FINISHING THE CONTRACT Sample Clauses

FINISHING THE CONTRACT. 27. 61.1 As built drawings shall be supplied by the contractor by 30 days after the construction completion date. Operating manual shall be supplied by the contractor by [NIL].
Sample 1Sample 2Sample 3See All (10)
AutoNDA by SimpleDocs
FINISHING THE CONTRACT. 55.1. The Contractor shall request the Engineer to issue a Certificate of Completion of the Works and the Engineer will do so upon deciding that the Work is completed.
Sample 1
FINISHING THE CONTRACT. The bidder shall request MP State Food Craft Institute, Rewa to issue a certificate of completion of the Supply, and the MP State Food Craft Institute, Rewa will do so upon deciding the
Sample 1Sample 2
FINISHING THE CONTRACT. 53 Completion 53.1 The Contractor shall request the Project Manager to issue a Certificate of Completion of the Works, and the Project Manager shall do so upon deciding that the whole of the Works is completed.
Sample 1Sample 2
FINISHING THE CONTRACT. GCC 56.1 * The date by which operating and maintenance manuals are required is within 28 days of issue of certificate of completion of whole or section of work, as the case may be 30.06.2015 * The date by which “as-built” drawings (in scale…) including a compact disc containing digitized drawings in 2 sets are required is within 28 days of issue of certificate of completion of whole or section of the work, as the case may be 30.06.2015.
Sample 1Sample 2
FINISHING THE CONTRACT. 26. 61.1 As built drawings shall be supplied by the contractor by: Fourteen (14) days after Completion Date. Operating manual shall be supplied by the contractor by: Fourteen (14) days after Completion Date.
Sample 1Sample 2
FINISHING THE CONTRACT. GCC 58.1 The date by which “as-built” drawings (in scale Horizontal 1:2000, Vertical 1:200 in A2 size) in 2 sets are required is within 28 days of issue of certificate of completion of whole or section of the work, as the case may be. [58] GCC 58.2 The amount to be withheld for failing to supply “as built” drawings/ or operating and maintenance manuals by the date required is Rs. 50 Lacs
Sample 1
AutoNDA by SimpleDocs
FINISHING THE CONTRACT. GCC 66.1 The date by which operating and maintenance manuals are required is [insert date]. The date by which “as built” drawings are required is [insert date].
Sample 1
FINISHING THE CONTRACT. GCC 55.1 Replace the Sub-Clause with the following: The Contractor shall request the Engineer to issue a certificate of Completion of the Works, and the Engineer shall do so upon deciding that the Part-1 Works is completed in all respects.
Sample 1

Related to FINISHING THE CONTRACT

  • SUBLETTING OR ASSIGNING THE CONTRACT This provision is applicable to all Federal-aid construction contracts on the National Highway System.

  • Execution of the Contract 30.1 This Contract and any amendments thereto may be executed in any number of counterparts with the same effect as if all parties hereto had signed the same document. All counterparts will be construed together and will constitute one and the same original agreement.

  • TERM OF THE CONTRACT A. This Contract has an initial term of one (1) year and a bilateral option provision for three (3) additional terms. The total term of the Contract cannot exceed four (4) years. An extension may be offered beyond the original four-year term if Sourcewell deems such action to be in the best interests of Sourcewell and its Members. The Contractor may withdraw from the Contract on each anniversary of the award, provided that the Contractor gives 60 Days written notice of its intent to withdraw. Sourcewell may, for any reason, terminate this Contract at any time.

  • PARTIES TO THE CONTRACT This Contract is solely between the Company and the SBA which administers the FHCF. In no instance shall any insured of the Company or any claimant against an insured of the Company, or any other third party, have any rights under this Contract, except as provided in Article XIV. The SBA will only disburse funds to the Company, except as provided for in Article XIV of this Contract. The Company shall not, without the prior approval of the Office of Insurance Regulation, sell, assign, or transfer to any third party, in return for a fee or other consideration any sums the FHCF pays under this Contract or the right to receive such sums.

  • SUBJECT OF THE CONTRACT 1. The subject of the Contract is the creation of the work ordered as a result of own creative intellectual activity of the Author – to elaborate the evaluation of applications delivered to the Client (hereinafter “Work”) within an open call for submitting applications to solve projects of research and development in particular science and technology fields pursuant to the Article 6 Section 3 of Act No.172/2005 Coll. On State Aid Administration and Central State Administration as amended (hereinafter “Act”) subsequently as amended, labelled VV 2021 (hereinafter “Open Call”).

  • OBJECT OF THE CONTRACT 1.1. FINC’s obligations shall consist in supplying one “Anchor Handling, Towing and Supply“ Vessel (hereinafter referred to as the "Ship"), to be built at FINC’s Shipyards and delivered to the Owner, which agrees to accept delivery from FINC, and built in accordance with the conditions and stipulations stated herein, and as specified in the following technical documents: Specification : 382688/BS 8000000M rev. 0 dated 16/03/07 – Technical Specifications; Side Letter No. 1 dated 20/03/07. Drawings : 2000-100 rev. 02 – General Arrangement (Xxxx Maritime) 2000-101 rev. 02 – Tankplan (Xxxx Maritime) which, signed by both Parties, are an integral part hereof, although not attached hereto.

  • Duration of the contract This contract becomes effective on , and will continue in effect for 365 days from the above date. Either party may terminate treatment with reasonable notice to the other party, as provided in the agreement. Notwithstanding this right to terminate treatment, both Provider and Beneficiary agree that the obligation not to pursue Medicare reimbursement for items and services provided under this contract will survive this contract.

  • SCOPE OF THE CONTRACT 4.1 The Contractor shall perform the Services set out [in Schedule 1] [below2] in accordance with the Contract.

  • of the Contract (7) No action can be instituted on this bond after one year from the date of Final Completion as determined pursuant to Article 6.2.2. SIGNED AND SEALED THIS DAY OF , 20 . ATTEST: (NAME OF Contractor) By Secretary(*) President (SURETY) (*)(*) (TITLE) (*) Please apply seal of Corporation over Secretary’s Signature. (*)(*)Please apply seal of Surety and arrange for countersignature by a “Georgia Licensed Agent” of Surety pursuant to O.C.G.A. §33-23-5. Kindly show title of the aforesaid agent as “Georgia Licensed Agent.” (*) Attach Power of Attorney GEORGIA SECURITY AND IMMIGRATION COMPLIANCE ACT AFFIDAVIT(S)

  • Formation of the contract i. A contract for the Services will be formed between you and us, once you have given us a signed, fully completed, Admissions form, Contract and a £15 booking fee, and we have confirmed to you in writing that your application for a place has been successful.

Time is Money Join Law Insider Premium to draft better contracts faster.