LIMITED MUTUAL WAIVER OF CONSEQUENTIAL DAMAGES Sample Clauses

LIMITED MUTUAL WAIVER OF CONSEQUENTIAL DAMAGES. Except for any (a) liquidated, consequential, or other damages that the Owner is entitled to recover against the Constructor under the prime agreement, and (b) losses covered by insurance required by the Subcontract Documents, the Constructor and Subcontractor mutually waive all claims against each other for consequential damages, including damages for loss of business, loss of financing related to the Project, loss of profits not related to this Project, loss of bonding capacity, loss of reputation, or insolvency. Similarly, the Subcontractor shall obtain in another agreement from its subcontractors mutual waivers of consequential damages that correspond to the Subcontractor's waiver of consequential damages herein. The provisions of this section shall also apply to and survive termination of this Agreement.
Sample 1Sample 2See All (5)
AutoNDA by SimpleDocs
LIMITED MUTUAL WAIVER OF CONSEQUENTIAL DAMAGES. Except for damages mutually agreed upon by the Parties as liquidated damages in Section 6.9 and excluding losses covered by insurance required by the Contract Documents, the Parties agree to waive all claims against each other for any consequential damages that may arise out of or relate to this Agreement related to failure to complete the Project timely.
Sample 1
LIMITED MUTUAL WAIVER OF CONSEQUENTIAL DAMAGES. 5.3.1 To the extent the Prime Contract provides for a mutual waiver of special, incidental, indirect, or consequential damages by the Owner and the Design-Builder, the Design-Builder and the Architect/Engineer waive claims against each other for special, incidental, indirect, or consequential damages arising out of or relating to this Agreement, whether arising in contract, warranty, tort (including negligence), strict liability, or otherwise, including, but not limited to, losses of use, profits, business, reputation, or financing, in connection with any claims, controversies, or disputes concerning matters which pertain to disputes cognizable under the Disputes Clause of the Prime Contract. The Design-Builder and the Architect/Engineer further waive claims against each other for special, incidental, indirect, or consequential damages arising out of or relating to this Agreement, whether arising in contract, warranty, tort (including negligence), strict liability, or otherwise, including, but not limited to, losses of use, profits, business, reputation, or financing, in connection with any claims, controversies, or disputes concerning matters which pertain to disputes between the Design-Builder and the Architect/Engineer that are not cognizable under the Disputes Clause of the Prime Contract. To the extent applicable, this mutual waiver applies to consequential damages due to termination by the Design-Builder or the Owner in accordance with this Agreement or the Prime Contract. The provisions of this Paragraph shall also apply to and survive termination of this Agreement.
Sample 1
LIMITED MUTUAL WAIVER OF CONSEQUENTIAL DAMAGES. 4.3.1 Except for damages provided for by the Subcontract Documents as liquidated damages and excluding losses covered by insurance required by the Subcontract Documents, the Contractor and Subcontractor waive claims against each other for consequential damages arising out of or relating to this Agreement, to the same extent the Owner-Contractor agreement furnished to the Subcontractor in accordance with Paragraph 2.3 provides for a mutual waiver of consequential damages by the Owner and Contractor, including to the extent provided in the Owner-Contractor agreement, damages for loss of business, loss of financing, principal office overhead and expenses, loss of profits not related to this Project, loss of bonding capacity, loss of reputation, or insolvency. Similarly, the Subcontractor shall obtain in another agreement from its Sub-Subcontractors mutual waivers of consequential damages that correspond to the Subcontractor’s waiver of consequential damages herein. To the extent applicable, this mutual waiver applies to consequential damages due to termination by the Contractor or Owner in accordance with this Agreement or the Owner-Contractor agreement. The provisions of this Article shall also apply to and survive termination of this Agreement.
Sample 1
LIMITED MUTUAL WAIVER OF CONSEQUENTIAL DAMAGES. Except for damages mutually agreed upon by the Parties as liquidated damages in this Article and excluding losses covered by insurance required by the Contract Documents, the Owner and the Construction Manager agree to waive all claims against each other for any consequential damages that may arise out of or relate to this Agreement, except for those specific items of damages excluded from this waiver as mutually agreed upon by the Parties and identified below. The Owner agrees to waive damages including but not limited to the Owner’s loss of use of the Project, any rental expenses incurred, loss of income, profit or financing related to the Project, as well as the loss of business, loss of financing, loss of profits not related to this Project, loss of reputation, or insolvency. The Construction Manager agrees to waive damages including but not limited to loss of business, loss of financing, principal office overhead and expenses, loss of profits not related to this Project, loss of bonding capacity, loss of reputation, or insolvency. The following items of damages are excluded from this mutual waiver: None.
Sample 1

Related to LIMITED MUTUAL WAIVER OF CONSEQUENTIAL DAMAGES

  • Waiver of Consequential Damages To the fullest extent permitted by applicable Law, the Borrower shall not assert, and hereby waives, any claim against any Indemnitee, on any theory of liability, for special, indirect, consequential or punitive damages (as opposed to direct or actual damages) arising out of, in connection with, or as a result of, this Agreement, any other Loan Document, the Related Documents or any agreement or instrument contemplated hereby or thereby, the transactions contemplated hereby or thereby, any Term Loan or the use of the proceeds thereof. No Indemnitee referred to in subsection (b) above shall be liable for any damages arising from the use by unintended recipients of any information or other materials distributed by it through telecommunications, electronic or other information transmission systems in connection with this Agreement or the other Loan Documents, the Related Documents or the transactions contemplated hereby or thereby other than for direct or actual damages resulting from the gross negligence or willful misconduct of such Indemnitee as determined by a final and nonappealable judgment of a court of competent jurisdiction.

  • Waiver of Consequential Damages, Etc To the fullest extent permitted by applicable law, the Borrower shall not assert, and hereby waives, any claim against any Indemnitee, on any theory of liability, for special, indirect, consequential or punitive damages (as opposed to direct or actual damages) arising out of, in connection with, or as a result of, this Agreement, any other Loan Document or any agreement or instrument contemplated hereby, the transactions contemplated hereby or thereby, any Loan or Letter of Credit or the use of the proceeds thereof. No Indemnitee referred to in subsection (b) above shall be liable for any damages arising from the use by unintended recipients of any information or other materials distributed to such unintended recipients by such Indemnitee through telecommunications, electronic or other information transmission systems in connection with this Agreement or the other Loan Documents or the transactions contemplated hereby or thereby other than for direct or actual damages resulting from the gross negligence or willful misconduct of such Indemnitee as determined by a final and nonappealable judgment of a court of competent jurisdiction.

  • Disclaimer of Consequential Damages Notwithstanding any provision to the contrary, in no event shall any Party be liable to another Party for any incidental, consequential, special, exemplary or indirect damages, lost business profits or lost data arising out of or in any way related to the Contract Documents.

  • Waiver of Punitive Damages Notwithstanding anything to the contrary contained in this Agreement, the Borrower hereby agrees that it shall not seek from the Lenders or the Administrative Agent punitive, consequential, or indirect damages relating to any such matters under any theory of liability.

  • Exclusion of Consequential Damages ‌ Notwithstanding anything contained herein to the contrary, neither Party will be liable under this Agreement or under any cause of action relating to the subject matter of this Agreement for any special, indirect, incidental, punitive, exemplary or consequential damages, including loss of profits, loss of use of any property or claims of customers or contractors of the Parties for any such damages.

  • Limitation on Consequential Damages NEITHER PARTY WILL HAVE ANY OBLIGATION OR LIABILITY (WHETHER IN CONTRACT, WARRANTY, TORT (INCLUDING NEGLIGENCE) OR OTHERWISE, AND NOTWITHSTANDING ANY FAULT, NEGLIGENCE (WHETHER ACTIVE, PASSIVE OR IMPUTED), REPRESENTATION, STRICT LIABILITY OR PRODUCT LIABILITY), FOR COVER OR FOR ANY INCIDENTAL, INDIRECT, CONSEQUENTIAL, MULTIPLIED, PUNITIVE, SPECIAL, OR EXEMPLARY DAMAGES OR LOSS OF REVENUE, PROFIT, SAVINGS OR BUSINESS ARISING FROM OR OTHERWISE RELATED TO THIS AGREEMENT, EVEN IF A PARTY OR ITS REPRESENTATIVES HAVE BEEN ADVISED OF THE POSSIBILITY OF SUCH DAMAGES. THE PARTIES ACKNOWLEDGE THAT THESE EXCLUSIONS OF POTENTIAL DAMAGES WERE AN ESSENTIAL ELEMENT IN SETTING CONSIDERATION UNDER THIS AGREEMENT.

  • WAIVER OF JURY TRIAL, PUNITIVE DAMAGES, ETC BORROWER, ADMINISTRATIVE AGENT, AND EACH BANK HEREBY (a) KNOWINGLY, VOLUNTARILY, INTENTIONALLY, AND IRREVOCABLY WAIVE, TO THE MAXIMUM EXTENT NOT PROHIBITED BY LAW, ANY RIGHT IT MAY HAVE TO A TRIAL BY JURY IN RESPECT OF ANY LITIGATION BASED HEREON, OR DIRECTLY OR INDIRECTLY AT ANY TIME ARISING OUT OF, UNDER OR IN CONNECTION WITH THE LOAN PAPERS OR ANY TRANSACTION CONTEMPLATED THEREBY OR ASSOCIATED THEREWITH, BEFORE OR AFTER MATURITY; (b) IRREVOCABLY WAIVE, TO THE MAXIMUM EXTENT NOT PROHIBITED BY LAW, ANY RIGHT IT MAY HAVE TO CLAIM OR RECOVER IN ANY SUCH LITIGATION ANY “SPECIAL DAMAGES,” AS DEFINED BELOW; (c) CERTIFY THAT NO PARTY HERETO NOR ANY REPRESENTATIVE OR AGENT OR COUNSEL FOR ANY PARTY HERETO HAS REPRESENTED, EXPRESSLY OR OTHERWISE, OR IMPLIED THAT SUCH PARTY WOULD NOT, IN THE EVENT OF LITIGATION, SEEK TO ENFORCE THE FOREGOING WAIVERS, AND (d) ACKNOWLEDGE THAT IT HAS BEEN INDUCED TO ENTER INTO THIS AGREEMENT, THE OTHER LOAN PAPERS AND THE TRANSACTIONS CONTEMPLATED HEREBY AND THEREBY BY, AMONG OTHER THINGS, THE MUTUAL WAIVERS AND CERTIFICATIONS CONTAINED IN THIS SECTION. AS USED IN THIS SECTION, “SPECIAL DAMAGES” INCLUDES ALL SPECIAL, CONSEQUENTIAL, EXEMPLARY, OR PUNITIVE DAMAGES (REGARDLESS OF HOW NAMED), BUT DOES NOT INCLUDE ANY PAYMENT OR FUNDS WHICH ANY PARTY HERETO HAS EXPRESSLY PROMISED TO PAY OR DELIVER TO ANY OTHER PARTY HERETO.

  • WAIVER OF SPECIAL DAMAGES THE BORROWER WAIVES, TO THE MAXIMUM EXTENT NOT PROHIBITED BY LAW, ANY RIGHT THE UNDERSIGNED MAY HAVE TO CLAIM OR RECOVER FROM THE BANK IN ANY LEGAL ACTION OR PROCEEDING ANY SPECIAL, EXEMPLARY, PUNITIVE OR CONSEQUENTIAL DAMAGES.

  • No Consequential Damages Other than the Liquidated Damages heretofore described and the indemnity obligations set forth in Article 18.1, in no event shall any Party be liable under any provision of this Agreement for any losses, damages, costs or expenses for any special, indirect, incidental, consequential, or punitive damages, including but not limited to loss of profit or revenue, loss of the use of equipment, cost of capital, cost of temporary equipment or services, whether based in whole or in part in contract, in tort, including negligence, strict liability, or any other theory of liability; provided, however, that damages for which a Party may be liable to another Party under separate agreement will not be considered to be special, indirect, incidental, or consequential damages hereunder.

  • Consequential Damages Waiver NEITHER PARTY SHALL HAVE ANY LIABILITY ARISING OUT OF OR RELATED TO THIS AGREEMENT FOR ANY LOSS OF USE, LOST DATA, LOST PROFITS, FAILURE OF SECURITY MECHANISMS, INTERRUPTION OF BUSINESS, LOSS CAUSED BY THE INTERRUPTION, TERMINATION OR DELAYED OPERATION OF THE INTERNET, THIRD-PARTY TELECOMMUNICATION SERVICES OR THIRD-PARTY SECURITY FEATURES OR SYSTEMS, EXCEPT AS REQUIRED BY LAW. EXCEPT FOR CUSTOMER’S BREACH OF SECTION 1.4 (USE RESTRICTIONS) OR EITHER PARTY’S UNLAWFUL OR WILLFUL MISCONDUCT OR GROSS NEGLIGENCE, NEITHER PARTY SHALL BE LIABLE FOR ANY INDIRECT, SPECIAL, INCIDENTAL, EXEMPLARY, PUNITIVE, RELIANCE, OR CONSEQUENTIAL DAMAGES OF ANY KIND, EVEN IF INFORMED OF THE POSSIBILITY IN ADVANCE, SUFFERED BY ANY PARTY OR ANY PARTY CLAIMING ON BEHALF OF OR THROUGH THE OTHER PARTY, OR ANY OTHER THIRD PARTY RESULTING FROM OR ARISING OUT OF OR RELATED TO THIS AGREEMENT OR THE PERFORMANCE OR BREACH THEREOF.

Time is Money Join Law Insider Premium to draft better contracts faster.