Scheduled Construction Completion Date definition

Scheduled Construction Completion Date means date of the completion of the Construction Period, which shall be at the expiry of a period of 6 (Six) months from the Compliance Date.
Sample 1Sample 2Sample 3
Scheduled Construction Completion Date means date of the completion of the Construction Period, which shall be at the expiry of a period of 18 (eighteen) months from the Compliance Date.
Sample 1Sample 2Sample 3
Scheduled Construction Completion Date has the same meaning as Section 8.03 (a) in this Agreement.
Sample 1Sample 2

Examples of Scheduled Construction Completion Date in a sentence

  • The relevant portions of Article 3.3 state:3.3.2 Contractor shall achieve Mechanical Completion no later than the Scheduled Mechanical Completion Date and Construction Completion no later than the Scheduled Construction Completion Date.

  • The Concessionaire shall in consultation with the Independent Engineer prepare and evolve, not later than 28 days prior to the Scheduled Construction Completion Date, a draft Operation and Maintenance Manual (“O&M Manual”) providing the detailed plan for regular and preventive maintenance of the Ecotourism & Adventure Park.

  • In the event that Construction Completion Date is not achieved by the Scheduled Construction Completion Date, unless the delay is on account of reasons solely attributable to the Concessioning Authority or due to Force Majeure, the Concessioning Authority shall encash 5% of the Performance Security amount per month, for a maximum period of 6 (six) months after which Concessioning Authority shall be entitled to terminate this Agreement.

  • The Annual Fee is payable throughout the Concession Period commencing from Commercial Operations Date / Scheduled Construction Completion Date, whichever is earlier and shall be escalated by 5% every year throughout the Concession Period.

  • Therefore, the Parties have agreed to quantify and to agree upon such damages in advance.3.3.3 In the event Contractor fails to achieve (a) Mechanical Completion by the Scheduled Mechanical Completion Date or (b) Construction Completion by the Scheduled Construction Completion Date, in either case, Contractor agrees to pay Covanta as liquidated damages (and not as a penalty nor subject to any proof of such loss)Contract art.

  • The Concessionaire will be required to design, finance, construct and complete the Facilities on or prior to the Scheduled Construction Completion Date, in accordance with the Concession Agreement.

  • The Concessionaire shall in consultation with the Independent Engineer prepare and evolve, not later than 28 (twenty eight) days prior to the Scheduled Construction Completion Date, a draft Operation and Maintenance Manual (“O&M Manual”) providing the detailed plan for regular and preventive maintenance of the Circuit House.

  • If the Independent Engineer reasonably determines that the rate of progress of the construction of the Bus Terminal Facility is such that the Construction Completion is not feasible on or before the Scheduled Construction Completion Date, it shall so notify the Concessionaire.

  • RSBTDA shall ensure that an O&M Steering Committee, comprising of one person nominated by the RSBTDA, an officer nominated by Transport Commissioner, one representative of the GoR, who may be a Superintending Engineer of PWD or his nominee not below the rank of Executive Engineer, PWD and one person nominated by the Concessionaire (the “O&M Steering Committee”), is established one month prior to the Scheduled Construction Completion Date or date of Construction Completion, whichever is earlier.

  • The end of 18th month from the Effective Date shall be the Scheduled Construction Completion Date (the “Scheduled Construction Completion Date”) for completion of construction and the Concessionaire agrees and undertakes that an Old Age Home in accordance with the specifications mentioned in Schedule D shall be ready on or before the Scheduled Construction Completion Date.


More Definitions of Scheduled Construction Completion Date

Scheduled Construction Completion Date means Scheduled Construction Completion Date – P&D as more particularly specified at Annexure 14;
Sample 1
Scheduled Construction Completion Date means the date falling 12 monthsfromthe Commencement Date, being the date by which the Concessionaire is expected to acquire the Construction Completion Certificateas such date may be extended from time to time in accordance with this Agreement.
Sample 1
Scheduled Construction Completion Date shall have the meaning specified in Clause 9.5(b).
Sample 1

Related to Scheduled Construction Completion Date

  • Construction Completion Date means the date by which the overall development of the Project is completed in accordance with the provisions of this Agreement and when the Construction Completion Certificate is issued by the Independent Engineer as per Article 14.1.

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Scheduled Project Completion Date shall have the meaning specified in Section 6.3 (c);

  • Scheduled Completion Date shall be the date set forth in Clause 10.3;

  • Construction Completion means physical construction of a cleanup action component is complete.

  • Target Completion Date has the meaning given such term in Section 3.3(b).

  • Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity

  • project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;

  • Construction Commencement Date means the date set out in the Addendum, if applicable, by which you must commence construction of the Hotel. For the Hotel to be considered under construction, youmust have begun to pour concrete foundations for the Hotel or otherwise satisfied any site-specific criteria for “under construction” set out in the Addendum.

  • Project Completion means completion of the Redevelopment in accordance with this Agreement to the state where the whole of the Morley Shopping Centre, as so redeveloped, is capable of occupation for its intended purpose;

  • The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.

  • Final Completion Date means the date on which Final Completion occurs.

  • Substantial Completion Date means the date on which Substantial Completion occurs.

  • Commenced Construction means (a) all of the following site preparation work is completed: ingress and egress routes exist; the site on which the project will be located is cleared and graded; there is power service to the site; footings are prepared; and foundations have been poured consistent with purchased equipment specifications and project design; or (b) the following financial commitments have been made: (i) (A) an engineering, procurement, and construction contract (“EPC”) has been executed by all parties and is effective; or (B) contracts (collectively, “EPC Equivalents”) for all of the following have been executed by all parties and is effective: (1) project engineering, (2) procurement of all major equipment, and (3) construction of the project, and (ii) the cumulative payments made by the developer under the EPC or EPC Equivalents to the counterparties to those respective agreements is equal to at least thirty (30) percent of the total costs of the EPC or EPC Equivalents.

  • Construction Completion Certificate means a document:

  • Project Completion Schedule means the progressive Project Milestones set forth in Schedule-J for completion of the Project Highway on or before the Scheduled Completion Date;

  • Construction Schedule means a construction schedule indicating the planned start and completion dates of the major activities of the Work as set out in Appendix [ ], a future Appendix;

  • Construction Plant means appliances, machinery with necessary supply to up keep and maintenance of the works or temporary works but dose not include materials or other things intended to form part of the permanent work.

  • Construction project means the same as that term is defined in Section 38-1a-102.

  • Construction Period means the period commencing from the Appointed Date and ending on the date of the Completion Certificate;

  • Project Commencement Date means the commencement date notified to the Minister pursuant to clause 4(1);

  • Commencement Date or Handover Date means the date on which the Licensed Space of first lot of stations as per Annexure 1 is handed over by DMRC to the Selected Bidder, in accordance with the terms of this agreement.

  • construction site means a workplace where construction work is being performed;

  • Notice to Proceed (NTP) means the authorization issued by the CO to start performance on this Contract.

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Erection, construction, remodeling, repairing means all types of work done on a particular building or work at the site thereof in the construction or development of the project, including without limitation, erecting, construction, remodeling, repairing, altering, painting, and decorating, the transporting of materials and supplies to or from the building or work done by the employees of the Contractor, Subcontractor, or Agent thereof, and the manufacturing or furnishing of