NOTICE OF LABOR DISPUTES. (a) If the Contractor has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of this Contract, the Contractor immediately shall give notice, including all relevant information, to the Authority.
NOTICE OF LABOR DISPUTES. Whenever Seller has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of this Agreement, Seller shall immediately give notice thereof to Cadence, including all relevant information with respect thereto. Delivery delays caused by labor disputes shall be governed by Section 2 of this Agreement.
NOTICE OF LABOR DISPUTES. Whenever any actual or potential labor dispute delays or threatens to delay the timely performance of this order, Seller shall immediately give notice thereof to Buyer.
NOTICE OF LABOR DISPUTES. Whenever an actual or potential labor dispute, or any government embargo or regulatory or tribunal proceedings relating thereto, is delaying or threatens to delay the timely performance of the Agreement, Supplier will immediately notify Applied of such dispute and furnish all relevant details, regardless of whether said dispute arose directly or indirectly as a result of an actual or potential dispute within the Supplier's sub-tier supply base or Supplier's own operations.
NOTICE OF LABOR DISPUTES. Whenever an actual or potential labor dispute is delaying or threatens to delay the timely performance of this Order, Seller shall immediately give notice thereof, including all relevant information with respect thereto, to Buyer. Any subcontract hereunder as to which a labor dispute may delay the timely performance of this Order, shall provide that in the event its timely performance is delayed or threatened to be delayed by any actual or potential labor dispute, the subcontractor shall immediately notify Seller of all relevant information with respect to such dispute.
NOTICE OF LABOR DISPUTES. If RPTA has knowledge of any actual or threatened labor dispute that is delaying or threatens to delay the timely or proper performance of this Agreement, RPTA shall immediately give Tempe Notice of this dispute, including all relevant information.
NOTICE OF LABOR DISPUTES. Borrower will notify Bank in writing (i), promptly upon Borrower’s learning thereof, of (a) any labor dispute to which Borrower may become a party and which may have a Material Adverse Effect or (b) any strikes, walkouts, or lockouts relating to any of its plants or other facilities, and (ii) the entering into of any labor contract relating to any of its plants or other facilities.
NOTICE OF LABOR DISPUTES. 1. Whenever the Design-Builder has knowledge that any actual or potential labor disputes is delaying or threatens to delay the timely performance of this Contract, the Design-Builder must immediately give notice to the Commission Representative in accordance with the Notice provision of Section 22.05 and must include all available information with respect thereto to the Commission.
NOTICE OF LABOR DISPUTES. Seller shall immediately notify Boeing of any actual or potential labor dispute that may disrupt the timely performance of an Order. Seller shall include the substance of this Section 4.3, including this sentence, in any subcontract relating to an Order if a labor dispute involving the subcontractor would have the potential to delay the timely performance of such Order. Each subcontractor, however, shall only be required to give the necessary notice and information to its next higher-tier subcontractor.
NOTICE OF LABOR DISPUTES. Whenever Seller has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of this Subcontract, Seller shall immediately give notice thereof, including all relevant information relating thereto, to Buyer. OCCUPATIONAL SAFETY AND HEALTH ACT (OSHA) COMPLIANCE Any Work furnished by Seller pursuant to this Subcontract shall comply with the Occupational Safety and Health Act of 1970 and regulations issued pursuant thereto, collectively referred to as “OSHA.” Seller agrees to repair, modify, or replace any Work not complying with OSHA at Seller’s sole cost and expense, and to hold harmless and indemnify Buyer (and Buyer’s affiliates and their respective directors, officers, employees, and agents) from any liability and expense (including attorneys fees) by reason of property damage or personal injury (including death) occasioned in whole or in part from a violation of OSHA. PACKAGING AND SHIPMENT
