REFUND BY THE BUILDER Sample Clauses

REFUND BY THE BUILDER. The payments made by the BUYER to the BUILDER prior to delivery of the VESSEL shall constitute advances to the BUILDER. If the VESSEL is rejected by the BUYER in accordance with the terms of this CONTRACT, or except in the case of rescission or rescission of this CONTRACT by the BUILDER under the provisions of Article XI hereof, if the BUYER terminates or rescinds this CONTRACT pursuant to any of the provisions of this CONTRACT specifically permitting the BUYER to do so, the BUILDER shall forthwith refund to the BUYER, in U.S. Dollars, the full amount of total sums paid by the BUYER to the BUILDER in advance of delivery together with interest thereon as herein provided. The transfer and other bank charges of such refund shall be for the BUILDER’s account. The interest rate of the refund, as above provided, shall be seven per cent (7%) per annum from the date following the date of receipt by the BUILDER of the pre-delivery instalment(s) to the date of remittance by telegraphic transfer of such refund, provided, however, that if the cancellation of this CONTRACT by the BUYER is based upon delays due to force majeure or other causes beyond the control of the BUILDER as provided for in Article VIII hereof, then in such event, the interest rate of refund shall be reduced to six point five per cent (6.5%) per annum. It is hereby understood by both parties that payment of any interest provided herein is by way of liquidated damages due to rescission of this CONTRACT and not by way of compensation for use of money. If, the BUILDER is required to refund to the BUYER the instalments paid by the BUYER to the BUILDER as provided in this Paragraph, the BUILDER shall return to the BUYER all of the BUYER’s supplies as stipulated in Article XII which were not incorporated into the VESSEL and pay to the BUYER an amount equal to the cost to the BUYER of those supplies incorporated into the VESSEL.
Sample 1Sample 2Sample 3See All (36)
AutoNDA by SimpleDocs
REFUND BY THE BUILDER. (a) The payments made by the BUYER to the BUILDER prior to delivery of the VESSEL shall constitute advances to the BUILDER. If the VESSEL is rejected by the BUYER in accordance with the terms of this CONTRACT or, except in the case of rescission or cancellation of this CONTRACT by the BUILDER under the provisions of Article XI.1 hereof, if the BUYER terminates, cancels or rescinds this CONTRACT pursuant to any of the provisions of this CONTRACT specifically permitting the BUYER to do so, the BUILDER shall forthwith refund to the BUYER, in U.S. Dollars, the full amount of total sums paid by the BUYER to the BUILDER in advance of delivery together with interest thereon as herein provided without deduction, set-off or withholding in US dollars.
Sample 1Sample 2Sample 3See All (6)
REFUND BY THE BUILDER. In case the BUILDER receives the notice stipulated in Paragraph 1 of this Article, the BUILDER shall refund to the BUYER the full amount of all sums paid by the BUYER to the BUILDER on account of the VESSEL within Seven (7) days after the date of the notice as provided in paragraph 1 of this Article hereof together with interest if any and with, if appropriate, an amount equal to the original purchase prices of the BUYER’s supplied material as evidenced by the invoice issued by the each supplier of the same including lubricating oil, grease and fuel oil, if any, which are purchased by the BUYER to the VESSEL, except those items which are able to return to the BUYER as they are, unless the BUILDER proceeds to the arbitration under the provisions of Article XIII hereof. In such event, the BUILDER shall pay the BUYER interest at the rate of six percent (6%) per annum on the amount required herein to be refunded to the BUYER, computed from the respective dates on which such sums were paid by the BUYER to the BUILDER to the date of remittance by telegraphic transfer of such refund with interest to the BUYER by the BUILDER, provided, however, that if the said rescission by the BUYER is made under the provisions of Paragraph 4 of Article VIII hereof, then in such event the BUILDER shall not be required to pay the BUYER any interest.
Sample 1Sample 2See All (4)
REFUND BY THE BUILDER. Thereupon the BUILDER shall refund to the BUYER the full amount of all sums paid by the BUYER to the BUILDER on account of the VESSEL within seven (7) days together with an amount equal to the original purchase prices of the BUYER’s supplied material as evidenced by the invoice issued by the each supplier of the same including lubricating oil, grease and fuel oil, if any, which are purchased by the BUYER to the VESSEL, except those items which are able to return to the BUYER, unless the BUILDER proceeds to the arbitration under the provisions of Article XIII hereof. In such event, the BUILDER shall pay the BUYER interest at the rate of eight percent (8%) per annum on the amount required herein to be refunded to the BUYER, computed from the respective dates on which such sums were paid by the BUYER to the BUILDER to the date of remittance by telegraphic transfer of such refund with interest to the BUYER by the BUILDER, provided, however, that if the said rescission by the BUYER is made under the provisions of Paragraph 1 of Article VIII hereof, then in such event the BUILDER shall pay to the BUYER the interest at the rate of four percent (4%) per annum. The bank charges to such refund relating to the BUILDER’s Bank to be on account of the BUILDER.
Sample 1Sample 2
REFUND BY THE BUILDER. Thereupon, the BUILDER shall promptly refund to the BUYER the full amount of all sums paid by the BUYER to the BUILDER on account of the VESSEL (unless the BUILDER proceeds to dispute resolution under the provisions of Article XIV hereof). In such event, the BUILDER shall pay the BUYER interest at the rate of two percent (2%) per annum above the average LIBOR three month rate on the amount required herein to be refunded to the BUYER, computed from the respective dates on which such sums were paid by the BUYER to the BUILDER to the date of remittance by transfer of such refund to the BUYER by the BUILDER, provided, however, that if such rescission by the BUYER is made under the provisions of Paragraph 4 of Article VIII hereof, the BUILDER shall not be required to pay any interest.
Sample 1Sample 2
REFUND BY THE BUILDER. (a) The payments made by the BUYER to the BUILDER prior to delivery of the VESSEL shall constitute advance payments to the BUILDER. If the VESSEL is rejected by the BUYER in accordance with the terms of this CONTRACT, or except in the case of termination of this CONTRACT by the BUILDER under the provisions of ARTICLE XI, if the BUYER terminates this CONTRACT pursuant to any of the provisions of this CONTRACT specifically permitting the BUYER to do so, the BUILDER shall, within thirty (30) days after its receipt of the BUYER’s NOTICE of written demand, forthwith refund to the BUYER, in U.S. Dollars, the full amount of total sums paid by the BUYER to the BUILDER in advance of delivery together with interest thereon as herein provided.
Sample 1

Related to REFUND BY THE BUILDER

  • Partial Terminations by the Purchasers In the event so instructed by the Purchasers in writing after the Closing Date and at the Purchasers’ sole expense, each Seller shall execute documents prepared by the Purchasers and reasonably acceptable to such Seller resigning or appointing a successor Appointed Trustee under any Serviced Appointment for which such Seller acts as Appointed Trustee (other than with respect to any Serviced Appointment that is an Excluded Appointment), and shall reasonably cooperate, at the Purchasers’ sole expense, as instructed by the Purchasers, in finding a qualified successor Appointed Trustee, including executing any documents prepared by the Purchasers in connection with the application to a court of competent jurisdiction to appoint a successor Appointed Trustee.

  • TERMINATION BY THE CONTRACTOR If the Work is stopped for a period of thirty days under an order of any court or other public authority having jurisdiction, or as a result of an act of government, such as a declaration of a national emergency making materials unavailable, through no act or fault of the Contractor or a Subcontractor or their agents or employees or any other persons performing any of the Work under a contract with the Contractor, or if the Work should be stopped for a period of thirty days by the Contractor because the Architect has not issued a Certificate for Payment as provided in Paragraph 9.7 of these General Conditions or because the State has not made payment thereon as provided in Paragraph 9.7, then the Contractor may, upon seven additional days written notice to the State and the Architect, terminate the Contract and recover from the State payment for all Work executed and for any proven loss sustained upon any materials, equipment, tools, construction equipment and machinery, including reasonable profit and damages.

  • Clean-Up Terminations by the Sellers (a) The Sellers shall have the right to elect to terminate this Agreement in the event that the remaining Serviced Appointments have generated LTM Fee Revenue that is less than 5% of the aggregate fee revenue generated by all Appointments that are Serviced Appointments as of January 1, 2024 in the twelve-month period prior to January 1, 2024.

  • Delivery by the Company At the Closing, the Company shall register the Shares in the name of the Employee. If the Shares are certificated, any certificates relating to the Shares shall be held by the Secretary of the Company or his or her designee on behalf of the Employee.

  • Damages for delay by the Concessionaire In the event that (i) the Concessionaire does not procure fulfilment of any or all of the Conditions Precedent set forth in Clause 4.1.3 within a period of 180 (one hundred and eighty) days from the date of this Agreement, and (ii) the delay has not occurred as a result of failure to fulfil the obligations under Clause 4.1.2 or other breach of this Agreement by the Authority, or due to Force Majeure, the Concessionaire shall pay to the Authority Damages in an amount calculated at the rate of 0.2% (zero point two per cent) of the Performance Security for each day's delay until the fulfilment of such Conditions Precedent, subject to a maximum of 20% (twenty percent) of the Performance Security.

  • Deliveries by the Purchaser At the Closing, the Purchaser shall deliver or cause to be delivered to the Selling Shareholders, the following:

  • Deliveries by the Buyer At the Closing, the Buyer shall deliver, or cause to be delivered, to the Seller the following:

  • Actions by the Board Any and all determinations or other actions required of the Board hereunder that relate specifically to Executive’s employment by the Company or the terms and conditions of such employment shall be made by the members of the Board other than Executive if Executive is a member of the Board, and Executive shall not have any right to vote or decide upon any such matter.

  • TERMINATION BY THE OWNER 14.2.1 The Owner may terminate the contract if the Contractor:

  • TERMINATION BY THE PARTIES This Agreement may be terminated upon sixty (60) days’ written notice (a) by the Independent Directors of the Company or the Advisor, without Cause and without penalty, (b) by the Advisor for Good Reason, or (c) by the Advisor upon a Change of Control. The provisions of Sections 19 through 31 of this Agreement shall survive termination of this Agreement.

Time is Money Join Law Insider Premium to draft better contracts faster.