Waiver of Claims. 9.1. The CONTRACTOR's acceptance of final payment shall constitute a full waiver of any and all claims, except for insurance company subrogation claims, by it against the CITY arising out of this Agreement or otherwise related to the Project, except those previously made in writing and identified by the CONTRACTOR as unsettled at the time of the final payment. Neither the acceptance of the CONTRACTOR's services nor payment by the CITY shall be deemed to be a waiver of any of the CITY's rights against the CONTRACTOR.
Waiver of Claims. In the event City terminates the Agreement in accordance with the terms of this Section, Consultant hereby expressly waives any and all claims for damages or compensation as a result of such termination except as expressly provided in this Section 6.
Waiver of Claims. Except as otherwise provided in this Agreement, EACH ASSIGNOR HEREBY WAIVES, TO THE EXTENT PERMITTED BY APPLICABLE LAW, NOTICE AND JUDICIAL HEARING IN CONNECTION WITH THE COLLATERAL AGENT’S TAKING POSSESSION OR THE COLLATERAL AGENT’S DISPOSITION OF ANY OF THE COLLATERAL, INCLUDING, WITHOUT LIMITATION, ANY AND ALL PRIOR NOTICE AND HEARING FOR ANY PREJUDGMENT REMEDY OR REMEDIES, and each Assignor hereby further waives, to the extent permitted by law:
Waiver of Claims. Borrower and Guarantors acknowledge, represent and agree that Borrower and Guarantors as of the date hereof have no defenses, setoffs, claims, counterclaims or causes of action of any kind or nature whatsoever with respect to the Loan Documents, the administration or funding of the Loans or with respect to any acts or omissions of Agent or any of the Lenders, or any past or present officers, agents or employees of Agent or any of the Lenders, and each of Borrower and Guarantors does hereby expressly waive, release and relinquish any and all such defenses, setoffs, claims, counterclaims and causes of action, if any.
Waiver of Claims. To the maximum extent permitted by law, each Non-Lender Secured Party waives any claim it might have against the Collateral Agent or the Lenders with respect to, or arising out of, any action or failure to act or any error of judgment, negligence, or mistake or oversight whatsoever on the part of the Collateral Agent or the Lenders or their respective directors, officers, employees or agents with respect to any exercise of rights or remedies under the Loan Documents or any transaction relating to the Collateral (including, without limitation, any such exercise described in Subsection 8.1(b)), except for any such action or failure to act that constitutes willful misconduct or gross negligence of such Person. To the maximum extent permitted by applicable law, none of the Collateral Agent or any Lender or any of their respective directors, officers, employees or agents shall be liable for failure to demand, collect or realize upon any of the Collateral or for any delay in doing so or shall be under any obligation to sell or otherwise dispose of any Collateral upon the request of Holdings, any Subsidiary of Holdings, any Non-Lender Secured Party or any other Person or to take any other action or forbear from doing so whatsoever with regard to the Collateral or any part thereof, except for any such action or failure to act that constitutes willful misconduct or gross negligence of such Person.
Waiver of Claims. CONTRACTOR’s acceptance of final payment shall constitute a full waiver of any and all claims by the CONTRACTOR against the COUNTY arising out of the contract or otherwise related to the Project/Service, except those previously made in writing and identified by CONTRACTOR as unsettled at the time the final estimate is prepared. Neither the acceptance of the work nor payment by the COUNTY shall be deemed a waiver of the COUNTY’s rights to enforce any continuing obligations of CONTRACTOR or to the recovery of damages for defective work not discovered by the COUNTY at the time of final inspection.
Waiver of Claims. Except as otherwise provided in this Agreement, EACH ASSIGNOR HEREBY WAIVES, TO THE EXTENT PERMITTED BY APPLICABLE LAW, NOTICE AND JUDICIAL HEARING IN CONNECTION WITH THE COLLATERAL AGENT'S TAKING POSSESSION OR THE COLLATERAL AGENT'S DISPOSITION OF ANY OF THE COLLATERAL, INCLUDING, WITHOUT LIMITATION, ANY AND ALL PRIOR NOTICE AND HEARING FOR ANY PREJUDGMENT REMEDY OR REMEDIES AND ANY SUCH RIGHT WHICH SUCH ASSIGNOR WOULD OTHERWISE HAVE UNDER THE CONSTITUTION OR ANY STATUTE OF THE UNITED STATES OR OF ANY STATE, and such Assignor hereby further waives, to the extent permitted by law:
Waiver of Claims. Unless a shorter time is specified elsewhere in this Contract, on or before making his final request for payment, Contractor shall submit to County, in writing, all claims for compensation under or arising out of this Contract; the acceptance by Contractor of the final payment shall constitute a waiver of all claims against County under or arising out of this Contract except those previously made in writing and identified by Contractor as unsettled at the time of his final request for payment.
Waiver of Claims. 15 7.4. Application of Proceeds..................................... 15 7.5.
Waiver of Claims. Each of the Borrower and each Guarantor acknowledges, represents and agrees that it has no defenses, setoffs, claims, counterclaims or causes of action of any kind or nature whatsoever with respect to the Loan Documents, the administration or funding of the Loan or with respect to any acts or omissions of Agent or any Lender, or any past or present officers, agents or employees of Agent or any Lender, and the Borrower does hereby expressly waive, release and relinquish any and all such defenses, setoffs, claims, counterclaims and causes of action, if any.
