CONTRACTOR NOTICE REGARDING LATE DELIVERY Sample Clauses

CONTRACTOR NOTICE REGARDING LATE DELIVERY a. Time is of the essence in the Purchase Order.
Sample 1Sample 2Sample 3See All (8)
AutoNDA by SimpleDocs
CONTRACTOR NOTICE REGARDING LATE DELIVERY. In the event that the contractor, for any reason, anticipates or encounters difficulty in complying with the contract delivery schedule or date, or in meeting any of the other requirements of the contract, they shall immediately notify the Administrative and Procuring Contracting Officers (ACO and PCO) in writing, providing all of the pertinent details. This data shall be informational only in character and its receipt by the Government shall not be construed as a waiver by the Government of (i) any delivery schedule or date, (ii) compliance with any other contract requirement by the contractor, or (iii) any other rights or remedies belonging to the Government under law or otherwise under this contract.
Sample 1Sample 2
CONTRACTOR NOTICE REGARDING LATE DELIVERY. In the event the Contractor anticipates or encounters difficulty in complying with the contract delivery schedule or date, he/she shall immediately notify, in writing, the Contracting Officer and the cognizant Contract Administration Services Office, if assigned. The notice shall give the pertinent details; however such notice shall not be construed as a waiver by the Government of any contract delivery schedule, or of any rights or remedies provided by law or under this contract. DELIVERY INFORMATION CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC / CAGE 0001 N/A N/A N/A N/A 0001AA POP 01-NOV-2022 TO 31-OCT-2023 N/A N/A FOB: Destination 0002 N/A N/A N/A N/A 0002AA POP 01-NOV-2022 TO 31-OCT-2023 N/A N/A FOB: Destination 0003 POP 01-NOV-2022 TO 31-OCT-2023 N/A N/A FOB: Destination 0004 N/A N/A N/A N/A 0004AA POP 01-NOV-2023 TO 31-OCT-2024 N/A N/A FOB: Destination 0005 N/A N/A N/A N/A 0005AA POP 01-NOV-2023 TO 31-OCT-2024 N/A N/A FOB: Destination 0006 POP 01-NOV-2023 TO 31-OCT-2024 N/A N/A FOB: Destination 0007 N/A N/A N/A N/A 0007AA POP 01-NOV-2024 TO 31-OCT-2025 N/A N/A FOB: Destination 0008 N/A N/A N/A N/A 0008AA POP 01-NOV-2024 TO 31-OCT-2025 N/A N/A FOB: Destination 0009 POP 01-NOV-2024 TO 31-OCT-2025 N/A N/A FOB: Destination 0010 N/A N/A N/A N/A 0010AA POP 01-NOV-2025 TO 31-OCT-2026 N/A N/A FOB: Destination 0011 N/A N/A N/A N/A 0011AA POP 01-NOV-2025 TO 31-OCT-2026 N/A N/A FOB: Destination 0012 POP 01-NOV-2025 TO 31-OCT-2026 N/A N/A FOB: Destination 0013 N/A N/A N/A N/A 0013AA POP 01-NOV-2026 TO 31-OCT-2027 N/A N/A FOB: Destination 0014 N/A N/A N/A N/A 0014AA POP 01-NOV-2026 TO 31-OCT-2027 N/A N/A FOB: Destination 0015 POP 01-NOV-2026 TO 31-OCT-2027 N/A N/A FOB: Destination CLAUSES INCORPORATED BY REFERENCE 52.242-15 Alt I Stop-Work Order (Aug 1989) - Alternate I APR 1984 CLAUSES INCORPORATED BY FULL TEXT F-247-H001 DELIVERY OF DATA (NAVSEA) (OCT 2018) All data to be furnished under this contract shall be delivered prepaid to the destination(s) and at the time(s) specified on the Contract Data Requirements List(s), DD Form 1423. (End of Text) Section G - Contract Administration Data FUNDING PROFILE Funding Profile It is estimated that these incremental funds will provide for the number of hours of labor stated below. The following details funding to date: CLIN CPFF Funds This Action Previous Funding Total Funded Amount Balance Unfunded Funded Labor Hours 0001 Base Total 0004 0005 Option 1 Total 0007 0008 Option 2 Total 0010 0011 Option 3 Total 0013 ...
Sample 1
CONTRACTOR NOTICE REGARDING LATE DELIVERY. In the event Seller for any reason anticipates or encounters difficulty in complying with this contract delivery schedule or date, or in meeting any of the other requirements of this contract, it shall immediately notify Buyer, in writing, giving pertinent details; provided, however, that this notice shall be informational only in character and that its receipt by Buyer shall not be construed as, or a basis for, waiver by the Buyer (i) of any delivery schedule or date, (ii) of compliance with any other contract requirement by the Seller or (iii) of any other rights or remedies provided to the Buyer by law or under this contract.
Sample 1
CONTRACTOR NOTICE REGARDING LATE DELIVERY. In the event the contractor anticipates or encounters difficulty in complying with the contract delivery schedule or date, he/she shall immediately notify the Contracting Officer in writing, via the cognizant Contract Administration Services Office, if assigned. The notice shall give the pertinent details; however such notice shall not be construed as a waiver by the Government of any contract delivery schedule, or of any rights or remedies provided by law or under this contract.
Sample 1
CONTRACTOR NOTICE REGARDING LATE DELIVERY. In the event the contractor anticipates or encounters difficulty in complying with the contract delivery schedule or date, the contractor shall immediately notify, in writing, the Contracting Officer and the cognizant Contract Administration Services Office, if assigned. The notice shall give the pertinent details; however, such notice shall not be construed as a waiver by the Government of any contract delivery schedule, or of any rights or remedies provided by law or under this contract. PARTIAL DELIVERIES Partial deliveries will not be accepted without specific approval from the Contracting Officer. DELIVERY INFORMATION CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC / CAGE 0001 40 wks. ADC 1 NAVAL SURFACE WARFARE CENTER RECEIVING OFFICER PORT HUENEME DIVISON, BLDG 435 0000 XXXXXXX XXX XXXX XXXXXXX XX 00000-4307 805-228-6200 FOB: Destination N63394 0002 40 wks. ADC 1 (SAME AS PREVIOUS LOCATION) FOB: Destination N63394 0003 N/A N/A N/A N/A 0004 40 wks. AOE 7 NAVAL SURFACE WARFARE CENTER RECEIVING OFFICER PORT HUENEME DIVISON, BLDG 435 0000 XXXXXXX XXX XXXX XXXXXXX XX 00000-4307 805-228-6200 FOB: Destination N63394 0005 40 wks. AOE 3 (SAME AS PREVIOUS LOCATION) FOB: Destination N63394 1001 40 wks. AOE 8 (SAME AS PREVIOUS LOCATION) FOB: Destination N63394 1002 40 wks. AOE 4 (SAME AS PREVIOUS LOCATION) FOB: Destination N63394 2001 40 wks. AOE 8 (SAME AS PREVIOUS LOCATION) FOB: Destination N63394 2002 40 wks. AOE 4 (SAME AS PREVIOUS LOCATION) FOB: Destination N63394 3001 40 wks. AOE 8 (SAME AS PREVIOUS LOCATION) FOB: Destination N63394 3002 40 wks. AOE 4 (SAME AS PREVIOUS LOCATION) FOB: Destination N63394 4001 40 wks. AOE 8 (SAME AS PREVIOUS LOCATION) FOB: Destination N63394 4002 40 wks. AOE 4 (SAME AS PREVIOUS LOCATION) FOB: Destination N63394 CLAUSES INCORPORATED BY REFERENCE 52.242-15 Stop-Work Order AUG 1989 52.242-17 Government Delay Of Work APR 1984 52.247-34 F.O.B. Destination NOV 1991 52.247-48 F.O.B. Destination--Evidence Of Shipment FEB 1999 252.232-7003 Electronic Submission of Payment Requests and Receiving Reports JUN 2012 CLAUSES INCORPORATED BY FULL TEXT
Sample 1

Related to CONTRACTOR NOTICE REGARDING LATE DELIVERY

  • Service Delivery Grantee shall:

  • SERVICE DELIVERABLES You will receive service on the Covered Product as described below: Carry-In: Unless otherwise provided in this Agreement, the Covered Product must be shipped or delivered and retrieved by You at Our authorized service center during normal business hours. In-Home/On-Site: Service will be performed in Your home or on-site as indicated on the Declarations Page of this Agreement, or on Your sales receipt or invoice provided You have fulfilled the following requirements: (1) provide Our authorized technician with accessibility to the Covered Product; (2) provide a non-threatening and safe environment for Our authorized technician; and (3) an adult over the age of 18 must be present for the period of time Our authorized technician is scheduled to provide service and while Our authorized technician is on Your property servicing the Covered Product. In-Home Service will be provided by Our authorized service provider during regular business hours, local time, Monday through Friday, except holidays. Our authorized service center may opt to remove the Covered Product to perform service in-shop. The Covered Product will be returned upon completion. Additional time and mileage charges for in-home repairs outside of twenty-five (25) contiguous land miles or the normal service radius of Our authorized service center are not covered by this Agreement, and are Your responsibility.

  • Project Delivery Order Procedures The TIPS Member having approved and signed an interlocal agreement, or other TIPS Membership document, may make a request of the awarded Vendor under this Agreement when the TIPS Member desires goods or services awarded to the Vendor. Notification may occur via phone, the web, courier, email, fax, or in person. Upon notification of a pending request, the awarded Vendor shall acknowledge the TIPS Member’s request as soon as possible, but must make contact with the TIPS Member within two working days. Status of TIPS Members as Related to This Agreement TIPS Members stand in the place of TIPS as related to this agreement and have the same access to the proposal information and all related documents. TIPS Members have all the same rights under the awarded Agreement as TIPS.

  • Project Delivery Contractor shall construct the Project in accordance with the Contract Documents, and Contractor shall deliver the Project completed in accordance with the Contract Documents, substantially free from defects, and within the Contract Time.

  • Public Posting of Approved Users’ Research Use Statement The PI agrees that information about themselves and the approved research use will be posted publicly on the dbGaP website. The information includes the PI’s name and Requester, project name, Research Use Statement, and a Non-Technical Summary of the Research Use Statement. In addition, and if applicable, this information may include the Cloud Computing Use Statement and name of the CSP or PCS. Citations of publications resulting from the use of controlled-access datasets obtained through this DAR may also be posted on the dbGaP website.

  • Delivery Notice Notice of the Aircraft's Delivery Date, given by the Lessee as provided in Section 3.01 of the Participation Agreement and including any notice with respect to a postponed Delivery Date given by the Lessee pursuant to Section 3.05(c) of the Participation Agreement.

  • Transmission Delivery Service Implications Network Resource Interconnection Service allows Interconnection Customer's Large Generating Facility to be designated by any Network Customer under the Tariff on Transmission Provider's Transmission System as a Network Resource, up to the Large Generating Facility's full output, on the same basis as existing Network Resources interconnected to Transmission Provider's Transmission System, and to be studied as a Network Resource on the assumption that such a designation will occur. Although Network Resource Interconnection Service does not convey a reservation of transmission service, any Network Customer under the Tariff can utilize its network service under the Tariff to obtain delivery of energy from the interconnected Interconnection Customer's Large Generating Facility in the same manner as it accesses Network Resources. A Large Generating Facility receiving Network Resource Interconnection Service may also be used to provide Ancillary Services after technical studies and/or periodic analyses are performed with respect to the Large Generating Facility's ability to provide any applicable Ancillary Services, provided that such studies and analyses have been or would be required in connection with the provision of such Ancillary Services by any existing Network Resource. However, if an Interconnection Customer's Large Generating Facility has not been designated as a Network Resource by any load, it cannot be required to provide Ancillary Services except to the extent such requirements extend to all generating facilities that are similarly situated. The provision of Network Integration Transmission Service or firm Point-to-Point Transmission Service may require additional studies and the construction of additional upgrades. Because such studies and upgrades would be associated with a request for delivery service under the Tariff, cost responsibility for the studies and upgrades would be in accordance with FERC's policy for pricing transmission delivery services. Network Resource Interconnection Service does not necessarily provide Interconnection Customer with the capability to physically deliver the output of its Large Generating Facility to any particular load on Transmission Provider's Transmission System without incurring congestion costs. In the event of transmission constraints on Transmission Provider's Transmission System, Interconnection Customer's Large Generating Facility shall be subject to the applicable congestion management procedures in Transmission Provider's Transmission System in the same manner as Network Resources. There is no requirement either at the time of study or interconnection, or at any point in the future, that Interconnection Customer's Large Generating Facility be designated as a Network Resource by a Network Service Customer under the Tariff or that Interconnection Customer identify a specific buyer (or sink). To the extent a Network Customer does designate the Large Generating Facility as a Network Resource, it must do so pursuant to Transmission Provider's Tariff. Once an Interconnection Customer satisfies the requirements for obtaining Network Resource Interconnection Service, any future transmission service request for delivery from the Large Generating Facility within Transmission Provider's Transmission System of any amount of capacity and/or energy, up to the amount initially studied, will not require that any additional studies be performed or that any further upgrades associated with such Large Generating Facility be undertaken, regardless of whether or not such Large Generating Facility is ever designated by a Network Customer as a Network Resource and regardless of changes in ownership of the Large Generating Facility. However, the reduction or elimination of congestion or redispatch costs may require additional studies and the construction of additional upgrades. To the extent Interconnection Customer enters into an arrangement for long term transmission service for deliveries from the Large Generating Facility outside Transmission Provider's Transmission System, such request may require additional studies and upgrades in order for Transmission Provider to grant such request.

  • Project Deliverables The Contractor shall provide each of the following deliverables in writing to the City for review and approval to achieve the project objectives.

  • SERVICE MONITORING, ANALYSES AND ORACLE SOFTWARE 11.1 We continuously monitor the Services to facilitate Oracle’s operation of the Services; to help resolve Your service requests; to detect and address threats to the functionality, security, integrity, and availability of the Services as well as any content, data, or applications in the Services; and to detect and address illegal acts or violations of the Acceptable Use Policy. Oracle monitoring tools do not collect or store any of Your Content residing in the Services, except as needed for such purposes. Oracle does not monitor, and does not address issues with, non-Oracle software provided by You or any of Your Users that is stored in, or run on or through, the Services. Information collected by Oracle monitoring tools (excluding Your Content) may also be used to assist in managing Oracle’s product and service portfolio, to help Oracle address deficiencies in its product and service offerings, and for license management purposes.

  • Acceptance of Deliverables The State’s Project Manager shall be responsible for the sign-off acceptance of all Deliverables required and performed/submitted pursuant to this Agreement. Upon successful completion of a Deliverable, Contractor shall provide the State’s Project Manager with a completed Acceptance and Signoff Form (Exhibit E). The State’s Project Manager will apply the standards established in Exhibit D and the acceptance criteria set forth in subparagraph B of this article, as appropriate, to determine the acceptability of the Deliverable provided by Contractor. If the State’s Project Manager rejects the Deliverable, the parties agree to any dispute(s) resulting from such rejection(s) will be resolved as set forth in this article. Acceptance Criteria for Deliverables (“Criteria”) provided by Contractor pursuant to this Agreement include: Timeliness: The Work was provided on time; according to schedule; Completeness: The Deliverable contained all of the, Data, Materials, and features required by the Agreement; and Technical accuracy: The Deliverable complied with the standards of this Agreement, or, if this Agreement lacks a standard for provision of the Work, the currently generally accepted industry standard. Contractor shall provide the Deliverable to the State, in accordance with direction from the Project Manager and as provided for in Exhibit D. The State shall accept the Deliverable, provided that Contractor has delivered the Deliverable in accordance with the Criteria. The State’s Project Manager shall assign the Acceptance and Signoff Form to notify Contractor of the Deliverable’s acceptability. If the State rejects the Deliverable provided, the State’s Project Manager shall submit to Contractor’s Project Manager a written rejection describing in detail the failure of the Deliverable as measured against the Criteria. If the State rejects the Deliverable, then Contractor shall have a period of ten (10) Business Days from receipt of the Notice of rejection to correct the stated failure(s) to conform to the Criteria.

Time is Money Join Law Insider Premium to draft better contracts faster.