FINAL ACCEPTANCE OF WORKS Sample Clauses

FINAL ACCEPTANCE OF WORKS a) On receipt of The Owner's request for a final inspection as provided for in Clause 16 hereof, the City will again inspect the Works, and if the City is satisfied and provided that The Owner has otherwise complied with this Agreement including Clause 9b) hereof, the City will issue a Certificate of Assumption of Works and Facilities.
Sample 1Sample 2
AutoNDA by SimpleDocs
FINAL ACCEPTANCE OF WORKS. 63.2.1 Within twenty (20) days prior to the expiry of the guarantee period for the provisional acceptance of works a final acceptance shall be scheduled upon the request by the Contractor, subject to correction of all mistakes notified to the Contractor during the guarantee period.
Sample 1
FINAL ACCEPTANCE OF WORKS. At the end of the Defects Liability Period and provided all defects notified to the Contractor by the Superintendent have been satisfactorily completed, the Contractor shall notify the Superintendent in writing of the completion of the work. The Superintendent will promptly, by inspection, satisfy himself as to the actual completion of the work in accordance with the terms of the Contract and shall, if in agreement, issue a Final Certificate in accordance with the General Conditions of Contract. The Final Certificate will not be issued until the Superintendent is satisfied that the performance of the works is in conformity with all requirements of this Specification and with all performance guarantees tendered by the Contractor. The Contractor may during the Defects Liability Period be called upon to further amend the Works-as-Executed drawings should it be found necessary for the Superintendent to order modifications to the work.
Sample 1
FINAL ACCEPTANCE OF WORKS. On receipt of the Developer's request for a final inspection, the Township will again inspect the work and, if satisfied, will issue the Certificate of Maintenance and Final Acceptance, at which time the remaining 10% of the cash or Letters of Credit will be discharged by the Township in accordance with Clause 15. It should be noted that the Certificate of Maintenance and Final Acceptance may be applied for by the Developer two years after the receipt of the Certificate of Substantial Completion and Acceptance.
Sample 1
FINAL ACCEPTANCE OF WORKS a) The Township Engineer may issue a Certificate of Final Acceptance for the Works in any street block upon completion of the second lift of asphalt and concrete curbs, and upon the correction of all previously identified deficiencies. No later than twelve (12) months after the Final Acceptance of the Works or in the meantime if the need arises, the Township Engineer shall inspect them and submit a deficiency list to the Owner. Thereafter the Owner shall immediately rectify the deficiencies.
Sample 1

Related to FINAL ACCEPTANCE OF WORKS

  • Acceptance of Work Upon Purchaser’s written request and assurance that work has been com- pleted, Forest Service shall perform an inspection within 5 days, excluding weekends and Federal holidays, so as not to delay unnecessarily the progress of Purchaser’s Operations. Such a request may be for acceptance of:

  • Final Acceptance When the Project/Service or any portion thereof, as designated by the COUNTY, is ready for its intended use, the COUNTY and any other invited parties shall make an inspection of the Project/Service, to verify its completeness and develop a punch list of items needing completion or correction before final payment will be made. CONTRACTOR shall have ten (10) calendar days to correct all deficiencies. An eighty-dollar ($80.00) re-inspection fee shall be applied for the third inspection and any required re-inspection thereafter. The COUNTY shall have the right to exclude CONTRACTOR from those portions of the work designated as complete after the inspection; provided, however, that CONTRACTOR will have reasonable access for the time allotted by the COUNTY to complete or correct items on the punch list. When the work provided for under this Agreement has been completely performed by CONTRACTOR, and the final inspection has been made by the COUNTY, a final invoice will be prepared by the CONTRACTOR. The amount of this invoice, less any sums that may have been deducted or retained under the provisions of this Agreement, will be paid to CONTRACTOR in accordance with this Agreement, and after CONTRACTOR has agreed in writing to accept the balance due, as determined by the COUNTY, as full settlement of the account under the contract and of all claims in connection therewith. Occupancy by the COUNTY alone does not constitute final acceptance.

  • CORRECTION OF WORK 13.2.1 The Contractor shall be responsible for correcting all Work which the Architect has found to be defective or which fails to conform to the Contract Documents whether observed be- fore or after Substantial Completion and whether or not fabricated, installed or completed. The Contractor shall bear all costs of correcting such rejected Work, including compensation for the Architect's and the State’s additional services made necessary thereby. The Architect, upon a finding of defect or failure to conform, shall immediately notify the State and Contractor, in writing, of the defect. The Contractor shall begin correcting the defective or non-conforming Work within ten (10) days unless the State agrees to a Change Order which reflects the reduction in Contract Sum due to the value of diminishment of the defective or nonconforming Work.

  • Payment Does Not Imply Acceptance of Work The granting of any payment by City, or the receipt thereof by Contractor, shall in no way lessen the liability of Contractor to replace unsatisfactory work, equipment, or materials, although the unsatisfactory character of such work, equipment or materials may not have been apparent or detected at the time such payment was made. Materials, equipment, components, or workmanship that do not conform to the requirements of this Agreement may be rejected by City and in such case must be replaced by Contractor without delay.

  • Completion of Work Contractor is accountable for completing the Work within the Contract Time stated in the Contract, or as otherwise amended by Change Order.

  • Statement of Work The Contractor shall provide the services and staff, and otherwise do all things necessary for or incidental to the performance of work, as set forth below:

  • Rejection of Work Using the Notice of Non-Conforming Work procedures outlined in the General Conditions, the Design Professional shall reject work that does not comply with the requirements of the Contract Documents or that does not comply with the applicable laws and codes. The Design Professional shall have authority to order testing of the Work, as is provided in the Contract Documents or as otherwise required in its judgment, whether such work is fabricated, installed, or completed.

  • ACCEPTANCE OF NONCONFORMING WORK If the Owner prefers to accept Work that is not in accordance with the requirements of the Contract Documents, the Owner may do so instead of requiring its removal and correction, in which case the Contract Sum will be reduced as appropriate and equitable. Such adjustment shall be effected whether or not final payment has been made.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!