Excusable Delays Except with respect to defaults of subproviders, the Engineer shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure to progress in the performance of the work) if such failure arises out of causes beyond the control and without the default or negligence of the Engineer. Such causes may include, but are not restricted to, acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, freight embargoes, and unusually severe weather.
Excusable Delay The Contractor is entitled to an equitable adjustment of time, issued via Change Order, for delays caused by the following:
Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”
Unavoidable Delays Delays due to acts of God, acts of public agencies, labor disputes, strikes, fires, freight embargoes, inability (despite the exercise of due diligence) to obtain supplies, materials, fuels or permits, or other causes or contingencies (excluding financial inability) beyond the reasonable control of Landlord or Tenant, as applicable. Landlord shall use commercially reasonable efforts to provide Tenant with prompt notice of any Unavoidable Delays.
Unavoidable Delay When construction is impeded as a result of strikes, lockouts, acts of God or other factors beyond the control, and ability to remedy, of the Developer.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
FORCE MAJEURE CLAUSE Contractor shall be excused from performance hereunder during the time and to the extent that it is prevented from obtaining delivery, or performing by act of God, fire, strike, loss, or shortage of transportation facilities, lock-out, commandeering of materials, product, plant, or facilities by the government, when satisfactory evidence thereof is presented to the District, provided that it is satisfactorily established that the non-performance is not due to the fault or neglect of Contractor.
Permitted Delays The Company shall be entitled to postpone the filing of any Registration Statement under Section 2.3 if (i) at any time prior to the filing of such Registration Statement the Board of Directors of the Company determines, in its good faith business judgment, that such registration and offering would materially and adversely affect any financing, acquisition, corporate reorganization or other material transaction involving the Company, and (ii) the Company delivers the Holders requesting such registration written notice thereof within 10 business days of the date of receipt of such request; provided, that all such periods of postponement may not exceed 45 days during any 365-day period.
Force Majeure If by reason of Force Majeure, either party hereto shall be rendered unable wholly or in part to carry out its obligations under this Agreement then such party shall give notice and full particulars of Force Majeure in writing to the other party within a reasonable time after occurrence of the event or cause relied upon, and the obligation of the party giving such notice, so far as it is affected by such Force Majeure, shall be suspended during the continuance of the inability then claimed, except as hereinafter provided, but for no longer period, and such party shall endeavor to remove or overcome such inability with all reasonable dispatch. Choice of Law The Agreement between the Vendor and TIPS/ESC Region 8 and any addenda or other additions resulting from this procurement process, however described, shall be governed by, construed and enforced in accordance with the laws of the State of Texas, regardless of any conflict of laws principles. Venue, Jurisdiction and Service of Process Any Proceeding arising out of or relating to this procurement process or any contract issued by TIPS resulting from or any contemplated transaction shall be brought in a court of competent jurisdiction in Camp County, Texas and each of the parties irrevocably submits to the exclusive jurisdiction of said court in any such proceeding, waives any objection it may now or hereafter have to venue or to convenience of forum, agrees that all claims in respect of the Proceeding shall be heard and determined only in any such court, and agrees not to bring any proceeding arising out of or relating to this procurement process or any contract resulting from or any contemplated transaction in any other court. The parties agree that either or both of them may file a copy of this paragraph with any court as written evidence of the knowing, voluntary and freely bargained for agreement between the parties irrevocably to waive any objections to venue or to convenience of forum. Process in any Proceeding referred to in the first sentence of this Section may be served on any party anywhere in the world. Venue for any dispute resolution process, other than litigation, between TIPS and the Vendor shall be located in Camp or Xxxxx County, Texas.
Force Majeure Events a) Neither Party shall be responsible or liable for or deemed in breach hereof because of any delay or failure in the performance of its obligations hereunder (except for obligations to pay money due prior to occurrence of Force Majeure events under this Agreement) or failure to meet milestone dates due to any event or circumstance (a "Force Majeure Event") beyond the reasonable control of the Party experiencing such delay or failure, including the occurrence of any of the following:
