Review of Bids Sample Clauses

Review of Bids. CenturyLink may review all bids, submittals, or other proposals made to Supplier by any Subcontractor, whether successful, responsive, or utilized in the performance of the Service.
Sample 1Sample 2
AutoNDA by SimpleDocs
Review of Bids. The selection of subcontractors will be based on the review of the bids submitted with respect to each such category, and subject to the reasonable approval of Tenant as to amounts for categories of the work that are either the payment responsibility of Tenant under the Lease or are to be applied against the Tenant Construction Allowance. Tenant's Representative, Tenant's Architect and Tenant's Construction Administrator, if any, each shall have the right to reasonably revise and approve all categories for which Tenant has payment responsibility under the Lease or are to be applied against the Tenant Construction Allowance, and shall have a one-time right to require General Contractor to reallocate the amounts in each category; provided however, there shall be no right to an adjustment of the General Contractor's fees or general conditions fee. Landlord shall afford Tenant the opportunity to revise the TI Plans and Specifications and other requirements to bring the Tenant Improvements into conformity with Tenant's budget requirements (but any such changes shall be subject to Landlord's approval) and shall cooperate with Tenant and the Architect to achieve completion of such changes INTER ALIA, by promptly providing information available to Landlord regarding costs and the estimated effect of the proposed revisions on the completion of the Tenant Improvements. General Contractor shall state estimated delivery dates for all items of work, equipment and materials. Tenant's Architect and Tenant's Construction Administrator, if any, each shall have the right to participate and attend the opening of all bids submitted by potential subcontractors. In connection with any negotiations or discussions with any bidders regarding their proposals (including any negotiations as to revisions in the amounts of their bids), Tenant's Architect and Tenant's Construction Administrator, if any, each shall have the right to participate with respect to negotiations regarding categories which are to be applied against the Tenant Construction Allowance. Notwithstanding the foregoing, it is understood that no such participation, revisions or negotiations initiated on Tenant's behalf shall delay the Commencement Date of the Lease, which, unless occupancy occurs earlier, shall be November 1, 1999.
Sample 1
Review of Bids. The Landlord will cause the Landlord’s Contractor to prepare a final cost estimate document based on the detailed bids for the Premises Fitout. The bids will be made available to the Tenant for its review and comment with the final cost estimate. The final cost estimate shall be used by the Tenant and Landlord as the basis for award and the selection of the subcontractors and materialmen to perform the Premises Fitout. Said subcontractors and materialmen shall be retained by the Landlord’s Contractor on behalf of Landlord under such terms and conditions as are appropriate for the proper and expeditious prosecution of the Premises Fitout. Landlord reserves the right to negotiate the cost with any and all bidders in order to achieve the best price for the Work.
Sample 1
Review of Bids. Architect shall assist the Owner and Construction Manager in reviewing and analyzing construction bids.
Sample 1
Review of Bids. Analyze all bids received, prepare a certified “Bid Tabulation,” and prepare and submit a letter summarizing the results of the bid and the evaluation of the lowest apparent responsive bidder for the construction contract. Bids received will be evaluated for arithmetic errors and completeness of bid forms.
Sample 1

Related to Review of Bids

  • Rejection of Bids 22.1. The ACCO may reject a Bid if:

  • Submission of Bids When the Scheduling Coordinator on behalf of the Participating Generator submits a Bid for Ancillary Services, the Participating Generator will, by the operation of this Section 4.3.1, warrant to the CAISO that it has the capability to provide that service in accordance with the CAISO Tariff and that it will comply with CAISO Dispatch Instructions for the provision of the service in accordance with the CAISO Tariff.

  • REVIEW OF CONTRACT DOCUMENTS 4.2.1 The Contractor shall carefully study and compare the Contract Documents and shall immediately report in writing to the Architect and the State any error, inconsistency or omission he may discover. The Contractor shall not be liable to the State or the Architect for any damage resulting from any such errors, inconsistencies or omissions in the Contract Documents. The Contractor shall perform no portion of the Work at any time without Contract Documents or, where required, approved Shop Drawings, Product Data or Samples for such portion of the Work.

  • Review of Decision Within sixty (60) days after the Secretary’s receipt of a request for review, he or she will review the Company’s determination. After considering all materials presented by the Claimant, the Secretary will render a written opinion, written in a manner calculated to be understood by the Claimant, setting forth the specific reasons for the decision and containing specific references to the pertinent provisions of this Agreement on which the decision is based. If special circumstances require that the sixty (60) day time period be extended, the Secretary will so notify the Claimant and will render the decision as soon as possible, but no later than one hundred twenty (120) days after receipt of the request for review.

  • Clarification of Bids 25.1 To assist in the examination, evaluation, and comparison of Bids, the Employer may, at his discretion, ask any Bidder for clarification of his Bid, including breakdowns of the unit rates. The request for clarification and the response shall be in writing or by cable, but no change in the price or substance of the Bid shall be sought, offered, or permitted except as required to confirm the correction of arithmetic errors discovered by the Employer in the evaluation of the Bids in accordance with Clause 27.

  • OIG INSPECTION, AUDIT, AND REVIEW RIGHTS ‌ In addition to any other rights OIG may have by statute, regulation, or contract, OIG or its duly authorized representative(s) may conduct interviews, examine or request copies of Xxxxxx’x books, records, and other documents and supporting materials and/or conduct on-site reviews of any of Xxxxxx’x locations for the purpose of verifying and evaluating: (a) Xxxxxx’x compliance with the terms of this IA and (b) Xxxxxx’x compliance with the requirements of the Federal health care programs. The documentation described above shall be made available by Xxxxxx to OIG or its duly authorized representative(s) at all reasonable times for inspection, audit, and/or reproduction. Furthermore, for purposes of this provision, OIG or its duly authorized representative(s) may interview Xxxxxx and any of Xxxxxx’x employees or contractors who consent to be interviewed at the individual’s place of business during normal business hours or at such other place and time as may be mutually agreed upon between the individual and OIG. Xxxxxx shall assist OIG or its duly authorized representative(s) in contacting and arranging interviews with such individuals upon OIG’s request. Xxxxxx’x employees and contractors may elect to be interviewed with or without a representative of Xxxxxx present.

  • SCOPE OF BID 1.1 The Employer, as defined in the Conditions of Contract Part II hereinafter “the Employer” wishes to receive bids for the construction of works as described in Section 1, clause 102 of the Special Specifications –“Location and extent of the Works”)

  • PREPARATION OF BIDS 12 LANGUAGE OF BID

  • WITHDRAWAL OF BIDS Bids may be withdrawn by bidders prior to the time set for official opening. After time has been called, no bid may be withdrawn for a period of thirty-five days after the time and date of opening except as provided in O.C.G.A Section 13-10-22 (appreciable error in calculation of bid). Negligence or error on the part of any bidder in preparing his bid confers no right of withdrawal or modification of his bid after time has been called except as provided by Georgia law.

  • ADB’s Review of Procurement Decisions 11. All contracts procured under international competitive bidding procedures and contracts for consulting services shall be subject to prior review by ADB, unless otherwise agreed between the Borrower and ADB and set forth in the Procurement Plan. SCHEDULE 5 Execution of Project and Operation of Project Facilities; Financial Matters

Time is Money Join Law Insider Premium to draft better contracts faster.