CAFA Notice Pursuant to 28 U.S.C. § 1715, not later than ten (10) days after the Agreement is filed with the Court, the Settlement Administrator shall cause to be served upon the Attorneys General of each U.S. State in which Settlement Class members reside, the Attorney General of the United States, and other required government officials, notice of the proposed settlement as required by law, subject to Paragraph 5.1 below.
Notice of Delay 12.1. When anything delays or threatens to delay the timely performance of the Purchase Order, Supplier must immediately provide written notice to Buyer in writing of all relevant information, including but not limited to the reasons for the potential delay and Supplier’s short-term and long-term mitigation actions.
NOTICE OF DELAYS Except as otherwise provided under this Contract, when either party has knowledge that any actual or potential situation is delaying or threatens to delay the timely performance of this Contract, that party shall, within one (1) business day, give notice thereof, including all relevant information with respect thereto, to the other party.
Delivery Notice Notice of the Aircraft's Delivery Date, given by the Lessee as provided in Section 3.01 of the Participation Agreement and including any notice with respect to a postponed Delivery Date given by the Lessee pursuant to Section 3.05(c) of the Participation Agreement.
STOP WORK NOTICE The City may issue an immediate Stop Work Notice in the event the Contractor is observed performing in a manner that is in violation of Federal, State, or local guidelines, or in a manner that is determined by the City to be unsafe to either life or property. Upon notification, the Contractor will cease all work until notified by the City that the violation or unsafe condition has been corrected. The Contractor shall be liable for all costs incurred by the City as a result of the issuance of such Stop Work Notice.
Response to Notice Within ten business days of receiving the Claim Notice, the Respondent must notify the Claimant of its representative to negotiate the dispute.
Termination Warning Notice 5.B The Secretary of State may serve a Termination Warning Notice where he considers that:
Your Rights and Our Responsibilities After We Receive Your Written Notice We must acknowledge your letter within 30 days, unless we have corrected the error by then. Within 90 days, we must either correct the error or explain why we believe the statement was correct. After we receive your letter, we cannot try to collect any amount you question or report you as delinquent. We can continue to bill you for the amount you question, including FINANCE CHARGES, and we can apply any unpaid amount against your credit limit. You do not have to pay any questioned amount while we are investigating, but you are still obligated to pay the parts of your statement that are not in question. If we find that we made a mistake on your statement, you will not have to pay any FINANCE CHARGES related to any questioned amount. If we didn’t make a mistake, you may have to pay FINANCE CHARGES and you will have to make up any missed payments on the questioned amount. In either case, we will send you a statement of the amount you owe and the date that it is due. If you fail to pay the amount that we think you owe, we may report you as delinquent. However, if our explanation does not satisfy you and you write to us within 10 days telling us that you still refuse to pay, we must tell anyone we report you to that you have a question about your statement. And, we must tell you the name of anyone we reported you to. We must tell anyone we report you to that the matter has been settled between us when it finally is. If we don’t follow these rules, we can’t collect the first $50.00 of the questioned amount, even if your statement was correct.
Notice to the Holder Whenever the Conversion Price is adjusted pursuant to any provision of this Section 5, the Company shall deliver to each Holder within two (2) Business Days a notice setting forth the Conversion Price after such adjustment and setting forth a brief statement of the facts requiring such adjustment.
Method of Giving Notice Unless the Business Corporations Act or these Articles provides otherwise, a notice, statement, report or other record required or permitted by the Business Corporations Act or these Articles to be sent by or to a person may be sent by any one of the following methods: