS. Save as otherwise provided herein, nothing in this Agreement shall limit or restrict the rights of IBRD or Sinosure pursuant to any other agreement.
Sample 1Sample 2
AutoNDA by SimpleDocs
SEPARATE CONTRACTUAL RIGHTS. Save as may be expressly provided herein, nothing in this Agreement shall limit or restrict the rights of the PEA pursuant to any other agreement.
Sample 1
SEPARATE CONTRACTUAL RIGHTS. Nothing in this Agreement shall limit or restrict the rights of XXX or UMEME pursuant any other agreement. Governing Law and Dispute Resolution This Agreement shall be governed by and construed in accordance with the laws of England. The parties agree that any dispute arising out of or in connection with this Agreement which cannot be amicably settled within thirty (30) calendar days after one party gives the other party written notice of the dispute, shall be settled by arbitration as follows: The dispute shall be finally settled by arbitration before a tribunal (the “Arbitration Tribunal”) conducted in accordance with the rules of the United Nations Commission on International Trade Law (UNCITRAL) as in effect on the date of this Agreement (the “Rules”). The arbitration proceedings shall be conducted, and the award shall be rendered, in the English language. In the event of a difference between the Rules and the terms of this Agreement, the terms of this Agreement shall govern. Unless the parties otherwise agree, the number of arbitrators shall be three. Each party shall select one arbitrator within thirty (30) calendar days of a request by a party for arbitration pursuant to this Section 15(b). The two arbitrators thus appointed shall, within thirty (30) calendar days of the selection of the second arbitrator, select a third arbitrator to serve as the chairperson of the Arbitration Tribunal for resolution of the dispute. If the two arbitrators so appointed fail to timely select a third arbitrator to serve as a chairperson, such arbitrator shall be appointed by the London Court of International Arbitration in accordance with the Rules. Any arbitral award under this Section 15(b) shall be final and binding upon the parties and shall be the sole and exclusive remedy between the parties regarding all disputes, and each party undertakes to comply with and to carry out any such arbitral award, fully and without delay. This Agreement and the rights and obligations of the parties hereunder shall remain in full force and effect pending the award in any arbitration proceeding instituted hereunder. Until such time as any arbitral proceedings begun pursuant to this Section 15(b) have been finally concluded, each party irrevocably agrees not to initiate any proceedings, file any action or suit in any court of competent jurisdiction or before any judicial or other authority arising under, out of, in connection with or relating to this Agreement, the arbitration agree...
Sample 1

Related to SEPARATE CONTRACTUAL RIGHTS

  • Separate Contracts The Owner reserves the right at any time and from time to time upon notice to Contractor to perform, or cause to be performed by other Contractors, other work at the Site in connection with the development of the Project that is not contemplated hereby or that is contemplated hereby if the Contractor and the Owner shall be unable to agree upon a Change Order incorporating such work as Work of the Contractor under this Contract. In either case, the Owner shall assure that such personnel or Contractors do not cause any conflict with the Work of Contractor. Contractor shall afford the Owner and other Contractors reasonable opportunity for the introduction, protection, and storage of material and equipment at the Site and the execution of work, and shall properly connect, if required by Contract Documents, and coordinate its work with theirs. If any work by the Owner or its other Contractors increases Contractor's costs or extends the time of performance, Contractor shall be entitled upon timely claim to a Change Order for payment by Owner of any reasonable costs actually incurred by Contractor as a result thereof and to an extension of time for performance for such reasonable time as the Design Professional shall determine. Contractor has no responsibility hereunder to certify the suitability or correctness of any work performed by Owner's own personnel or other Contractors under direct contract with the Owner. This Article also applies to installation of loose equipment and fixtures by the Owner, Using Agency, or a Separate Contractor.

  • WAIVER OF CONTRACTUAL RIGHT The failure of either party to enforce any provision of this Agreement shall not be construed as a waiver or limitation of that party's right to subsequently enforce and compel strict compliance with every provision of this Agreement.

  • SUBCONTRACTUAL RELATIONS 5.3.1 By written agreement, the Contractor shall require each Subcontractor, to the extent of the Work to be performed by the Subcontractor, to be bound to the Contractor by the terms of the Contract Documents, and to assume toward the Contractor all the obligations and responsibilities which the Contractor, by these Documents, assumes toward the State and the Architect. Said agreement shall preserve and protect the rights of the State and the Architect under the Contract Documents with respect to the Work to be performed by the Subcontractor so that the subcontracting thereof will not prejudice such rights, and shall allow to the Subcontractor, unless specifically provided otherwise in the Contractor Subcontractor agreement, the benefit of all rights, remedies and redress against the Contractor that the Contractor, by these Documents, has against the State. The Contractor shall require each Subcontractor to enter into similar agreements with his Sub-subcontractors. The Contractor shall make available to each proposed Subcontractor, prior to the execution of the Subcontract, copies of the Contract Documents to which the Subcontractor will be bound by this Paragraph 5.3, and identify to the Subcontractor any terms and conditions of the proposed Subcontract which may be at variance with the Contract Documents. Each Subcontractor shall similarly make copies of such Documents available to his / her Sub-subcontractors.

  • Contractual Relations Nothing contained in this Contract shall create any contractual relations between County and a subcontractor.

  • Contractual Relationship It is understood and agreed that the relationship described in this Agreement between the Parties is contractual in nature and is not to be construed to create a partnership or joint venture or agency relationship between the parties. Neither party shall have the right to act on behalf of the other except as expressly set forth in this Agreement. Contractor will be solely responsible for and will pay all taxes related to the receipt of payments hereunder and shall give reasonable proof and supporting documents, if reasonably requested, to verify the payment of such taxes. No Contractor personnel shall obtain the status of or otherwise be considered an employee of NCTCOG or Participating Entity by virtue of their activities under this Agreement.

  • CONTRACTUAL AGREEMENT This Invitation for Bids shall be included and incorporated in the final contract or purchase order. The order of contract precedence will be the contract (purchase order), bid document, and response. Any and all legal actions associated with this Invitation for Bids and/or the resultant contract (purchase order) shall be governed by the laws of the State of Florida. Venue for any litigation involving this contract shall be the Ninth Circuit Court in and for Orange County, Florida.

  • CONTRACTUAL RECOGNITION OF BAIL-IN Notwithstanding any other term of any Finance Document or any other agreement, arrangement or understanding between the Parties, each Party acknowledges and accepts that any liability of any Party to any other Party under or in connection with the Finance Documents may be subject to Bail-In Action by the relevant Resolution Authority and acknowledges and accepts to be bound by the effect of:

  • Contractual Provisions The Provisions found in Contractual Provisions Attachment (Form DA-146a, Rev. 06-12), which is attached hereto, are hereby incorporated in this contract and made a part hereof.

  • Separate Contractor Any person or entity other than Contractor that enters into an agreement with Owner to perform the construction of all or any portion of the construction on a Project.

  • CONTRACTUAL TERMS [Terms used herein shall be deemed to be defined as such for the purposes of the Terms and Conditions (the “Conditions”) set forth in the Prospectus dated [ ] [and the supplement[s] to it dated [ ]] which [together] constitute[s] a base prospectus for the purposes of the Prospectus 1 This date reference should not be included in Final Terms for offers concluded on or after 1 January 2018. Directive. This document constitutes the Final Terms of the Notes described herein for the purposes of Article 5.4 of the Prospectus Directive and must be read in conjunction with the Prospectus[, as supplemented]. Full information on the Issuer and the offer of the Notes is only available on the basis of the combination of these Final Terms and the Prospectus[, as supplemented]. The Prospectus [and the supplements] to it] [has / have] been published on the website xxxx://xxx.xxxxxxxxx.xx.xx/uk/about-santander-uk/investor-relations.] [Terms used herein shall be deemed to be defined as such for the purposes of the Terms and Conditions (the "Conditions") set forth in the Prospectus/[Information Memorandum] dated [ ] [and the supplement[s] to it dated [ ]] which are incorporated by reference in the Prospectus dated [ ]. This document constitutes the Final Terms of the Notes described herein for the purposes of Article 5.4 of the Prospectus Directive and must be read in conjunction with the Prospectus dated [ ] [and the supplement[s] to it dated [ ]] which [together] constitute[s] a base prospectus for the purposes of the Prospectus Directive. Full information on the Issuer and the offer of the Notes is only available on the basis of the combination of these Final Terms and the Prospectus dated [ ] [and the supplement[s] to it dated [ ]]. Copies of such Information Memoranda and Prospectus [and the supplements] to [it] [them] have been published on the website xxxx://xxx.xxxxxxxxx.xx.xx/uk/about-santander-uk/investor-relations.]

Time is Money Join Law Insider Premium to draft better contracts faster.