DELIVERY OF THE VESSEL Sample Clauses

DELIVERY OF THE VESSEL. A. The Vessel will be delivered by Owner hereunder to Charterer as is and where is at the Port of Palm Beach, Florida as of the date hereof ("Delivery").
AutoNDA by SimpleDocs
DELIVERY OF THE VESSEL. 5.1 The Owner shall notify the Contractor in writing at least 60 Days, 30 Days and 15 Days in advance of the arrival of the Vessel at the Yard.
DELIVERY OF THE VESSEL. DELIVERY
DELIVERY OF THE VESSEL. The Government will, without cost or expense to the Buyer, but at the risk of the Buyer, render the Obsolete Vessel free of moorings at the Shipyard, and make such Obsolete Vessel available for towing at such location for delivery to the Buyer pursuant to this Contract. The Obsolete Vessel will be available for delivery to the Buyer on the date of undocking at the Shipyard, however, that the Government shall not be liable for delay in making any Obsolete Vessel available for delivery due to conditions beyond its control or conditions which by the exercise of reasonable diligence it was unable to prevent. The Government shall not be obligated to deliver any Obsolete Vessel on Saturdays, Sundays, or federal holidays.
DELIVERY OF THE VESSEL. The Government will, without cost or expense to the Buyer, but at the risk of the Buyer, render the Obsolete Vessel free of moorings at its location, and make such Obsolete Vessel available at such location for delivery to the Buyer pursuant to this Contract. The Obsolete Vessel will be available for delivery to the Buyer on the date requested by the Buyer in writing, which written request shall be received by the Contracting Officer not less than five (5) days in advance of each requested date; provided, however, that the Government shall not be liable for delay in making any Obsolete Vessel(s) available for delivery due to conditions beyond its control or conditions which by the exercise of reasonable diligence it was unable to prevent. The Government shall not be obligated to deliver any Obsolete Vessel on Saturdays, Sundays, or federal holidays.
DELIVERY OF THE VESSEL. Clause (a) in the Article V “DELIVERY” of the Shipbuilding Contract shall be replaced in its entirety with the following:
DELIVERY OF THE VESSEL. Delivery
AutoNDA by SimpleDocs
DELIVERY OF THE VESSEL. A. The Vessel will be delivered by Owner hereunder to Charterer at a safe and accessible berth or anchorage at Joliet, Illinois on or about the date hereof ("Delivery").
DELIVERY OF THE VESSEL. 1.1 Subject to paragraph 1.2 below, it is hereby agreed that the BUILDER will tender the Vessel for delivery to the BUYER; and the BUYER will accept delivery of the Vessel, on 9 October 2017. This agreement relates to the timing of actual delivery of the Vessel to the BUYER and does not amend the contractual Delivery Date.
DELIVERY OF THE VESSEL. (a) Evidence that:
Time is Money Join Law Insider Premium to draft better contracts faster.