Delays Entitling Claim for Extension of Time Sample Clauses

Delays Entitling Claim for Extension of Time. If the Contractor has been delayed in carrying out the Contractor's Activities: prior to the Date for Completion of the Works or a Stage by an Act of Prevention or a cause specified in the Contract Particulars in a manner which has delayed, or is likely to delay, the Contractor in achieving Completion of the Works or the Stage; or after the Date for Completion of the Works or a Stage by an Act of Prevention in a manner which has delayed, or is likely to delay, the Contractor in achieving Completion of the Works or the Stage, the Contractor may claim an extension of time. To claim an extension of time to the Date for Completion of the Works or a Stage, the Contractor must submit a written claim to the Contract Administrator: not later than 28 days after the commencement of the delay to the carrying out of the Contractor's Activities; and which gives detailed particulars of the delay and states the number of days' extension of time claimed. Extension of Time The relevant Date for Completion will be extended: where the Contractor has made a written claim in accordance with clause 9.4 and the Contractor will be delayed in the manner set out in clause (i) or clause (ii) by a reasonable period determined by the Contract Administrator and notified to the parties within 21 days after the later of the Contractor's claim under clause 9.4 or the end of the effects of the delay; and by any period specified in a notice to the Contractor by the Commonwealth who may (in its absolute discretion) by such a notice unilaterally extend the Date for Completion for the Works or a Stage. The Contractor acknowledges that: the Commonwealth is not required to exercise the Commonwealth's discretion under paragraph (ii) for the benefit of the Contractor; paragraph (ii) does not give the Contractor any rights; and the exercise or failure to exercise the Commonwealth's discretion under paragraph (ii) is not capable of being the subject of a dispute or difference for the purposes of clause 15. or otherwise subject to review. Delay Damages Subject to complying with clause 12., the Contractor will be entitled to be paid the extra costs reasonably incurred by the Contractor up to the maximum daily amount specified in the Contract Particulars for each day by which the Date for Completion of the Works or a Stage is extended due to a breach of Contract by the Commonwealth. The amount determined under this clause 9.6 will be a limitation upon the Commonwealth's liability to the Contractor for ...
Sample 1Sample 2
AutoNDA by SimpleDocs
Delays Entitling Claim for Extension of Time. If the Contractor is or will be delayed (prior to the Date for Completion) in reaching Completion by the Date for Completion or will be delayed (after the Date for Completion) in reaching Completion by: an act or omission (including breach of Contract) of the Commonwealth, the PDS Contractor or an employee of the Commonwealth performing duties in the Commonwealth Department of Defence or as a member of the Australian Defence Force; unless a direction is given under clause 8.4(b) and the Contractor is responsible for the non-conformance, a Variation; a Latent Condition; proceedings being taken by adjacent or neighbouring owners or occupiers; statewide industrial disputation or other industrial disputation caused by the Commonwealth, which in neither case is caused or contributed to by the Contractor or any subcontractor of the Contractor; inclement weather at the Site excluding the conditions resulting from inclement weather; delay of any governmental authority in giving any Approval for the Works; paragraph (c), (d) or (e) of the Commonwealth Risks; a change in a Statutory Requirement after the Award Date; valuable, archaeological or special interest items found on or in the Site; or if clause 1 of the Special Conditions applies, Latent Hazardous Substances, Asbestos, ACM or GHS Material, the Contractor may claim an extension of time to the Date for Completion. To claim an extension of time to the Date for Completion the Contractor must submit a written claim to the PDS Contractor: within 14 days of the commencement of the delay; and which gives detailed particulars of the delay and (if possible) states the number of days' extension of time claimed.
Sample 1
Delays Entitling Claim for Extension of Time. If the Contractor is, or is likely to be, delayed: prior to the Date for Completion, by an Act of Prevention or a cause specified in the Contract Particulars in a manner which will prevent it from achieving Completion by the relevant Date for Completion; or after the Date for Completion of the Works or a Stage, by an Act of Prevention in a manner which will delay it in achieving Completion, the Contractor may claim an extension of time. Claim for Extension of Time To claim an extension of time the Contractor must: within 14 days of the commencement of the occurrence causing the delay submit a written claim to the Contract Administrator for an extension to the relevant Date for Completion which: gives detailed particulars of the delay and the occurrence causing the delay; and states the number of days extension of time claimed together with the basis of calculating that period, including evidence that it will be delayed in achieving Completion in the manner set out in clause 10.7(c); and if the effects of the delay continue beyond the period of 14 days after the commencement of the occurrence causing the delay and the Contractor wishes to claim an extension of time in respect of the further delay, submit a further written claim to the Contract Administrator: every 14 days after the first written claim until 7 days after the end of the effects of the delay; and containing the information required by paragraph (a).
Sample 1
Delays Entitling Claim for Extension of Time. If the Subcontractor is or will be delayed (prior to the Date for Completion) in reaching Completion by the Date for Completion or will be delayed (after the Date for Completion) in reaching Completion by: an act or omission (including breach of Subcontract) of the Contractor, the Contractor's Representative or of the Commonwealth, the MCC Contract Administrator or an employee of the Commonwealth performing duties in the Commonwealth Department of Defence or as a member of the Australian Defence Force; unless a direction is given under clause 8.4(b) and the Subcontractor is responsible for the non-conformance, a Variation; a Latent Condition; proceedings being taken by adjacent or neighbouring owners or occupiers; statewide industrial disputation or other industrial disputation caused by the Commonwealth, which in neither case is caused or contributed to by the Subcontractor or any subsubcontractor of the Subcontractor; inclement weather at the Site excluding the conditions resulting from inclement weather; delay of any governmental authority in giving any Approval for the Subcontract Works; paragraph (c), (d) or (e) of the Contractor Risks; a change in a Statutory Requirement after the Award Date; valuable, archaeological or special interest items found on or in the Site; or if clause 1 of the Special Conditions applies, Latent Hazardous Substances, Asbestos, ACM or GHS Material, the Subcontractor may claim an extension of time to the Date for Completion. To claim an extension of time to the Date for Completion the Subcontractor must submit a written claim to the Contractor's Representative: within 14 days of the commencement of the delay; and which gives detailed particulars of the delay and (if possible) states the number of days' extension of time claimed.
Sample 1
Delays Entitling Claim for Extension of Time. If the Contractor is or will be delayed (prior to the Date for Completion) in reaching Completion by the Date for Completion or will be delayed (after the Date for Completion) in reaching Completion by: an act or omission (including breach of Contract) of the Commonwealth, the PDS Contractor or an employee of the Commonwealth performing duties in the Commonwealth Department of Defence or as a member of the Australian Defence Force; unless a direction is given under clause 8.4(b) and the Contractor is responsible for the non-conformance, a Variation; a Latent Condition; proceedings being taken by adjacent or neighbouring owners or occupiers; statewide industrial disputation or other industrial disputation caused by the Commonwealth, which in neither case is caused or contributed to by the Contractor or any subcontractor of the Contractor; inclement weather at the Site excluding the conditions resulting from inclement weather; delay of any governmental authority in giving any Approval for the Works; paragraph (c), (d) or (e) of the Commonwealth Risks; a change in a Statutory Requirement after the Award Date; valuable, archaeological or special interest items found on or in the Site;
Sample 1
Delays Entitling Claim for Extension of Time. If the Contractor is, or is likely to be, delayed: prior to the Date for Remediation Completion of the Remediation Works or a Stage, by an Act of Prevention or a cause specified in the Contract Particulars in a manner which will prevent it from achieving Remediation Completion of the Remediation Works or the Stage by the relevant Date for Remediation Completion; or after the Date for Remediation Completion of the Remediation Works or a Stage, by an Act of Prevention in a manner which will delay it in achieving Remediation Completion of the Remediation Works or the Stage, the Contractor may claim an extension of time. Claim for Extension of Time To claim an extension of time the Contractor must: within 14 days of the commencement of the occurrence causing the delay submit a written claim to the Contract Administrator for an extension to the relevant Date for Remediation Completion which: gives detailed particulars of the delay and the occurrence causing the delay; and states the number of days extension of time claimed together with the basis of calculating that period, including evidence that it will be delayed in achieving Remediation Completion in the manner set out in clause 10.7(c); and if the effects of the delay continue beyond the period of 14 days after the commencement of the occurrence causing the delay and the Contractor wishes to claim an extension of time in respect of the further delay, submit a further written claim to the Contract Administrator: every 14 days after the first written claim until 7 days after the end of the effects of the delay; and containing the information required by paragraph (a).
Sample 1

Related to Delays Entitling Claim for Extension of Time

  • Contract Negotiation Meetings 14.09 When operational requirements permit, the Employer will grant leave without pay to an employee for the purpose of attending contract negotiation meetings on behalf of the Alliance. Preparatory Contract Negotiation Meetings

  • Request for Extension Upon request, the Department may extend the time allowed for both a response to the Letter of Concern and a Corrective Action Plan depending upon the nature of the deficiency. The Provider shall request an extension of time in writing from the Department’s designated representative. The written request shall contain a justification and proposed extension period.

  • Indemnification for Expenses of a Party Who is Wholly or Partly Successful Notwithstanding any other provisions of this Agreement except for Section 27, to the extent that Indemnitee was or is, by reason of Indemnitee’s Corporate Status, a party to (or a participant in) and is successful, on the merits or otherwise, in any Proceeding or in defense of any claim, issue or matter therein, in whole or in part, the Company shall, to the fullest extent permitted by applicable law, indemnify, hold harmless and exonerate Indemnitee against all Expenses actually and reasonably incurred by him or her in connection therewith. If Indemnitee is not wholly successful in such Proceeding but is successful, on the merits or otherwise, as to one or more but less than all claims, issues or matters in such Proceeding, the Company shall, to the fullest extent permitted by applicable law, indemnify, hold harmless and exonerate Indemnitee against all Expenses actually and reasonably incurred by him or her or on his or her behalf in connection with each successfully resolved claim, issue or matter. If Indemnitee is not wholly successful in such Proceeding, the Company also shall, to the fullest extent permitted by applicable law, indemnify, hold harmless and exonerate Indemnitee against all Expenses reasonably incurred in connection with a claim, issue or matter related to any claim, issue, or matter on which Indemnitee was successful. For purposes of this Section and without limitation, the termination of any claim, issue or matter in such a Proceeding by dismissal, with or without prejudice, shall be deemed to be a successful result as to such claim, issue or matter.

  • Reimbursement for Expenses of a Witness or in Response to a Subpoena Notwithstanding any other provision of this Agreement, to the extent that Indemnitee, by reason of his or her Corporate Status, (i) is a witness in any Proceeding to which Indemnitee is not a party and is not threatened to be made a party or (ii) receives a subpoena with respect to any Proceeding to which Indemnitee is not a party and is not threatened to be made a party, the Company shall reimburse Indemnitee for all Expenses actually and reasonably incurred by him or her or on his or her behalf in connection therewith.

  • NOTICE TO EMPLOYEES REGARDING THE SAFELY SURRENDERED BABY LAW The Contractor shall notify and provide to its employees, and shall require each Subcontractor to notify and provide to its employees, a fact sheet regarding the Safely Surrendered Baby Law, its implementation in Los Angeles County, and where and how to safely surrender a baby. The fact sheet is set forth in Exhibit I of this Contract and is also available on the Internet at xxx.xxxxxxxxxx.xxx for printing purposes.

  • Breach of Contract Claims To the extent that Chapter 2260, Texas Government Code, is applicable to this Agreement and is not preempted by other applicable law, the dispute resolution process provided for in Chapter 2260 and the related rules adopted by the Texas Attorney General pursuant to Chapter 2260, will be used by University and Contractor to attempt to resolve any claim for breach of contract made by Contractor that cannot be resolved in the ordinary course of business. The chief business officer of University will examine Contractor's claim and any counterclaim and negotiate with Contractor in an effort to resolve the claims. The parties specifically agree (i) neither execution of this Agreement by University nor any other conduct, action or inaction of any representative of University relating to this Agreement constitutes or is intended to constitute a waiver of University’s or the state's sovereign immunity to suit; and (ii) University has not waived its right to seek redress in the courts.

  • INDEMNIFICATION FOR EXPENSES OF A WITNESS Notwithstanding any other provision of this Agreement except for Section 27, to the extent that Indemnitee is, by reason of Indemnitee’s Corporate Status, a witness or deponent in any Proceeding to which Indemnitee was or is not a party or threatened to be made a party, Indemnitee shall, to the fullest extent permitted by applicable law, be indemnified, held harmless and exonerated against all Expenses actually and reasonably incurred by Indemnitee or on Indemnitee’s behalf in connection therewith.

  • Notice of Extension (a) If the Institutional Trustee is the only registered Holder at the time the Company selects an Extended Interest Payment Period, the Company shall give written notice to the Regular Trustees, the Institutional Trustee and the Trustee of its selection of such Extended Interest Payment Period one Business Day before the earlier of (i) the next succeeding date on which Distributions on the Trust Securities issued by the Trust are payable, or (ii) the date the Trust is required to give notice of the record date, or the date such Distributions are payable, to the New York Stock Exchange or other applicable self-regulatory organization or to holders of the Preferred Securities issued by the Trust, but in any event at least one Business Day before such record date.

  • Notice of Potential Claims The Contractor shall not be entitled to additional compensation or to extension of time for (1) any act or failure to act by the County Project Manager or the County, or (2) the happening of any event or occurrence, unless the Contractor has given the County a written Notice of Potential Claim within ten (10) days of the commencement of the act, failure, or event giving rise to the claim, and before final payment by the County. The written Notice of Potential Claim shall set forth the reasons for which the Contractor believes additional compensation or extension of time is due, the nature of the cost involved, and insofar as possible, the amount of the potential claim. Contractor shall keep full and complete daily records of the work performed, labor and material used, and all costs and additional time claimed to be additional.

  • Indemnification for Expenses in Enforcing Rights To the fullest extent allowable under applicable law, the Company shall also indemnify against, and, if requested by Indemnitee, shall advance to Indemnitee subject to and in accordance with Section 4, any Expenses actually and reasonably paid or incurred by Indemnitee in connection with any action or proceeding by Indemnitee for (a) indemnification or reimbursement or advance payment of Expenses by the Company under any provision of this Agreement, or under any other agreement or provision of the Constituent Documents now or hereafter in effect relating to Claims relating to Indemnifiable Events, and/or (b) recovery under any directors’ and officers’ liability insurance policies maintained by the Company. However, in the event that Indemnitee is ultimately determined not to be entitled to such indemnification or insurance recovery, as the case may be, then all amounts advanced under this Section 5 shall be repaid. Indemnitee shall be required to reimburse the Company in the event that a final judicial determination is made that such action brought by Indemnitee was frivolous or not made in good faith.

Time is Money Join Law Insider Premium to draft better contracts faster.