Approval by Landlord. Tenant’s Plans and any revisions thereof shall be subject to Landlord’s approval, which approval or disapproval:
Approval by Landlord. Landlord’s approval of, or requirements concerning, Lines and Equipment, the plans, specifications or drawings related thereto or Tenant’s contractors, subcontractors, or service provider, shall not be deemed a warranty as to the adequacy thereof, and Landlord hereby disclaims any responsibility or liability for the same. Landlord further disclaims all responsibility for the condition, security or utility of Lines and Equipment, and makes no representation regarding the suitability of any such Lines or Equipment for Tenant’s intended use or the adequacy or fitness of the Building Systems for any such Lines or Equipment.
Approval by Landlord. No approval by Landlord of any insurer shall be construed to be a representation, certification or warranty of its solvency and no approval by Landlord as to the amount, type or form of any insurance shall be construed to be a representation, certification or warranty of its sufficiency.
Approval by Landlord. Tenant's Plans and any revisions thereof shall be subject to Landlord's approval, which approval or disapproval (i) shall not be unreasonably withheld, provided however, that Landlord may disapprove Tenant's Plans in its sole discretion if they (a) adversely affect the structural integrity of the Building, (b) adversely affect the Building Systems (as defined in Section 1.03 of the Lease), the Common Areas or any other tenant space (whether or not currently occupied), (c) fail to fully comply with Laws, (d) affect the exterior appearance of the Building, (e) involve any installation on the roof, or otherwise affect the roof, roof membrane or any warranties regarding either, (f) provide for improvements which require removal of any portion of the slab, except that Landlord will allow Tenant to install freezers and coolers in a portion of the Premises, remove the existing slab where the freezers and coolers will be located, and install related plumbing, wiring, subsurface protection, support and new slab, but the plans and specifications therefor shall be subject to Landlord's approval, in its sole discretion; and (ii) shall not be delayed beyond ten (10) business days with respect to initial submissions and major change orders (those which impact Building Systems or any item listed in above in this B(i)(a)-(f)) and beyond five (5) business days with respect to required revisions and other change orders. If Landlord disapproves of any of Tenant's Plans, Landlord shall advise Tenant of what Landlord disapproves in reasonable detail. After being so advised by Landlord, Tenant shall submit a redesign, incorporating the revisions required by Landlord, for Landlord's approval. The approval procedure shall be repeated as necessary until Tenant's Plans are ultimately approved. Approval by Landlord shall not be deemed to be a representation or warranty by Landlord with respect to the safety, adequacy, correctness, efficiency or compliance with Laws of Tenant's Plans. Tenant shall be fully and solely responsible for the safety, adequacy, correctness and efficiency of Tenant's Plans and for the compliance of Tenant's Plans with any and all Laws.
Approval by Landlord. This Sublease is conditional upon written --------------------- consent being obtained from the Landlord. In the event the Landlord does not give its consent, either the undersigned parties may, at its option, rescind its signature and this Sublease shall thereafter be of no force or effect.
Approval by Landlord. Tenant's Plans shall be subject to Landlord's approval, which approval shall not be unreasonably withheld, conditioned or delayed. Landlord shall be entitled to withhold approval if the proposed plans and specifications (i) interfere with the structural integrity of the Building, (ii) overload the utility systems of the Building, (iii) violate any applicable laws or regulations, or (iv) materially affect the architectural integrity of the Building. If Landlord disapproves of any of Tenant's Plans, Landlord shall advise Tenant in reasonable detail of required revisions and the reasons therefor. After being so advised by Landlord, Tenant shall promptly submit a redesign, incorporating the revisions required by Landlord, for Landlord's approval. If Tenant has reason to dispute any Landlord disapproval, then the parties shall meet within 5 days and attempt to resolve the dispute. If the Parties are unable to resolve their differences as to Tenant's Preliminary Plans within 5 days after meeting, then either party may initiate an arbitration procedure by notifying the other Party of the need to submit their disagreements to binding and final arbitration by a mutually acceptable arbitrator with at least ten (10) years commercial office design experience. If the parties are unable to agree on the arbitrator within a period often (10) days of notice, then either party may request resolution by a single arbitrator before the American Arbitration Association, as set forth at the end of Lease Section 3(c).
Approval by Landlord. Tenant’s Plans shall be subject to Landlord’s approval, which approval shall not be unreasonably conditioned, withheld or delayed. Landlord agrees to approve or disapprove Tenant’s Plans within ten (10) business days after receipt thereof.
Approval by Landlord. Tenant's Plans shall be subject to Landlord's reasonable approval. Landlord shall have ten (10) business days following receipt of Tenant's Plans to approve or disapprove the submissions by Tenant. If Landlord reasonably disapproves of any of Tenant's Plans, Landlord shall advise Tenant of the required revisions concurrently with such disapproval. After being so advised by Landlord, Tenant shall promptly submit a redesign, addressing the revisions required by Landlord, for Landlord's reasonable approval. Landlord shall then have five (5) business days to approve or disapprove any re-submittal of Tenant's plans, and failure to respond within such 5-business day period shall be deemed Landlord's approval of such re-submitted plans and specifications. If Tenant's Plans have not been approved within thirty (30) days from the date of this Lease, the parties agree to promptly meet in good faith to attempt to reach agreement regarding Tenant's Plans. Approval by Landlord shall not be deemed to be a representation or warranty by Landlord with respect to the safety, adequacy, correctness, efficiency or compliance with law of Tenant's Plans.
Approval by Landlord. Landlord has approved this Assignment as evidenced by the executed letter agreement attached hereto as Exhibit “B”.
Approval by Landlord. No alterations, renovations, improvements, other installation to be made in or on the Premises (including, but not limited to, electrical, plumbing, and mechanical installation and storefront or facade construction) shall be commenced until plans and specifications therefor have been submitted to Landlord and Landlord has approved same in writing. The plans and specifications required hereunder and the improvements to be made pursuant thereto shall be certified and performed by a person duly qualified to do the work described in said plans and specifications in the jurisdiction wherein the Premises are situated, and same shall comply with all applicable codes, rules, regulations and ordinances.
