Change Order Due to Suspension of Work by Owner Sample Clauses

Change Order Due to Suspension of Work by Owner. Subject to Section 9.5.1, if after the Effective Date Owner suspends the Work pursuant to the provisions of
Sample 1Sample 2Sample 3See All (4)
AutoNDA by SimpleDocs
Change Order Due to Suspension of Work by Owner. Subject to Section 9.5.1, if after the Effective Date Owner suspends the Work pursuant to the provisions of Section 12.6, then: (A) Owner shall issue a Change Order extending the Project Schedule to the extent required under Section 9.5.2; and (B) to the extent that such suspension increases Contractor’s Direct Costs in performing the Work, Owner will, via Change Order, increase the Contract Price to the extent required under Section 9.5.3. Such Change Order shall be Contractor’s sole and exclusive remedy for any increased costs and delays resulting from such suspension of Work by Owner, and Contractor will not be entitled to any additional payment, damages or other compensation in connection with any such delays.
Sample 1Sample 2
Change Order Due to Suspension of Work by Owner. In the event that Owner suspends the Work pursuant to the provisions of Section 23.2, then, upon submission of a proper Change Order Notice and subject to the other Sections of this Article 19, Contractor will be entitled to a Change Order extending the Approved Project Schedule as required and, if necessary, increasing the Contract Price pursuant to Section 19.14 so as to equitably compensate Contractor for additional demonstrable Direct Costs incurred by Contractor as Directly Caused by such suspension. Such Change Order will be Contractor’s sole and exclusive remedy for such increased costs and/or delay. During the suspension period, Owner shall reimburse Contractor on a time and material basis for its stand-by charges, storage and maintenance charges, and demobilization and remobilization charges.
Sample 1
Change Order Due to Suspension of Work by Owner. In the event that Owner suspends the Work (i) in the circumstances with respect to which the Contractor is entitled to a Change Order as set out in Article 14.1; or (ii) in the circumstances set out in Section 14.2, or (iii) Contractor suspends the Work pursuant to Section 6.9.6.
Sample 1

Related to Change Order Due to Suspension of Work by Owner

  • Suspension of Work and Termination OWNER May Suspend Work:

  • Suspension of Work The Department may, at its sole discretion, suspend any or all activities under the Contract, at any time, when it is in the best interest of the State of Florida to do so. The Customer may suspend a resulting contract or purchase order, at any time, when in the best interest of the Customer to do so. The Department or Customer will provide the Contractor written notice outlining the particulars of the suspension. After receiving a suspension notice, the Contractor must comply with the notice and will cease the performance of the Contract or purchase order. Suspension of work will not entitle the Contractor to any additional compensation. The Contractor will not resume performance of the Contract or purchase order until so authorized by the Department.

  • Contract Suspension and Modification (a) Contracting Officer may, by written order, delay or interrupt authorized operations under this contract or, notwithstanding B8.3, modify this contract, in whole or in part:

  • COMMENCEMENT OF WORK UNDER A SOW AGREEMENT Commencement of work as a result of the SOW-RFP process shall be initiated only upon issuance of a fully executed SOW Agreement and Purchase Order.

  • Suspension of Work Authorization DocuSign Envelope ID: 117D111C-A794-4428-BDF3-5CF841540F29

  • Statement of Work The Contractor shall provide the services and staff, and otherwise do all things necessary for or incidental to the performance of work, as set forth below:

  • CORRECTION OF WORK 13.2.1 The Contractor shall be responsible for correcting all Work which the Architect has found to be defective or which fails to conform to the Contract Documents whether observed be- fore or after Substantial Completion and whether or not fabricated, installed or completed. The Contractor shall bear all costs of correcting such rejected Work, including compensation for the Architect's and the State’s additional services made necessary thereby. The Architect, upon a finding of defect or failure to conform, shall immediately notify the State and Contractor, in writing, of the defect. The Contractor shall begin correcting the defective or non-conforming Work within ten (10) days unless the State agrees to a Change Order which reflects the reduction in Contract Sum due to the value of diminishment of the defective or nonconforming Work.

  • Rejection of Work Using the Notice of Non-Conforming Work procedures outlined in the General Conditions, the Design Professional shall reject work that does not comply with the requirements of the Contract Documents or that does not comply with the applicable laws and codes. The Design Professional shall have authority to order testing of the Work, as is provided in the Contract Documents or as otherwise required in its judgment, whether such work is fabricated, installed, or completed.

  • Modification of Licensed Materials The Participating Institutions or the Authorized Users shall not modify or manipulate the Licensed Materials without the prior written permission of the Licensor.

  • Performance of Work by City If the Contractor fails to perform the Work in accordance with the schedule referred to in section 2 above, the City may, in its discretion, in order to bring the project closer to the schedule, perform or cause to be performed some or all of the Work, and doing so shall not waive any of the City’s rights and remedies. Before doing so, the City shall give the Contractor notice of its intention. The Contractor shall reimburse the City for additional costs incurred by the City in exercising its right to perform or cause to be performed some or all of the Work pursuant to this section.

Time is Money Join Law Insider Premium to draft better contracts faster.