Performance Tests definition

Performance Tests means all tests meant to ensure that the Plant(s)/Unit(s) is/are in all respects in accordance with the requirements of the Contract and that the Plant functions properly and smoothly, in all respects as per the approved design parameters, within the permissible tolerances, and satisfies all the stipulated operating parameters, and will include the Guarantee Tests.

AI-Powered Contracts

Draft, Review & Redline at the Speed of AI

Performance Tests means the tests to be conducted on the equipment at site for checking the performance parameters of the equipment as defined in Technical Specification.

Performance Tests means the tests performed (including any repetition thereof) to determine whether the Project meets the Performance Guarantee and/or Minimum Acceptance Criteria set forth in Attachment T, which tests shall be as specified in and consistent with Attachment S.

Examples of Performance Tests in a sentence

Contractor shall promptly provide Notice to Owner in writing that such corrective measures have been completed and shall specify in such Notice the date on which the LNG Production System or the Facility will be ready for the Performance Tests to be rerun.
Owner may request that Contractor provide written information (prior to the issuance of a request for change) regarding the effect of a contemplated change on (a) the Work or the requirements set forth in Exhibit A, (b) the Target Price, (c) the Project Schedule, (d) the Critical Path, (e) any Applicable Deadline or Schedule Milestone Completion Date, if applicable, (f) the Demonstration Tests or Performance Tests, or (g) any right, liability or obligation of Contractor hereunder.
Owner shall manage the operation and maintenance personnel (including the personnel of Contractor) during the Performance Tests.
Defects or Deficiencies discovered during any Performance Tests may, in the sole, reasonable judgment of Owner, require remedy and a subsequent Performance Test; provided that, if the immediately prior Performance Test was successfully passed, then any subsequent Performance Test shall not prevent Contractor’s achievement of LNG Production System Substantial Completion of an LNG Production System or Facility Substantial Completion, as applicable.
In addition, Contractor shall provide the support services necessary at the Job Site for the installation, start-up and performance of the Commissioning of each LNG Production System and the Facility and the running or rerunning of the Performance Tests in accordance with the requirements of the Performance Tests and the provisions hereof.

More Definitions of Performance Tests

Performance Tests means such tests as are prescribed in the ‘Specification’, to be done by the vendor before the Plant is taken over under guarantee by the owner/ purchaser.

Performance Tests means all tests to be carried out by contractor as per specifications prior to installation being taken over by Bank under guarantee.

Performance Tests has the meaning set forth in Exhibit R.

Performance Tests means the Liquefaction Train Performance Tests and the Liquefaction Train System Performance Tests.

Performance Tests means all start-up and shakedown procedures and performance tests to be conducted under the EPC Agreement before Final Completion.

Performance Tests means such tests as are prescribed in the 'Specification', to be done by the CONTRACTOR before the plant is taken over under guarantee by the Owner to the satisfaction of the ENGINEER.

Performance Tests has the meaning ascribed in Article 12 of this Contract.