Successful Acceptance Test definition

Successful Acceptance Test means acceptance test conducted by the team of technical experts nominated by the HIGH COURT to ascertain that the items after delivery at the premises of HIGH COURT at Allahabad and its Bench at Lucknow are as per the technical specifications and of acceptable quality;
Sample 1Sample 2Sample 3
Successful Acceptance Test means acceptance test conducted by the team of technical experts nominated by the JTRI to ascertain that the items after delivery at the different site of Installations are as per the technical specifications and of acceptable quality;
Sample 1Sample 2
Successful Acceptance Test means acceptance test conducted by the team of technical experts nominated by the HIGH COURT to ascertain that the items after delivery at the different site of Installations are as per the technical specifications and of acceptable quality;
Sample 1Sample 2Sample 3

More Definitions of Successful Acceptance Test

Successful Acceptance Test means acceptance test conducted by the team of technical experts nominated by the HIGH COURT to ascertain that the items after delivery at the premises of HIGH COURT at Allahabad are as per the technical specifications and of acceptable quality;
Sample 1
Successful Acceptance Test means acceptance test conducted by the team of Officers nominated by the HIGH COURT to ascertain that the items after delivery at the premises of District Courts of U.P. under E-Court Project are as per the technical specifications and of acceptable quality;
Sample 1

Related to Successful Acceptance Test

  • Acceptance Test is a test of the Features executed by the Customer to prepare the acceptance.

  • Operational Acceptance Tests means the tests specified in the Technical Requirements and Agreed Project Plan to be carried out to ascertain whether the System, or a specified Sub system, is able to attain the functional and performance requirements specified in the Technical Requirements and Agreed Project Plan, in accordance with the provisions of GCC Clause 27.2 (Operational Acceptance Test).

  • Acceptance Tests means those tests performed during the Performance Period which are intended to determine compliance of Equipment and Software with the specifications and all other Attachments incorporated herein by reference and to determine the reliability of the Equipment.

  • Acceptance Testing mean the tests, reviews and other activities that are performed by or on behalf of Agency to determine whether the Deliverables meet the Acceptance Criteria or otherwise satisfy the Agency, as determined by the Agency in its sole discretion.

  • Successful Completion means that in the reasonable opinion of the Customer, Deliverables completed by the Supplier are fit for purpose, completed on time and otherwise meet all the criteria defined under this Contract;

  • Final Acceptance Date means, in respect of any Offer, the final date for acceptance of such Offer which, if such Offer is extended prior to becoming unconditional, shall be the final date for acceptance of the extended Offer (but, if such Offer is or becomes unconditional, disregarding any additional or further period during which such Offer is open for acceptance);

  • Project Milestone means the project milestone set forth in Schedule-J;

  • Final Acceptance means final written acceptance of all the Work by the Commissioner, a copy of which shall be sent to the Contractor.

  • Acceptance Test Document means a document, which defines procedures for testing the functioning of installed system. The document will be finalized with the contractor within 7 days of issuance of the Letter of Award.

  • Performance Test means all operational checks and tests required to determine the performance parameters including inter-alia capacity, efficiency and operating characteristics of the Stores as specified in the Contract.

  • Final Completion Date means the date on which Final Completion occurs.

  • Final completion and acceptance means the stage in the progress of the work as determined by the Contracting Officer and confirmed in writing to the Contractor, at which all work required under the contract has been completed in a satisfactory manner, subject to the discovery of defects after final completion, and except for items specifically excluded in the notice of final acceptance.

  • Completion Period means the period starting from the date of issue of "Order" and required to complete the work in all respect.

  • Project Milestones means the project milestones set forth in Schedule-G;

  • Performance Tests means the tests to be conducted on the equipment at site for checking the performance parameters of the equipment as defined in Technical Specification.

  • Witness Test means the Company’s right to witness the commissioning testing and/or Company-required Interconnecting Customer-owned communication system. Commissioning testing is defined in IEEE Standard 1547-2003.

  • Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.

  • Operational Acceptance means the acceptance by the Procuring Entity of the Facilities (or any part of the Facilities where the Contract provides for acceptance of the Facilities in parts), which certifies the Contractor's fulfillment of the Contract in respect of Functional Guarantees of the Facilities (or the relevant part thereof) in accordance with the provisions of GCC Clause 28 (Functional Guarantees) hereof and shall include deemed acceptance in accordance with GCC Clause 25 (Commissioning and Operational Acceptance) hereof.

  • Completion Rate means the percentage of an apprenticeship cohort who receives a certificate of apprenticeship completion within 1 year of the projected completion date. An apprenticeship cohort is the group of individual apprentices registered to a specific program during a 1 year time frame, except that a cohort does not include the apprentices whose apprenticeship agreement has been cancelled during the probationary period or who have transferred.

  • DNS test Means one non-­‐recursive DNS query sent to a particular “IP address” (via UDP or TCP). If DNSSEC is offered in the queried DNS zone, for a query to be considered answered, the signatures must be positively verified against a corresponding DS record published in the parent zone or, if the parent is not signed, against a statically configured Trust Anchor. The answer to the query must contain the corresponding information from the Registry System, otherwise the query will be considered unanswered. A query with a “DNS resolution RTT” 5 times higher than the corresponding SLR, will be considered unanswered. The possible results to a DNS test are: a number in milliseconds corresponding to the “DNS resolution RTT” or, undefined/unanswered.

  • project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;

  • RDDS test Means one query sent to a particular “IP address” of one of the servers of one of the RDDS services. Queries shall be about existing objects in the Registry System and the responses must contain the corresponding information otherwise the query will be considered unanswered. Queries with an RTT 5 times higher than the corresponding SLR will be considered as unanswered. The possible results to an RDDS test are: a number in milliseconds corresponding to the RTT or undefined/unanswered.

  • LCT Test Date shall have the meaning provided in Section 1.12(b).

  • Subproject means a development activity proposed by a Beneficiary under Part A.2 (d) of the Project and financed or to be financed through a Subproject Grant (as hereinafter defined) made out of the proceeds of the Development Credit;

  • Development Milestone Event shall have the meaning set forth in Section 9.2(a).

  • Drug test means a test designed to detect the illegal use of a controlled substance.