Lessor Work definition

Lessor Work shall have the meaning contained in Article 11.
Sample 1Sample 2Sample 3
Lessor Work means “Structural Work” and “Capital Work,” collectively. Notwithstanding the foregoing or anything to the contrary herein, Lessee shall pay the cost of repairs for any damage to the Structural Elements, elements which would comprise items of Capital Work or the Exterior Common Areas caused by Lessee’s negligence, willful misconduct or the installation of any Alterations, to the extent (if any) not covered by the property insurance required to be carried by Lessor under the Lease.
Sample 1Sample 2Sample 3
Lessor Work means the construction of the Building and the Premises pursuant to the Design Documents.
Sample 1Sample 2

Examples of Lessor Work in a sentence

  • Lessee agrees to indemnify, defend and save the Lessor and the Premises harmless from and against any and all claims for mechanics’, materialmen’s or other liens in connection with any work by Lessee, except to the extent such claims are the result of Lessor’s failure to meet its funding obligations under this Lease, in which case Lessor agrees to indemnify, defend and save Lessee and the Premises harmless from and against any and all such claims and for any liens in connection with any Lessor Work.

  • Notwithstanding the foregoing or anything to the contrary herein, Lessee shall not be obligated to perform any Lessor Work or any Lessor Exterior Work (including, without limitation, any repair or maintenance of (x) the Base Building Systems to the extent that they serve the garage, and (y) any electrical, water, sewer and other utility lines that run between the exterior boundary of the Building and the respective utility providers junction box in the public right of way).

  • Lessor shall not be responsible for the interruption or shortage of any services or suspension of the use of any common facilities that were caused by the Lessor Work.

  • Upon the earlier to occur of the completion of the Lessor Work or the end of the interference with the Business of Lessee, (i) Lessee is obligated to resume occupancy of the Leased Premises, and (ii) Lessee shall resume the payments of the next regularly scheduled Rent, Lessor Maintenance Fee, Other Costs and related VAT in accordance with the terms of this Agreement, pro rated, as applicable, for the number of days of any partial month of Rent.

  • Lessor hereby agrees that any and all Lessor Work and any and all other development, demolition, improvement, partitioning and remodeling of the Property undertaken by Lessor or any of its agents shall not disturb Lessee’s use and enjoyment of the Tully’s Premises nor negatively impact Lessee’s security nor increase Lessee’s costs of security in the Tully’s Premises.

  • The DER will direct the employee to obtain, within 5 days, an evaluation from a licensed physician, acceptable to the MRO, who has expertise in the medical issues raised by the employee’s failure to provide a sufficient specimen.

  • Any costs related to establishment of separate metering shall be considered to be costs of Lessor Work.

  • Lessee shall at all times during the term hereof and at its own expense, keep the Premises in good order, condition and repair, reasonable wear and tear damage and destruction and Lessor Work excepted, including such repairs, and alterations as may be required by fire insurance companies, by law, ordinance or regulation of any public authority relating to the use or occupancy of the Premises or otherwise.

  • Effective as of the date (the “Expansion Commencement Date”) that occurs two (2) business days after the date of Lessor’s delivery of the Lessor Work Completion Notice (as that term is defined below in Section 5), Lessee shall lease from Lessor and Lessor shall lease to Lessee the Expansion Premises.

  • Lessor shall pay for the costs associated with Lessor’s Work, subject to Lessee’s reimbursement to Lessor of fifty percent (50%) of the documented out-of-pocket costs actually incurred by Lessor for that portion of Lessor’s Work described in sub part (ii) above within twenty (20) business days of Lessee’s receipt of the Lessor Work Completion Notice, together with invoices or other documentation supporting such costs.


More Definitions of Lessor Work

Lessor Work has the meaning set forth in Section 4.2 of this Lease.
Sample 1

Related to Lessor Work

  • Landlord Work means the work, if any, that Landlord is obligated to perform in the Premises pursuant to a separate agreement (the “Work Letter”), if any, attached to this Lease as Exhibit C.

  • Landlord’s Work means the work of constructing the Tenant Improvements.

  • Tenant Work All work installed or furnished to the Premises by Tenant in connection with Tenant’s initial occupancy pursuant to Rider 2 and the Workletter.

  • Tenant’s Work means all improvements, alterations, fixture, equipment, and signage installation, and furniture placement necessary or appropriate for the conduct of the Permitted Use, including all work described as Tenant’s Work on Exhibit D, attached (the “Work Letter”).

  • Tenant Improvement Work means the construction of the Tenant Improvements, together with any related work (including demolition) that is necessary to construct the Tenant Improvements.

  • Building Work has the meaning given to it in section 6 of the Building and Construction Industry (Improving Productivity) Act 2016 (Cth);

  • Base Building Work means the base building work for the Building as described in this Manual.

  • The Work means each and every activity required for the successful performance of the services described in Section II, the Terms of Reference.

  • Tenant Improvements Defined in Exhibit B, if any.

  • Major Work means any Work to Construct or Maintain the Distribution System that costs more than One Hundred Thousand ($100,000.00) Dollars;

  • Construction Work means any work in connection with

  • Work space means that portion of the court’s facilities dedicated to each court reporter, including but not limited to actual space in the courtroom and any designated office space.

  • Tenant Delays A "Tenant Delay" shall mean any delay in Substantial Completion of the Building as a result of any of the following: (i) Tenant's failure to complete or approve the Tenant Improvement Plans by the dates set forth in Section 5.B, (ii) Tenant's failure to approve the bids for construction by the dates set forth in Section 5.C, (iii) changes to either the Shell Plans and Specifications or the Tenant Improvement Plans requested by Tenant which delay the progress of the work, (iv) Tenant's request for materials, components or finishes which are not available in a commercially reasonable time given the target Commencement Date, (v) Tenant's failure to make a progress payment for Tenant Improvement costs as provided in Section 5.F, (vi) Tenant's request for more than one (1) rebidding of the cost of all or a portion of the work, and (vii) any errors or omissions in the Tenant Improvement Plans provided by Tenant's architect. In the event Landlord believes Tenant is causing a Tenant Delay, Landlord shall notify Tenant in writing, state the action or inaction that it believes is causing the Tenant Delay, and state the date from which a Tenant Delay is being calculated. Claim of Tenant Delay shall be made within five (5) days after Landlord's discovery of the occurrence of the event giving rise to such claim. Tenant shall have the right to expedite work, at its sole cost, to minimize the effect of any Tenant Delays, to the extent it is practicable to do so. However, no Tenant Delay shall advance the Commencement Date to a date before the estimated Commencement Date of October 1, 2001. Notwithstanding anything to the contrary set forth in this Lease and regardless of the actual date the Premises are Substantially Complete (but subject to the limitation in the preceding sentence), the Commencement Date shall be deemed to be the date the Commencement Date would have occurred if no Tenant Delay had occurred as reasonably determined by Landlord. In addition, if a Tenant Delay results in an increase in the cost of the labor or materials, Tenant shall pay the cost of such increases.

  • Major renovation means the renovation of a building where:

  • Tenant Delay Any event or occurrence that delays the completion of the Landlord Work which is caused by or is described as follows:

  • Installation Work means the construction and installation of the System and the Start-up, testing and acceptance (but not the operation and maintenance) thereof; all performed by or for the Power Producer at the Premises.

  • this Tenant Work Letter means the relevant portion of Sections 1 through 6 of this Tenant Work Letter.

  • demolition work means a method to dismantle, wreck, break, pull down or knock down of a structure or part thereof by way of manual labour, machinery, or the use of explosives;

  • Excavation work means the making of any man-made cavity, trench, pit or depression formed by cutting, digging or scooping;

  • Landlord Delay means any actual delay in the completion of the Improvements as a result of Landlord’s breach or material default under this Third Amendment (including, without limitation, any breach of representation or warranty); any delays relating to any of the matters specified in Section 5.3 of Exhibit B; any failure to respond to any items required to be furnished or approved by Landlord within a time period expressly set forth in this Third Amendment or the Lease (unless a deemed approval is specified, in which case no Landlord Delay shall be assessed); Landlord’s failure to allow contractors access to the Building or Premises as scheduled in advance with the Building’s property manager or Landlord’s request for material changes in the fmal Plans and Specifications after Landlord’s approval thereof (unless such request was caused by an error or omission by Tenant), provided, however, that notwithstanding the foregoing, no Landlord Delay shall be deemed to have occurred unless and until Tenant has delivered to Landlord a factually correct written notice (the “Landlord Delay Notice”), specifying the bona fide action or inaction which Tenant contends constitutes the Landlord Delay. If such action or inaction is not cured by Landlord within two (2) business days of Landlord’s receipt of such Landlord Delay Notice, then the Landlord Delay shall be deemed to have occurred as of the expiration of such two (2) business day period. A delay in construction of the Improvements due to a Tenant Delay (as defined in Exhibit B, attached to and part of the Original Lease), any Force Majeure event or a delay by any governmental authority (including but not limited to the City of Los Angeles) shall not be deemed a Landlord Delay. Any Landlord Delay Notice shall be sent to the notice address set forth in the Lease with copies to (a) to the property manager at the management office of the Building; and to (b) Xxxxxxx Xxxxxx Management LLC, 000 Xxxxxxxx Xxxxxxxxx, Xxxxx 000, Xxxxx Xxxxxx, Xxxxxxxxxx 00000, Attention: Leasing Legal Department Manager.

  • Subleased Premises means approximately -18;961 rentable square feet on the 141h floor of the Building, as more specifically depicted on Exhibit A attached hereto and made a part hereof. The Subleased Premises include all of the Leased Premises identified in the Prime Lease.

  • a work means the outcome of building or civil engineering works taken as a whole which is sufficient in itself to fulfil an economic or technical function;

  • Alterations means all changes, additions, improvements or repairs to, all alterations, reconstructions, renewals, replacements or removals of and all substitutions or replacements for any of the Improvements or Equipment, both interior and exterior, structural and non-structural, and ordinary and extraordinary.

  • Work area means a room or defined space in a workplace where hazardous chemicals are produced or used, and where employees are present.

  • Leased space means a self−service storage unit or a space located within a self−service storage facility that a lessee is enti- tled to use for the storage of personal property on a self−service basis pursuant to a rental agreement and that is not rented or pro- vided to the lessee in conjunction with property for residential use by the lessee.

  • Major Alteration means change other than repair or replacement of building materials or equipment with materials and equipment of a similar type.