Redeveloper Grant of Security for Excess Awards in Eminent Domain Proceedings Sample Clauses

Redeveloper Grant of Security for Excess Awards in Eminent Domain Proceedings. At the time that the City conveys to Redeveloper a parcel of Acquisition Property which has been acquired by it via the exercise of the power of eminent domain (such a parcel being called, for purposes of this Section, a “Condemned Parcel”), the eminent domain proceeding in which such Condemned Parcel was acquired still may be pending and the value of such Condemned Parcel established by the Agency in such proceeding (the “Agency’s Parcel Value”), which Agency’s Parcel Value will be equal in amount to the sum of money deposited by the Agency with the Clerk of the Court together with the Statement of Compensation relating to such Condemned Parcel (the “Deposited Funds”), still may be subject to appeal or, if approved by Redeveloper, to action by the Ombudsman for Property Rights pursuant to § 8-132 of the Statutes, and an award in excess of the amount of the Agency’s Parcel Value and the Deposited Funds (an “Excess Award”) may be made in such proceeding, or the Agency (with the approval of the Redeveloper) may agree to pay an amount in excess of such Deposited Funds (a “Settlement Amount”) to settle such proceeding (it being agreed that the Agency and City may not make any settlement of any eminent domain proceeding or appeal without the prior written consent of Redeveloper), which, in either case, may require the Agency to pay to the owner of such Condemned Parcel (the “Parcel Owner”) additional sums in excess of the Deposited Funds. Any such Excess Award or Settlement Amount shall constitute Acquisition Expenses under this Agreement and the Redeveloper will be required to pay the amount thereof to the Agency, in accordance with this Agreement, to enable the Agency to pay such Excess Award or Settlement Amount to the Clerk of the Court or the Parcel Owner. The amount of the Deposited Funds with respect to any Condemned Parcel shall not be the limit of Redeveloper’s obligation and liability with respect to Acquisition Expenses incurred by the City and/or the Agency with respect to such Condemned Parcel, and the Redeveloper hereby agrees to indemnify, defend and hold harmless the City and the Agency against and from any and all claims, suits, costs, expenses, losses, liabilities, and damages, including reasonable attorneys’ fees, asserted against and/or incurred by either of them arising out of an Excess Award or Settlement Amount. This indemnity shall survive termination of this Agreement and shall be separate and independent of any other provision of this ...
AutoNDA by SimpleDocs

Related to Redeveloper Grant of Security for Excess Awards in Eminent Domain Proceedings

  • File Management and Record Retention relating to CRF Eligible Persons or Households Grantee must maintain a separate file for every applicant, Eligible Person, or Household, regardless of whether the request was approved or denied.

  • RIGHT OF ALLOTTEE TO USE COMMON AREAS AND FACILITIES SUBJECT TO PAYMENT OF TOTAL MAINTENANCE CHARGES The Allottee hereby agrees to purchase the [Apartment/Plot] on the specific understanding that is/her right to the use of Common Areas shall be subject to timely payment of total maintenance charges, as determined and thereafter billed by the maintenance agency appointed or the association of allottees (or the maintenance agency appointed by it) and performance by the Allottee of all his/her obligations in respect of the terms and conditions specified by the maintenance agency or the association of allottees from time to time.

  • Certification of Meeting or Exceeding Tobacco-Free Workplace Policy Minimum Standards A. Grantee certifies that it has adopted and enforces a Tobacco-Free Workplace Policy that meets or exceeds all of the following minimum standards of:

  • Compliance with Contractor Employee Jury Service Ordinance Contractor shall comply with the County Ordinance with respect to provision of jury duty pay to employees and have and adhere to a written policy that provides that its employees shall receive from the Contractor, on an annual basis, no less than five days of regular pay for actual jury service in San Mateo County. The policy may provide that employees deposit any fees received for such jury service with the Contractor or that the Contractor deduct from the employees’ regular pay the fees received for jury service.

  • Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree Alternative Dispute Resolution Limitations This is a requirement of the TIPS Contract and is non-negotiable. TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees No Waiver of TIPS Immunity This is a requirement of the TIPS Contract and is non-negotiable. Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. 5 Does Vendor agree? Yes, Vendor agrees Payment Terms and Funding Out Clause This is a requirement of the TIPS Contract and is non-negotiable. Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body. 2

  • Legal Action; Utilization of Special Receivership Powers The Assuming Institution shall notify the Receiver in writing (such notice to be given in accordance with Article V below and to include all relevant details) prior to utilizing in any legal action any special legal power or right which the Assuming Institution derives as a result of having acquired an asset from the Receiver, and the Assuming Institution shall not utilize any such power unless the Receiver shall have consented in writing to the proposed usage. The Receiver shall have the right to direct such proposed usage by the Assuming Institution and the Assuming Institution shall comply in all respects with such direction. Upon request of the Receiver, the Assuming Institution will advise the Receiver as to the status of any such legal action. The Assuming Institution shall immediately notify the Receiver of any judgment in litigation involving any of the aforesaid special powers or rights.

  • OWNER’S RIGHT TO PERFORM CONSTRUCTION AND TO AWARD SEPARATE CONTRACTS § 7.4.1 The Owner reserves the right to perform construction or operations related to the Project with the Owner’s own forces, and to award separate contracts in connection with other portions of the Project.

  • Files Management and Record Retention relating to Grantee and Administration of this Agreement a. The Grantee shall maintain books, records, and documents in accordance with generally accepted accounting procedures and practices which sufficiently and properly reflect all expenditures of funds provided by Florida Housing under this Agreement.

  • Obligations of Registry Operator to TLD Community Registry Operator shall establish registration policies in conformity with the application submitted with respect to the TLD for: (i) naming conventions within the TLD, (ii) requirements for registration by members of the TLD community, and (iii) use of registered domain names in conformity with the stated purpose of the community-­‐based TLD. Registry Operator shall operate the TLD in a manner that allows the TLD community to discuss and participate in the development and modification of policies and practices for the TLD. Registry Operator shall establish procedures for the enforcement of registration policies for the TLD, and resolution of disputes concerning compliance with TLD registration policies, and shall enforce such registration policies. Registry Operator agrees to implement and be bound by the Registry Restrictions Dispute Resolution Procedure as set forth at xxxx://xxx.xxxxx.xxx/en/resources/registries/rrdrp with respect to disputes arising pursuant to this Section 2.19. Registry Operator shall implement and comply with the community registration policies set forth on Specification 12 attached hereto.

  • How to Add or Remove Coverage for Family Members If your plan offers family coverage, you must notify your employer if you want to add or remove family members according to the Special Enrollment provisions described above. When adding or removing a family member, inform your employer in advance of the requested effective date and your employer will notify us. All requests must be made through your employer. We cannot directly add or remove coverage for you or your family members.

Time is Money Join Law Insider Premium to draft better contracts faster.