Force Majeure Clause definition

Force Majeure Clause. Wherever there is provided in this Lease a time limitation for performance by Tenant or Landlord of any non monetary obligation, including but not limited to obligations related to construction, repair, maintenance or service, the time provided for shall be extended for as long as and to the extent that delay in compliance with such limitation is due to an act of God, governmental control or other factors beyond the reasonable control of Landlord.
Sample 1Sample 2
Force Majeure Clause. If at any time, either party is prevented or delayed in the performance of any act required under the Licence Agreement by reason of war, or hostility, act of the public enemy, civic commotion, sabotage, act of State or direction from Governmental / Statutory Authority, explosion, epidemic, pandemic, quarantine restrictions, strikes and lockouts (as are not limited to the establishments and facilities of the contractor), fire, floods, natural calamities or any act of GOD, provided notice of happening of any such event is given by the affected party to the other, within 21 days from the date of occurrence thereof, neither Party, shall have any claims for damages against the other, in respect of such non-performance or delay in performance provided the Agreement shall be resumed as soon as practicable, after such event comes to an end or ceases to exist. The decision of the CMD, ITPO as to whether the service may be so resumed (and the time frame within which the service may be resumed) or not, shall be final and conclusive, provided further that if the performance in whole or part of any obligation under this Agreement is prevented or delayed by reason of any such event for a period exceeding 60 days either party may, at their option, terminate the Agreement.
Sample 1Sample 2Sample 3
Force Majeure Clause means [IPMA Version 1/Version 2] in the form in existence on [date on which Managers were informed of the Version to be used], with the clause relating to expenses being deemed to be Clause 10 of the Standard Terms, and with the Lead Manager referred to being deemed to be the Lead Manager, as defined herein;
Sample 1

Examples of Force Majeure Clause in a sentence

  • In the event a specified manufacturer’s Product listed in the Contract becomes unavailable or cannot be supplied by the Contractor for any reason (except as provided for in the Force Majeure Clause below) a Product deemed by the Commissioner to be equal to or better than that specified must be substituted by the Contractor at no additional cost or expense to the Authorized User.

  • If there is delay in performance or other failures by the supplier to perform its obligation under the contract due to an event of a Force Majeure and the contract is governed by Force Majeure Clause, the supplier shall not be held responsible for such delays / failures.

  • Warranty (GCC Clause 28), Force Majeure (Clause 32), Limitation of liability (GCC Clause 30), Governing law (GCC Clause 9) and Taxes & Duties (GCC Clause 17) will be deemed to be a material deviation.

  • If there is delay in performance or other failures by the supplier to perform its obligation under the contract due to an event of a Force Majeure and the contract is governed by Force Majeure Clause, the supplier shall not be held responsible for such delays/failures.

  • Except as provided under the Force Majeure Clause, a delay the supplier in the performance of its delivery obligations shall render the Supplier liable to the imposition of liquidated damages pursuant to liquidated damages Clause unless an extension of time is agreed upon pursuant to above clause without the application of penalty clause.

  • The contract entrusted to the successful tenderer shall be subject to "Force Majeure Clause" as per Section 56 of Indian Contract Act restricting to the case of natural calamity such as earthquake, storm, floods or rising of war by any country.

  • Non-acceptance of Resolution of Disputes/Arbitration Clause, applicable laws and Force Majeure Clause etc.

  • Force Majeure Clause will not be used by any party to effectively escape liability for bad performance and Contractor shall seek all reasonable alternative means for performance not prevented by Force Majeure events.

  • The contract entrusted to the successful vendor shall be subject to "Force Majeure Clause" as per Section 56 of Indian Contract Act restricting to the case of natural calamity such as earthquake, storm, floods or rising of war by any country.

  • The terms and conditions mutually agreed shall be subject to the Force Majeure Clause.


More Definitions of Force Majeure Clause

Force Majeure Clause. A party shall not be liable for any failure of or delay in the performance of this agreement for the period that such failure or delay is due to causes beyond its reasonable control. (Individual Pay)
Sample 1
Force Majeure Clause. [Xxxxx Xxxxxx 21 of General Terms & Conditions attached at Annexure A]. Contd./Pg5… :5:
Sample 1

Related to Force Majeure Clause

  • Force Majeure Delay means with respect to the Servicer, any cause or event which is beyond the control and not due to the negligence of the Servicer, which delays, prevents or prohibits such Person’s delivery of the reports required to be delivered or the performance of any other duty or obligation of the Servicer under the Indenture, as the case may be, including, without limitation, computer, electrical and mechanical failures, acts of God or the elements and fire; provided, that no such cause or event shall be deemed to be a Force Majeure Delay unless the Servicer shall have given the Indenture Trustee written notice thereof as soon as practicable after the beginning of such delay.

  • Force Majeure Delays means any actual delay in the construction of the Tenant Improvements, which is beyond the reasonable control of Landlord or Tenant, as the case may be, as described in Paragraph 33 of the Lease.

  • Force Majeure means an event beyond the control of the supplier and not involving the supplier’s fault or negligence and not foreseeable. Such events may include, but is not restricted to, acts of the purchaser in its sovereign capacity, wars or revolutions, fires, floods, epidemics, quarantine restrictions and freight embargoes.

  • Force Majeure Report means a report to be given by the Affected Party to the other party following the giving of a Force Majeure Notice;

  • Force Majeure Notice means a notice to be given by the Affected Party to the other party stating that a Force Majeure Event has occurred;

  • Force Majeure Event means an event, or a series of related events, that is outside the reasonable control of the party affected (including failures of the internet or any public telecommunications network, hacker attacks, denial of service attacks, virus or other malicious software attacks or infections, power failures, industrial disputes affecting any third party, changes to the law, disasters, explosions, fires, floods, riots, terrorist attacks and wars);

  • Force Majeure Events means acts of war, domestic and/or international terrorism, civil riots or rebellions, quarantines, embargoes and other similar unusual governmental actions, extraordinary elements of nature or acts of God.

  • Force Majeure Exception means any failure or delay in the performance of the Fund’s reporting obligation pursuant to Section 2.3 arising out of or caused, directly or indirectly, by circumstances beyond its reasonable control, including, without limitation, acts of God; earthquakes; flood; terrorism; wars and other military disturbances; sabotage; epidemics; riots; loss or malfunctions of utilities, computer (hardware or software) or communication services; accidents; acts of civil or military authority and governmental action. The Fund shall use commercially reasonable efforts to commence performance of its obligations during any of the foregoing circumstances.

  • Relevant Force Majeure Event means a Force Majeure Event in relation to which an Affected Party is claiming relief under this Clause 17; and

  • Force Majeure Period has the meaning specified in Section 13.1.

  • Force Majeure Failure has the meaning set forth in Section 8.1(d).

  • Unavoidable Delays means delays due to any of the following, and only the following, (provided that such delay is beyond Construction Manager’s reasonable control): war, insurrection, civil commotion, strikes, slowdowns, lock outs, riots, flood, earthquakes, fires, casualties, acts of God, acts of a public enemy, acts of terrorism, epidemics, quarantine restrictions, freight embargoes, lack of transportation, governmental moratoriums, unusually severe or abnormal weather conditions, failure of utilities, or a court order which causes a delay (unless resulting from a wrongful act of Construction Manager). In no event shall the application to Construction Manager of any applicable law, regulation, rule or other governmental requirement constitute an Unavoidable Delay. Contractor shall use reasonable good faith efforts to notify Owner not later than five (5) days after Construction Manager knows of the occurrence of an Unavoidable Delay. An extension of time for an Unavoidable Delay shall only be for the period of the Unavoidable Delay, which period shall commence to run from the time of the commencement of the cause of the Unavoidable Delay.

  • Unavoidable Delay means an event which delays Closing which is a strike, fire, explosion, flood, act of God, civil insurrection, act of war, act of terrorism or pandemic, plus any period of delay directly caused by the event, which are beyond the reasonable control of the Vendor and are not caused or contributed to by the fault of the Vendor. “Unavoidable Delay Period” means the number of days between the Purchaser’s receipt of written notice of the commencement of the Unavoidable Delay, as required by paragraph 5(b), and the date on which the Unavoidable Delay concludes.

  • Excusable Delay means a delay due to acts of God, governmental restrictions, stays, judgments, orders, decrees, enemy actions, civil commotion, fire, casualty, strikes, work stoppages, shortages of labor or materials or other causes beyond the reasonable control of Borrower, but lack of funds in and of itself shall not be deemed a cause beyond the control of Borrower.

  • Excusable Delays means delays due to acts of terrorism, acts of war or civil insurrection, strikes, riots, floods, earthquakes, fires, tornadoes, casualties, acts of God, labor disputes, governmental restrictions or priorities, embargoes, national or regional material shortages, failure to obtain regulatory approval from any Federal or State regulatory body, unforeseen site conditions, extraordinary rainfall or snowfall, or any other condition or circumstances beyond the reasonable or foreseeable control of the applicable Party using reasonable diligence to overcome which prevents such Party from performing its specific duties or obligation hereunder in a timely manner; provided, however, Excusable Delay does not include lack of financing, unanticipated or unexpected increases in the costs of construction, or errors in business judgment by a Party; and provided further that Excusable Delay shall only extend the time of performance for the period of such Excusable Delay, which shall begin on the date which the event of Excusable Delay first occurs and extend until the date which the event which has caused the Excusable Delay has been corrected or performed, or reasonably should have been corrected or performed.

  • Event of Force Majeure means one of the following events:

  • Tenant Delays A "Tenant Delay" shall mean any delay in Substantial Completion of the Building as a result of any of the following: (i) Tenant's failure to complete or approve the Tenant Improvement Plans by the dates set forth in Section 5.B, (ii) Tenant's failure to approve the bids for construction by the dates set forth in Section 5.C, (iii) changes to either the Shell Plans and Specifications or the Tenant Improvement Plans requested by Tenant which delay the progress of the work, (iv) Tenant's request for materials, components or finishes which are not available in a commercially reasonable time given the target Commencement Date, (v) Tenant's failure to make a progress payment for Tenant Improvement costs as provided in Section 5.F, (vi) Tenant's request for more than one (1) rebidding of the cost of all or a portion of the work, and (vii) any errors or omissions in the Tenant Improvement Plans provided by Tenant's architect. In the event Landlord believes Tenant is causing a Tenant Delay, Landlord shall notify Tenant in writing, state the action or inaction that it believes is causing the Tenant Delay, and state the date from which a Tenant Delay is being calculated. Claim of Tenant Delay shall be made within five (5) days after Landlord's discovery of the occurrence of the event giving rise to such claim. Tenant shall have the right to expedite work, at its sole cost, to minimize the effect of any Tenant Delays, to the extent it is practicable to do so. However, no Tenant Delay shall advance the Commencement Date to a date before the estimated Commencement Date of October 1, 2001. Notwithstanding anything to the contrary set forth in this Lease and regardless of the actual date the Premises are Substantially Complete (but subject to the limitation in the preceding sentence), the Commencement Date shall be deemed to be the date the Commencement Date would have occurred if no Tenant Delay had occurred as reasonably determined by Landlord. In addition, if a Tenant Delay results in an increase in the cost of the labor or materials, Tenant shall pay the cost of such increases.

  • Tenant Delay Any event or occurrence that delays the completion of the Landlord Work which is caused by or is described as follows:

  • Landlord Delay means any actual delay in the completion of the Improvements as a result of Landlord’s breach or material default under this Third Amendment (including, without limitation, any breach of representation or warranty); any delays relating to any of the matters specified in Section 5.3 of Exhibit B; any failure to respond to any items required to be furnished or approved by Landlord within a time period expressly set forth in this Third Amendment or the Lease (unless a deemed approval is specified, in which case no Landlord Delay shall be assessed); Landlord’s failure to allow contractors access to the Building or Premises as scheduled in advance with the Building’s property manager or Landlord’s request for material changes in the fmal Plans and Specifications after Landlord’s approval thereof (unless such request was caused by an error or omission by Tenant), provided, however, that notwithstanding the foregoing, no Landlord Delay shall be deemed to have occurred unless and until Tenant has delivered to Landlord a factually correct written notice (the “Landlord Delay Notice”), specifying the bona fide action or inaction which Tenant contends constitutes the Landlord Delay. If such action or inaction is not cured by Landlord within two (2) business days of Landlord’s receipt of such Landlord Delay Notice, then the Landlord Delay shall be deemed to have occurred as of the expiration of such two (2) business day period. A delay in construction of the Improvements due to a Tenant Delay (as defined in Exhibit B, attached to and part of the Original Lease), any Force Majeure event or a delay by any governmental authority (including but not limited to the City of Los Angeles) shall not be deemed a Landlord Delay. Any Landlord Delay Notice shall be sent to the notice address set forth in the Lease with copies to (a) to the property manager at the management office of the Building; and to (b) Xxxxxxx Xxxxxx Management LLC, 000 Xxxxxxxx Xxxxxxxxx, Xxxxx 000, Xxxxx Xxxxxx, Xxxxxxxxxx 00000, Attention: Leasing Legal Department Manager.

  • Dedicated FX Traffic means those calls routed by means of a physical, dedicated circuit delivering dial tone or otherwise serving an End User’s station from a serving Central Office (also known as End Office) located outside of that station’s mandatory local calling area. Dedicated FX Service permits the End User physically located in one exchange to be assigned telephone numbers resident in the serving Central (or End) Office in another “foreign” exchange, thereby creating a local presence in that “foreign” exchange.

  • Interruption of irradiation means the stopping of irradiation with the possibility of continuing irradiation without resetting of operating conditions at the control panel.

  • Base Building Work means the base building work for the Building as described in this Manual.

  • Act of God means a cataclysmic phenomenon of nature, including earthquake, flood or cyclone. Rain, snow, wind, high water or any other natural phenomenon, which might reasonably have been anticipated from historical records of the general locality of the City, shall be deemed not to be acts of God;

  • Excused Outage means any disruption to or unavailability of Services caused by or due to (i) Scheduled Maintenance,

  • Contract Work means everything required to be furnished and done by the Contractor by any one or more of the parts of the Contract referred to in Article 1, except Extra Work as hereinafter defined.

  • Subprocessors means third parties authorised under these Data Processing Terms to have logical access to and process Customer Personal Data in order to provide parts of the Processor Services and any related technical support.