Change Order means a written order to the Contractor signed by the Contracting Officer, issued after execu- tion of the Contract, authorizing a change in the term or scope of the Contract.
Change Orders mean changes or modifications to any Construction Contract or any other contract with labor or material suppliers.
Proposed Change Order (PCO means a document that informs Contractor of a proposed change in the Work and appropriately describes or otherwise documents such change including Contractor’s response of pricing for the proposed change.
Unilateral Change Order (ULCO means a Change Order issued by Owner without the complete agreement of Contractor, as to cost and/or time.
Change Order Request means a written request or proposal for a Change Order submitted by either Company or Contractor and including:
Purchase Order (PO) means a written offer made by a purchaser to a supplier formally stating the terms and conditions of a proposed transaction.
Statement of Work means the description of activities performed in completing the Project, as specified in the Contract and as may be amended.
Project Schedule means a document that, with respect to each Phase of the Project, identifies, coordinates and integrates the anticipated design and construction schedules, the Contracting Authority’s and Owner's responsibilities, government authority reviews and other activities as are necessary for the timely completion of the Work.
Delivery Schedule means the schedule for the delivery of Services as set forth in attached Annex 3.
Purchase Order Number means the Customer’s unique number relating to the supply of the Services;
Scope of Work means the description of Services and Deliverables specified in the Contract and as may be amended.
Construction Schedule means a construction schedule indicating the planned start and completion dates of the major activities of the Work as set out in Appendix [ ], a future Appendix;
Contract Schedule means a schedule to this Contract;
Order Schedule means an MSC Order Schedule (or other order document) agreed to by Customer and MSC, and which incorporates this Agreement, by reference or otherwise, and sets forth, among other things, the Software, Maintenance and/or Services ordered.
Work Order means an individually negotiated document that is executed by both Parties and which authorizes a Project, if any, in an indefinite quantity Contract.
Specification Schedule means the Schedule containing details of the Specification.
Software Order Form means the order form for the Software, Third Party Software and related SAP Support ordered by Licensee thereunder, including information on Software, Third Party Software, SAP Support, fees, and other information necessary for the delivery of such items to Licensee.
Completion Schedule means the fulfilment of the Related Services by the Supplier in accordance with the terms and conditions set forth in the Contract;
Implementation Schedule means the Implementation Schedule in Section VII of the tendering documents.
Project Completion Schedule means the progressive Project Milestones set forth in Schedule-J for completion of the Project Highway on or before the Scheduled Completion Date;
The Work Order means the order placed by the Purchaser on the Supplier signed by the Purchaser including all attachments and appendices thereto and all documents incorporated by reference therein. The Work order shall be deemed as "Contract" appearing in the document.
Cloud Service Order Form means all written order forms or other ordering documentation for Cloud Services entered into by SAP, or a SAP SE Affiliate or a reseller of SAP SE or an SAP SE Affiliate, and Prime Contractor.
Original contract price means the award price of the contract; or, for requirements contracts, the price payable for the estimated total quantity; or, for indefinite-quantity contracts, the price payable for the specified minimum quantity. Original contract price does not include the price of any options, except those options exercised at the time of contract award.
Product Schedule means PTC’s standard order form entitled “PTC Product Schedule” (including all schedules, attachments and other document(s) specifically referenced therein) or such alternative order form as may be submitted by Customer and accepted by PTC, in each case that specifies (i) the Licensed Products and/or Services ordered; and (ii) for Licensed Products, the installation address (including the Designated Country) and the Licence Term.
Schedule of Work means that schedule attached to the Interconnection Construction Service Agreement setting forth the timing of work to be performed by the Constructing Entity pursuant to the Interconnection Construction Service Agreement, based upon the Facilities Study and subject to modification, as required, in accordance with Transmission Provider’s scope change process for interconnection projects set forth in the PJM Manuals. Scope of Work:
Baseline Schedule means the initial time schedule prepared by Contractor for Owner’s information and acceptance that conveys Contractor’s and Subcontractors’ activities (including coordination and review activities required in the Contract Documents to be performed by A/E and ODR), durations, and sequence of work related to the entire Project to the extent required by the Contract Documents. The schedule clearly demonstrates the critical path of activities, durations and necessary predecessor conditions that drive the end date of the schedule. The Baseline Schedule shall not exceed the time limit current under the Contract Documents.