Contractor’s Notice of Claim Sample Clauses

Contractor’s Notice of Claim. In order to provide Princeton University with the information necessary to investigate and evaluate the Contractor’s potential entitlement to any remedy for a Claim or potential Claim, and to provide Princeton University with the opportunity to take action to avoid or mitigate the effects of any events or circumstances that may be alleged by Contractor as any Claim or potential Claim, including avoiding or mitigating additional costs or delays if Contractor would otherwise be entitled to an increase in the Contract Price or an extension to the Contract Time, it is an express condition precedent to Contractor’s ability to pursue any Claim or potential Claim or any remedy whatsoever relating to the events or circumstances regarding such that Contractor must deliver a written notice to Princeton University, in full and timely compliance with the provisions of Clause J3(c) below, of any Claim or of any events or circumstances that give rise or may give rise to any Claim or right to Claim by the Contractor, including without limitation, the following:
Sample 1Sample 2Sample 3See All (12)
AutoNDA by SimpleDocs
Contractor’s Notice of Claim. The Contractor’s notice of claim shall set forth: (i) the reasons for which the Contractor believes additional compensation will or may be due or additional time should be granted; (ii) the nature of the costs involved;
Sample 1Sample 2Sample 3See All (9)

Related to Contractor’s Notice of Claim

  • Notice of Claims If the City or Contractor receives notice of any claim or circumstances which could give rise to an indemnified loss, the receiving Party shall give written notice to the other Party within 30 days. The notice must include the following:

  • Notice of Claim Promptly after receipt by an Investor Indemnitee or Company Indemnitee of notice of the commencement of any action or proceeding (including any governmental action or proceeding) involving an Indemnified Liability, such Investor Indemnitee or Company Indemnitee, as applicable, shall, if a claim for an Indemnified Liability in respect thereof is to be made against any indemnifying party under this Article V, deliver to the indemnifying party a written notice of the commencement thereof; but the failure to so notify the indemnifying party will not relieve it of liability under this Article V except to the extent the indemnifying party is prejudiced by such failure. The indemnifying party shall have the right to participate in, and, to the extent the indemnifying party so desires, jointly with any other indemnifying party similarly noticed, to assume control of the defense thereof with counsel mutually reasonably satisfactory to the indemnifying party and the Investor Indemnitee or Company Indemnitee, as the case may be; provided, however, that an Investor Indemnitee or Company Indemnitee shall have the right to retain its own counsel with the actual and reasonable third party fees and expenses of not more than one counsel for such Investor Indemnitee or Company Indemnitee to be paid by the indemnifying party, if, in the reasonable opinion of counsel retained by the indemnifying party, the representation by such counsel of the Investor Indemnitee or Company Indemnitee and the indemnifying party would be inappropriate due to actual or potential differing interests between such Investor Indemnitee or Company Indemnitee and any other party represented by such counsel in such proceeding. The Investor Indemnitee or Company Indemnitee shall cooperate fully with the indemnifying party in connection with any negotiation or defense of any such action or claim by the indemnifying party and shall furnish to the indemnifying party all information reasonably available to the Investor Indemnitee or Company Indemnitee which relates to such action or claim. The indemnifying party shall keep the Investor Indemnitee or Company Indemnitee reasonably apprised as to the status of the defense or any settlement negotiations with respect thereto. No indemnifying party shall be liable for any settlement of any action, claim or proceeding effected without its prior written consent, provided, however, that the indemnifying party shall not unreasonably withhold, delay or condition its consent. No indemnifying party shall, without the prior written consent of the Investor Indemnitee or Company Indemnitee, consent to entry of any judgment or enter into any settlement or other compromise which does not include as an unconditional term thereof the giving by the claimant or plaintiff to such Investor Indemnitee or Company Indemnitee of a release from all liability in respect to such claim or litigation. Following indemnification as provided for hereunder, the indemnifying party shall be subrogated to all rights of the Investor Indemnitee or Company Indemnitee with respect to all third parties, firms or corporations relating to the matter for which indemnification has been made. The indemnification required by this Article V shall be made by periodic payments of the amount thereof during the course of the investigation or defense, as and when bills are received and payment therefor is due.

  • Notice of Elections To make an election pursuant to this Section, the Borrower shall notify the Administrative Agent of such election by telephone by the time that a Borrowing Request would be required under Section 2.03 if the Borrower were requesting a Borrowing of the Type resulting from such election to be made on the effective date of such election. Each such telephonic Interest Election Request shall be irrevocable and shall be confirmed promptly by hand delivery or telecopy to the Administrative Agent of a written Interest Election Request in a form approved by the Administrative Agent and signed by the Borrower.

  • Notice of Separation When an employee’s resignation is presumed in accordance with Section 27.2 above, the Employer will separate the employee by sending a separation notice to the employee by certified mail to the last known address of the employee. Such notice will include information regarding eligibility for continuation of medical benefits.

Time is Money Join Law Insider Premium to draft better contracts faster.