Acceptance of the Work. 19.1 The Contractor shall correct any Work that fails to conform to the requirements of the Contract Documents where such failure to conform appears during the progress of the Work, and shall remedy any defects due to faulty permitting, design, materials, equipment or workmanship which appear within a period of one year from the Date of Final Settlement of the Contract or within such longer period of time as may be prescribed by law or by the terms of any applicable special guarantee required by the Contract Documents. The provisions of this Article apply to Work done by Subcontractors as well as to Work done by direct employees of the Contractor, and are in addition to any other remedies or warranties provided by law.
Acceptance of the Work. The AOC Project Manager shall be responsible for the sign-off acceptance of all the Work required and submitted pursuant to this Agreement. Prior to approval of the Work and prior to approval for payment, the Project Manager will apply the acceptance criteria set forth in subparagraph B of this provision, as appropriate, to determine the acceptability of the Work provided by the Contractor. Unsatisfactory ratings will be resolved as set forth in this provision. Acceptance Criteria for Work (“Criteria”) provided by the Contractor pursuant to this Agreement: Timeliness: The Work was delivered on time; Completeness: The Work contained the Data, Materials (including number of copies), and features required in the Contract Documents; and Technical accuracy: The Work is accurate as measured against commonly accepted standard (for instance, a statistical formula, an industry standard, regulatory code compliance, or de facto marketplace standard). The Contractor shall provide the Work to the State, in accordance with direction from the Project Manager and as provided for in Exhibit D. The State shall accept the Work, provided the Contractor has delivered the Work in accordance with the Criteria. The State’s Project Manager shall issue a written communication to notify the Contractor of the Work’s acceptability. If the State rejects the Work provided, the State’s Project Manager shall submit to the Contractor a written rejection describing in detail the failure of the Work as measured against the Criteria. If the State rejects the Work, then the Contractor shall have a period of ten (10) business days from receipt of the Notice of rejection to correct the stated failure(s) to conform to the Criteria. If agreement cannot be reached between the State’s Project Manager and the Contractor on the Work’s acceptability, a principal of the Contractor and the Administrative Director of the AOC, or its designee, shall meet to discuss the problem. If agreement cannot be reached, in the reasonable judgment of the Administrative Director of the AOC, or its designee, and/or the Contractor fails to cure such deficiencies that are perceived in the Work to the reasonable satisfaction of the Administrative Director, or its designee, in the reasonable time established by the Administrative Director, the State may reject the Work and will notify the Contractor in writing of such action and the reason(s) for so doing. Upon rejection of the Work, the State may terminate this Agreement p...
Acceptance of the Work. Progress Schedule, or update and/or revision thereto does not indicate any approval of Contractor’s proposed sequences and duration.
Acceptance of the Work. All of the Contractor’s work and labor shall be subject to the inspection and approval of the City. If any materials or labor are rejected by the City as defective or unsuitable, then the materials shall be removed and replaced with other approved materials and the labor shall be done to the satisfaction and approval of the City at the Contractor’s sole cost and expense. Contractor shall replace at Contractor’s expense any loss or damage to the Work, however caused, which occurs during the construction thereof or prior to the final delivery to and acceptance of the Work by the City. Any payment made to Contractor, shall not be construed as operating to relieve Contractor from responsibility for the construction and delivery of Work. Acceptance of the completed Work shall be evidenced only by a Certificate of Final Completion issued by the City, which shall state the date on which the City accepts the completed Work (the “Final Completion Date”).
Acceptance of the Work. 19.1 No act of, or failure to act by, the Owner or the OWNER'S REPRESENTATIVE during the course of the Work, nor any extension of time for the completion of the Work, shall be regarded as an acceptance of such Work or any part thereof, or of materials used therein, either wholly or in part. Acceptance shall be evidenced only by the Final Payment by the Owner to Contractor. Before any final certificate shall issue, Contractor shall execute an affidavit on the certificate that it accepts the same in full payment and settlement of all claims on account of Work done and materials furnished under this Contract, and that all claims for materials provided or labor performed have been paid or set aside in full. No waiver of any breach of this Contract by the Owner or anyone acting on Owner's behalf shall be held as a waiver of any other subsequent breach thereof.
Acceptance of the Work. A. The Project Manager shall be responsible for the sign-off acceptance of all the Work required and submitted pursuant to this Agreement. Prior to approval of the Work and prior to approval for payment, the Project Manager will apply the acceptance criteria set forth in subparagraph B of this provision, as appropriate, to determine the acceptability of the Work provided by the Contractor. Unsatisfactory ratings will be resolved as set forth in this provision.
Acceptance of the Work. 22.1 UNICEF shall have a reasonable time after completion of the Works or part of the Works, and before issuance of the Certificate of Substantial Completion, to inspect the Works and to reject and refuse acceptance of Works not conforming to the Contract. Inspection prior to completion of Works does not relieve the Contractor from any of its obligations under the Contract.
Acceptance of the Work. A. The AOC Project Manager shall be responsible for the sign-off Acceptance of all the Work required and submitted pursuant to this Agreement. Prior to approval of the Work and prior to approval for payment, the AOC Project Manager will apply the Acceptance Criteria set forth in subparagraph B of this provision, as appropriate, to determine the acceptability of the Work provided by the Contractor. Unsatisfactory ratings will be resolved as set forth in this provision.
Acceptance of the Work. The Contract and the Vendor’s duty of performance shall not be considered complete until the work has been finally accepted by the Xxxxxx County Land Bank and the Vendor has furnished the following:
Acceptance of the Work. Upon receipt of notice by Xxxxxxxxx that the Work is ready for final inspection and acceptance, Customer will make such final inspection and issue acceptance within three (3) business days. Acceptance will be in a form provided by Xxxxxxxxx, stating that to the best of Customer’s knowledge, information and belief, and on the basis of Customer’s on-site visits and inspections, the Work has been fully completed in accordance with the terms and conditions of this Agreement. If Customer finds the Work unacceptable due to non-compliance with a material element of this Agreement, which non-compliance is due solely to the fault of Honeywell, Customer will notify Honeywell in writing within the three (3) business days setting forth the specific reasons for non-acceptance. Customer agrees that failure to inspect and/or failure to issue proper notice of non-acceptance within three (3) business days constitutes final acceptance of the Work under this Agreement. Customer further agrees that partial or beneficial use of the Work by Customer or Owner prior to final inspection and acceptance will constitute acceptance of the Work under this Agreement. To the fullest extent permitted by law, Customer indemnifies and holds harmless Honeywell and its agents and employees from and against any and all claims, damages, losses and expenses, including but not limited to attorneys’ fees, that in any way result from or arise under breach of the representations in this Section 21. This indemnification survives termination of this Agreement for whatever reason. Nothing in this Section 21 may be construed to require that Customer indemnify and hold harmless Honeywell from claims and costs resulting from Xxxxxxxxx’s negligent actions or willful misconduct.
