Comparative Fault. Except as expressly provided to the contrary herein, it is the intent of the Parties that where fault is determined to have been joint or contributory, principles of comparative fault will be followed and each Party shall bear the proportionate cost of any Losses attributable to such Party's fault.
Comparative Fault. Each party’s obligations in this SECTION 6 shall apply even if the Claim and/or Damages are due, or alleged to be due, in part to any concurrent negligence or other fault of the Indemnitee, breach of contract or warranty by the Indemnitee, or strict liability without regard to fault; provided, however, that the Indemnitor’s contractual obligations shall not extend to the percentage of the third party claimant’s Damages attributable to the Indemnitee’s negligence or other fault, breach of contract or warranty, or to strict liability imposed upon Indemnitee as a matter of law.
Comparative Fault. If an Injury is caused by the negligence or fault of both Vendor (and/or any Vendor Personnel), on the one hand, and any of the HealthTrust Indemnitees, on the other hand, the apportionment of said Damages shall be shared between Vendor and such HealthTrust Indemnitees based upon the comparative degree of each other’s negligence or fault, and each shall be responsible for its own defense and costs, including but not limited to the costs of defense, attorneys’ fees, witnesses’ fees and expenses incident thereto.
Comparative Fault. THE PARTIES AGREE THAT THE INDEMNITIES ABOVE SHALL CONTINUE IN EFFECT EVEN IN THE CASE WHERE A PORTION OF THE DAMAGE IS CAUSED BY THE ACTS OR OMISSIONS (INCLUDING NEGLIGENCE) OF OCA. HOWEVER, THE PARTIES FURTHER AGREE THAT CONTRACTOR IN NO WAY WAIVES ANY DEFENSE OTHERWISE AVAILABLE TO IT IN ANY SUCH EVENT, INCLUDING THE RIGHT TO ASSERT COMPARATIVE FAULT OF OCA.
Comparative Fault. Supplier and the applicable Eligible Recipient shall be liable under Sections 17.1 through 17.4, respectively, only to the extent of the respective obligations specifically imposed upon them by such Sections; provided, however, nothing herein shall be interpreted as relieving or limiting the indemnifying party’s defense obligations hereunder, the parties hereby agreeing that the resolution of each party’s respective level of fault shall be delayed until after the resolution of the underlying third party claim (whether by settlement, final non-appealable judgment or binding arbitration). In the event both parties bear fault for a matter, each party’s liability (including liability for defense costs and deductible amounts and self-insured retentions under insurance policies) shall be equal to the percentage determined to be due to the fault of such party as agreed upon by the parties or as fixed by settlement agreement approved by the parties or set forth in a final judgment of a court of competent jurisdiction or the decision of the arbitrator or arbitration panel in a binding arbitration proceeding. The parties agree that the provisions of this Section 17.8 shall only apply in the event of a third party claim.
Comparative Fault. To the extent that either Landlord or Tenant (inclusive of their respective employees, agents, contractors, servants, concessionaires, licensees, or invitees) is finally held by a court of competent jurisdiction to be partially at fault for any claim for which an indemnity obligation arises hereunder, then neither Landlord nor Tenant as against each other shall indemnify, defend or hold the other harmless and each party shall be liable only to the extent of the percentage of its own fault as finally held by the court of competent jurisdiction.
Comparative Fault. Except as expressly provided to the contrary herein, it is the intent of the Parties that where fault is determined to have been joint or contributory, principles of comparative fault will be followed and each Party shall bear the proportionate cost of any Losses attributable to such Party’s fault. Survival of Indemnity Obligations. The indemnities set forth in this Article 24 shall survive the Final Completion Date or the earlier termination of this Agreement for a period expiring five (5) years following the Final Completion Date or said termination, whichever first occurs; provided that (i) with respect to indemnities arising out of or related to the Warranties, the indemnities shall survive for a period of five (5) years after the last Day of the applicable Warranty Period; (ii) indemnities arising out of or related to environmental matters (including as set forth in Article 12) shall survive for a period equal to the applicable statute of limitations; (iii) the indemnities arising out of Section 24.3 shall survive for a period expiring ten (10) years following the Final Completion Date or the earlier termination of this Agreement; and (iv) indemnities arising out of or related to Tax shall survive for a period equal to the later of (A) five (5) years following the Final Completion Date and (B) the applicable statute of limitations plus one hundred twenty (120) Days (such period, as applicable, the “Survival Period”). All Claim Notices must be delivered, if at all, to the applicable Party prior to the expiration of such applicable Survival Period. If any Claim Notice is made within such Survival Period, then the indemnifying period with respect to all claims identified in such Claim Notice (and the indemnity obligation of the Parties hereunder with respect to such claim) shall extend through the final, non-appealable resolution of such claims. For purposes of clarification hereunder, without limiting the other rights granted hereunder to either Party, a Party may enforce the indemnity provisions hereunder pursuant to the provisions of this Article 24 without having to declare an Owner Event of Default or a Contractor Event of Default, as applicable. CONFIDENTIALITY
Comparative Fault. 18 ARTICLE 15 - ALTERATIONS.......................................... 18 15.1 Alterations by Tenant................................ 18 15.2 Alterations by Landlord.............................. 19
Comparative Fault. Any Loss sustained by an Indemnified Party shall be reduced to the extent such party’s own negligence or breach of representations, warranties or covenants under this Agreement caused such Loss.
Comparative Fault. In the event that HNT-AZ, HNL and ------------------ SafeHealth claim indemnity under Sections 8.01 and 8.02 of this Agreement, and in the event it is determined that each is entitled to indemnity from the other, then the amount of indemnity due from each to the other shall be determined according to comparative fault principles.
