NOTICE OF LABOR DISPUTES. (a) If the Contractor has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of this Contract, the Contractor immediately shall give notice, including all relevant information, to the Authority.
Appears in 23 contracts
Samples: Logic Elite Service Agreement, E Contractual Terms and Conditions, app.capmetro.org
NOTICE OF LABOR DISPUTES. (a) A. If the Contractor has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of this Contract, the Contractor immediately shall give notice, including all relevant information, information to the AuthorityOWNER.
Appears in 21 contracts
Samples: Contract Agreement, Contract Agreement, Contract Agreement
NOTICE OF LABOR DISPUTES. (a) If the Whenever Contractor has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely time of performance of this Contractcontract, the Contractor shall immediately shall give noticenotice thereof, including all relevant informationinformation with respect thereto, to the AuthorityCounty.
Appears in 6 contracts
Samples: Price Construction Contract, Price Construction Contract, Price Construction Contract
NOTICE OF LABOR DISPUTES. (a) A. If the Contractor has knowledge that any actual or potential labor dispute is delaying or threatens CONSTRUCTION CONTRACT SPECIAL PROVISIONS to delay the timely performance of this Contract, the Contractor immediately shall give notice, including all relevant information, information to the AuthorityOWNER.
Appears in 1 contract
Samples: Contract Agreement
NOTICE OF LABOR DISPUTES. (a) If Whenever the Contractor has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of this Contractcontract, the Contractor shall immediately shall give noticenotice to the Department, including all relevant information, to the Authorityinformation with respect thereto.
Appears in 1 contract
Samples: Supply and Service Agreement (Netco Waterbury Limited Partnership)
NOTICE OF LABOR DISPUTES. (a) If the Whenever Contractor has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of this Contract, the Contractor shall immediately shall give noticenotice thereof, including all relevant informationinformation relating thereto, to the AuthorityBuyer.
Appears in 1 contract
Samples: Definitions
NOTICE OF LABOR DISPUTES. (a) If the Contractor has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of this ContractContract Modification, the Contractor immediately shall give notice, including all relevant information, to the AuthorityContracting Officer.
Appears in 1 contract
Samples: app.capmetro.org
