Reasonable Efforts, Notice of Completion, Extension Sample Clauses

Reasonable Efforts, Notice of Completion, Extension. Seller shall satisfy each Condition Precedent set forth in Section 4.1 on or before the Completion Date (defined below). Within five (5) Business Days of satisfaction (or waiver in writing by Buyer) of each Condition Precedent set forth in Section 4.1, Seller shall deliver to Buyer a written acknowledgment that such Condition Precedent is satisfied, the date of such satisfaction, and accompanying documentation to reasonably demonstrate the satisfaction of such Condition Precedent. Upon satisfaction of all Conditions Precedent set forth in Section 4.1, Seller shall provide a written acknowledgement to Buyer (“Notice of Completion”) stating and affirming that (i) the Facility is constructed in accordance with the terms and conditions of this Agreement and is ready to deliver Test Energy and Net Energy as provided in this Agreement; (ii) all Interconnection Facilities have been constructed in accordance with the terms and conditions of this Agreement and the Interconnection Agreement and are available to receive Test Energy and Net Energy from the Facility; and (iii) all Conditions Precedent set forth in Section 4.1 have been satisfied. Seller shall satisfy all Conditions Precedent and provide a Notice of Completion to Buyer (the “Completion Date”) by no later than the date that is twelve (12) months following the Effective Date (“Completion Deadline”); provided, however, that if this Agreement was executed pursuant to the ELECTRONICALLY FILED - 2019 September 20 5:06 PM - SCPSC - Docket # 2019-184-E - Page 19 of 66 submittal of a Notice of Commitment to Sell Form by Seller to Buyer, the Completion Deadline shall be the date that is three hundred sixty five (365) days after the Submittal Date as defined therein. Notwithstanding anything else herein to the contrary, the Completion Deadline may be extended on a day-for-day basis for any and all Excusable Delays. Any Excusable Delay due to a Force Majeure event shall be governed by the terms of Article X below. In addition to any extensions for Excusable Delays, Seller may extend the Completion Deadline for up to one hundred twenty (120) days if (A) the Completion Deadline, as requested to be extended by Seller, can reasonably be satisfied within the extension time requested by Seller; (B), Seller has been making diligent efforts to meet the original Completion Deadline and continues to consistently make diligent efforts throughout the extended period to achieve the extended Completion Deadline; and (C), prior t...
Sample 1See All (4)
AutoNDA by SimpleDocs

Related to Reasonable Efforts, Notice of Completion, Extension

  • Notice of Completion The Interconnection Customer shall notify the Transmission Provider and the Interconnected Transmission Owner in writing when it has completed construction of (i) the Customer Facility;

  • Diligent Completion The Company agrees to use its reasonable efforts to cause the completion of the Project as soon as practicable, but in any event on or prior to the end of the Investment Period.

  • Required Acceptance of Daily Load Deliveries and Notification If the State is harmed by purchaser’s refusal to accept up to 10 truck deliveries of any one sort per day, Purchaser will be in breach of contract and subject to damages as per the D-026.2 and D-027.2 clauses. A truck delivery is all the wood delivered including sorts on super trucks, mule trains and pups brought to the delivery point by a single truck. The Purchaser shall notify the Contract Administrator at least 48 hours in advance if:

  • Notice of Commencement A Notice of Commencement shall be filed by the Contractor with the Clerk of the Superior Court in the county in which the Project is located, pursuant to O.C.G.A. §13-10-62.

  • Renewal Notice; Notification of Changes Subject to governing law, XOOM can renew this Agreement with new or revised Terms. XOOM will send you written notice at least (30) days before the end of the Term. The notice will specify the date by which you must advise XOOM if you do not want to renew your Agreement. If you do not advise XOOM by the specified date, this Agreement will automatically renew at the fixed rate or variable rate then in effect in accordance with the notice. XOOM reserves the right, with fifteen (15) days’ notice, to amend this Agreement to adjust its service to accommodate any change in regulations, law, tariff or other change in procedure required by any third party that may affect XOOM’s ability to continue to serve you under this Agreement.

  • Payment for Material Completion The Contractor may request payment of the remaining contract balance, including retainage, less amounts credited the Owner or incurred as liquidated damages, and less amounts withheld for the Punchlist by reason of Minor Items or Permitted Incomplete Work (See Paragraph 6.5.3.2). Payment for Material Completion shall be made by a check payable jointly to the Contractor and Surety and shall be mailed to the Surety.

  • Notice of Testing The Contractor shall give the ODR and the A/E timely notice of its readiness and the date arranged so the ODR and A/E may observe such inspection, testing or approval.

  • Reasonable Suspicion Testing The Employer may, but does not have a legal duty to, request or require an employee to undergo drug and alcohol testing if the Employer or any supervisor of the employee has a reasonable suspicion (a belief based on specific facts and rational inferences drawn from those facts) related to the performance of the job that the employee:

  • CAFA Notice Pursuant to 28 U.S.C. § 1715, not later than ten (10) days after the Agreement is filed with the Court, the Settlement Administrator shall cause to be served upon the Attorneys General of each U.S. State in which Settlement Class members reside, the Attorney General of the United States, and other required government officials, notice of the proposed settlement as required by law, subject to Paragraph 5.1 below.

  • Final Notice of Non-Compliant Work The Final Notice of Non-Compliant Work issued as a result of the Inspection for Material Completion, also known as the Final Punch List. Upon the completion or correction of this Non- Compliant Work (“punch list” work) the Design Professional will issue the Final Certificate.

Time is Money Join Law Insider Premium to draft better contracts faster.