XXXXX DAMAGES Sample Clauses

XXXXX DAMAGES. The Principal Representative and the State of Colorado shall be liable to the Contractor for the payment of any claim for extra costs, extra compensation or damages occasioned by hindrances or delays encountered in the Work only when and to the limited extent that such hindrance or delay is caused by an act or omission within the control of the Principal Representative, the Architect/Engineer or other persons or entities acting on behalf of the Principal Representative. Further, the Principal Representative and the State of Colorado shall be liable to the Contractor for the payment of such a claim only if the Contractor has provided required Notice of the delay or impact, or has presented its claim for an extension of time or claim of other delay or other impact due to changes ordered in the Work before proceeding with the changed Work. Except as otherwise provided, claims for extension of time shall be Noticed and filed in accordance with Article 38, Delays and Extensions of Time, within three (3) business days of the beginning of the delay with any claim filed within seven (7) days after the delay has ceased, or such claim is waived. Claims for extension of time or for other delay or other impact resulting from changes ordered in the Work shall be presented and adjusted as provided in Article 35, Changes in the Work.
Sample 1Sample 2Sample 3See All (7)
AutoNDA by SimpleDocs
XXXXX DAMAGES. For Development Projects for which the Parties agree in the Specifications that the provisions of this Section 4.3.3(f) shall apply, notwithstanding the Development Fees provided for in Section 4.3.4 below, if Supplier fails to deliver any Developed Software which has achieved Final Acceptance by the applicable Development Project Completion Date, then for each calendar week that the System fails to so achieve Final Acceptance beyond the scheduled Development Project Completion Date (as specified in the Implementation Schedule), then Supplier shall deduct from the fees payable pursuant to Section 4.3.4 below an amount equal to the percentage of such fees (or a specified dollar amount) set forth in the applicable Specifications, plus an additional percentage (or dollar amount) for each week thereafter that the System has failed to achieve Final Acceptance (“Delay Damages”). Customer and Supplier acknowledge that the amounts payable by Supplier to Customer under this Section 4.3.3(f) constitute liquidated damages for such delay and not penalties, that they represent Customer’s sole and exclusive monetary or financial remedy with respect to the delay, that the injuries to Customer caused by such delay are difficult or impossible to estimate MIVA/ PSC CONFIDENTIAL accurately, and that the sums payable herein are reasonable pre-estimates of the probable losses for such delay.
Sample 1

Related to XXXXX DAMAGES

  • Direct Damages A PARTY’S DAMAGES RESULTING FROM A BREACH OR VIOLATION OF ANY REPRESENTATION, WARRANTY, COVENANT, AGREEMENT OR CONDITION CONTAINED IN THIS AGREEMENT OR ANY ACT OR OMISSION ARISING FROM OR RELATED TO THIS AGREEMENT SHALL BE LIMITED TO ACTUAL DIRECT DAMAGES AND SHALL NOT INCLUDE ANY OTHER LOSS OR DAMAGE, INCLUDING INDIRECT, SPECIAL, CONSEQUENTIAL, INCIDENTAL, EXEMPLARY OR PUNITIVE DAMAGES, INCLUDING LOST PROFITS, PRODUCTION, OR REVENUES, AND EACH PARTY RELEASES THE OTHER PARTY FROM ALL SUCH CLAIMS FOR LOSS OR DAMAGE OTHER THAN ACTUAL DIRECT DAMAGES; PROVIDED THAT THIS LIMITATION TO DIRECT DAMAGES SHALL NOT LIMIT THE PARTIES’ INDEMNIFICATION OBLIGATIONS UNDER Section 3.5(c), Section 7.3, AND Article 15.

  • Payment of Damages The indemnification required hereunder shall be made by periodic payments of the amount thereof during the course of the investigation or defense, within 10 days as and when reasonably specific bills are received or loss, liability, claim, damage or expense is incurred and reasonable evidence thereof is delivered. In calculating any amount to be paid by an indemnifying party by reason of the provisions of this Agreement, the amount shall be reduced by all reimbursements (including, without limitation, insurance proceeds) credited to or received by the other party related to the Damages.

  • Punitive Damages The Administrative Agent, the Lenders and the Borrower hereby agree that no such Person shall have a remedy of punitive or exemplary damages against any other party to a Loan Document and each such Person hereby waives any right or claim to punitive or exemplary damages that they may now have or may arise in the future in connection with any Dispute, whether such Dispute is resolved through arbitration or judicially.

  • Certain Damages In the event that Landlord does not elect to terminate this Lease as permitted in subsection (a) of Section 25.02, but on the contrary elects to take possession as provided in subsection (b) of Section 25.02, Tenant will pay to Landlord: (a) Base Monthly Rent and other sums as provided in this Lease, which would be payable under this Lease if such repossession had not occurred, less (b) the net proceeds, if any, of any reletting of the Demised Premises after deducting all Landlord’s reasonable expenses in connection with such reletting, including without limitation, all repossession costs, brokerage commissions, reasonable attorneys’ fees, expenses of employees, reasonable alteration and repair costs and expenses of preparation for such reletting. If, in connection with any reletting, the new lease term extends beyond the existing Term, or the premises covered by such new lease include other premises not part of the Demised Premises, a fair apportionment of the rent received from such reletting and the expenses incurred in connection with such reletting as provided in this Section will be made in determining the net proceeds from such reletting, and any rent concessions will be equally apportioned over the term of the new lease. Tenant will pay such rent and other sums to Landlord monthly on the day on which the Base Monthly Rent would have been payable under this Lease if possession had not been retaken, and Landlord will be entitled to receive such rent and other sums from Tenant on each such day.

  • Monetary Damages In the event that the Partnership breaches its obligations set forth in Article 2, Article 3, or Article 6 with respect to a Protected Partner the Protected Partner’s sole right shall be to receive from the Partnership, and the Partnership shall pay to such Protected Partner as damages, an amount equal to:

  • Liability for Damages 1. The Purchaser shall be liable for any damages sustained by the State arising from Purchaser’s breach of the terms of this Contract and the State may cause all or part of the performance bond to be forfeited to recover such damages.

  • Waiver of Punitive Damages Notwithstanding anything to the contrary contained in this Agreement, the Borrower hereby agrees that it shall not seek from the Lenders or the Administrative Agent punitive, consequential, or indirect damages relating to any such matters under any theory of liability.

  • Disclaimer of Consequential Damages Notwithstanding any provision to the contrary, in no event shall any Party be liable to another Party for any incidental, consequential, special, exemplary or indirect damages, lost business profits or lost data arising out of or in any way related to the Contract Documents.

  • Consequential Damages Neither party to this Agreement shall be liable to the other party for special, indirect or consequential damages under any provision of this Agreement or for any special, indirect or consequential damages arising out of any act or failure to act hereunder.

  • Termination Damages If the Term of this Lease is terminated for default, unless and until Landlord elects lump sum liquidated damages described in the next paragraph, Tenant covenants, as an additional, cumulative obligation after any such termination, to pay punctually to Landlord all the sums and perform all of its obligations in the same manner as if the Term had not been terminated. In calculating such amounts Tenant will be credited with the net proceeds of any rent then actually received by Landlord from a reletting of the Premises after deducting all Rent that has not then been paid by Tenant, provided that Tenant shall never be entitled to receive any portion of the re-letting proceeds, even if the same exceed the Rent originally due hereunder.

Time is Money Join Law Insider Premium to draft better contracts faster.