After receipt of a Notice of Termination, and except as otherwise directed by the contracting officer, the contractor shall:
After receipt of a Notice. OF TERMINATION FROM THE OWNER, PURSUANT TO PARAGRAPH 10.2 OR 10.3, AND EXCEPT AS OTHERWISE DIRECTED BY THE OWNER, THE CM SHALL: .1 STOP WORK UNDER THE CONTRACT ON THE DATE AND TO THE EXTENT SPECIFIED IN THE NOTICE OF TERMINATION; .2 PLACE NO FURTHER ORDERS OR SUBCONTRACTS FOR MATERIALS, SERVICES OR FACILITIES, EXCEPT AS MAY BE NECESSARY FOR COMPLETION OF SUCH PORTION OF THE WORK UNDER THE CONTRACT AS IS NOT TERMINATED;
After receipt of a Notice. OF TERMINATION, THE CM SHALL SUBMIT TO THE OWNER HIS TERMINATION CLAIM, IN THE FORM AND WITH CERTIFICATION PRESCRIBED BY THE OWNER. SUCH CLAIM SHALL BE SUBMITTED PROMPTLY, BUT IN NO EVENT LATER THAN THIRTY (3O)DAYS FROM THE EFFECTIVE DATE OF TERMINATION, UNLESS ONE OR MORE EXTENSIONS IN WRITING ARE GRANTED BY THE OWNER UPON REQUEST OF THE CM MADE IN WRITING WITHIN SUCH THIRTY (30) DAY PERIOD OR AUTHORIZED EXTENSION THEREOF. HOWEVER, IF THE OWNER DETERMINES THAT THE FACTS JUSTIFY SUCH ACTION, HE MAY RECEIVE AND EVALUATE ANY SUCH TERMINATION CLAIM AT ANY TIME AFTER SUCH THIRTY (30) DAY PERIOD OR ANY EXTENSION THEREOF. UPON FAILURE OF THE CM TO SUBMIT HIS TERMINATION CLAIM WITHIN THE TIME ALLOWED, THE OWNER MAY DETERMINE, ON THE BASIS OF INFORMATION AVAILABLE TO HIM, THE AMOUNT, IF ANY, DUE TO THE CM BY REASON OF THE TERMINATION.
After receipt of a Notice of Termination and except as otherwise directed by the City, the Subrecipient shall: Stop work under the Agreement on the date and to the extent specified in the Notice of Termination; Obligate no additional Agreement funds for payroll costs and other costs beyond such date as the City shall specify, and place no further orders on subcontractors for materials, services, or facilities, except as may be necessary for completion of such portion of the work under this Agreement as is not terminated; Terminate all orders and subcontracts to the extent that they relate to the portion of work so terminated, and cause to be terminated all subcontracts, if any, to such extent; As of the date the termination is effective, preserve all Agreement Records (as hereinafter defined) and submit to the City such Records and reports as the City shall specify, and furnish to the City an inventory of all furnishings, equipment and other property purchased for the Program (if any) and all pertinent keys to files, buildings property to carry out such directives as the City may issue concerning the safeguarding or disposition of files and property; and Submit within thirty (30) days a final report of receipts and expenditures of funds relating to this Agreement and a listing of all creditors, contractors, lessors, and/or other parties with which the Subrecipient has incurred financial obligations pursuant to this Agreement (if any), and a listing of all subcontractors, if any.
After receipt of a Notice of Termination, and except as otherwise directed by the County, the Contractor shall:
After receipt of a Notice of Termination, and except as otherwise directed by City, Consultant shall:
After receipt of a Notice of Termination, and except as directed by DISTRICT, CONTRACTOR shall immediately proceed with the following obligations, as applicable, regardless of any delay in determining or adjusting any amounts due under this clause. CONTRACTOR shall:
After receipt of a Notice of Termination, and except as directed by DISTRICT, CONTRACTOR shall immediately proceed with the following obligations, as applicable, regardless of any delay in determining or adjusting any amounts due under this clause. CONTRACTOR shall: Stop work as specified in the Notice of Termination (except as required by any Disentanglement Services). Place no further subcontracts for materials, Services, Equipment, or facilities, except as necessary to complete the continuing portion of the Agreement. Terminate all subcontracts to the extent they relate to the work terminated. Settle all outstanding liabilities and settlement proposals arising from the termination of subcontracts.
After receipt of a Notice. OF TERMINATION FROM THE OWNER, PURSUANT TO PARAGRAPH 10.2 OR 10.3, AND EXCEPT AS OTHERWISE DIRECTED BY THE OWNER, THE CM SHALL:
After receipt of a Notice of Termination, and except as directed by the Contracting Officer, the Contractor shall immediately proceed with the following obligations, regardless of any delay in determining or adjusting any amounts due under this clause:
