Railroad Improvements definition

Railroad Improvements means a railroad extension running from the CSX branch line (west of the Property and intersecting Airport Road), in an easterly direction along the south side of Airport Road, crossing Wilkinson Street, and ending at the eastern edge of the right of way of Wilkinson Street, as substantially depicted on the Site Plan.
Sample 1Sample 2

Examples of Railroad Improvements in a sentence

  • The Mississippi Rail Grant Program (RAIL), as authorized and codified in the Mississippi Railroad Improvements Fund -- Miss.

  • Plaintiffs’ counsel also shall be permitted to interview the Audit Committee’s independent counsel on terms agreed to by the parties, including those set forth in a February 28, 2011 email from Xxxx Xxxxxxxxxx to Xxxxxxx Xxxxxx, and at a location, agreeable to Plaintiffs’ counsel, Defendants’ counsel and the Audit Committee’s independent counsel.

  • Following the execution by the City of the construction contracts for the First and Xxxxx Railroad Improvements, the Owner irrevocably waives its right to a permit fee refund pursuant Longmont Municipal Code 16.04.085.

  • Medical product manufac-pany may receive technical assistance and program support from a participating invest- ment company on a voluntary basis and without penalty for non-participation.‘‘(h) LOSS LIMITING FUND.—‘‘(1) IN GENERAL.—There is established in the Treasury a fund for making commit-SA 1754.

  • The Company shall be solely responsible for the cost of the design, construction, and completion of the Company Railroad Improvements.

  • The Sellers estimate that the costs of the Railroad Improvements are approximately $1.116 million, as set forth on Exhibit C.

  • PROJECT DEVELOPMENTBUREAU OF LOCAL ROADS AND STREETS MANUAL Chapter 22PROJECT DEVELOPMENT - Federal Funds Table of Contents Section Page 22-1 COORDINATION 22-1-122-1.01 Airports/Railroads/Utilities 22-1-122-1.01(a) Airport Coordination 22-1-122-1.01(b) Railroad Coordination 22-1-122-1.01(c) Procedure for Joint State-LPA Railroad Improvements .

  • The Owner shall pay the City the $900,000 upon receipt of one or more building permits for the 150 Main Improvements and prior to the City executing a contract with BNSF Railway or any private contractors performing work for the City for the First and Xxxxx Railroad Improvements.

  • Reduced investing costs going forward should support investment returns.

  • Notwithstanding the foregoing, to the extent that design, substantial completion and/or final completion of the Railroad Improvements is delayed due to the actions or inactions of CSX (“CSX Delays”) and the Sellers have taken all reasonable actions to mitigate such CSX Delays, the applicable completion date shall be extended by the number of days equal to the duration of the CSX Delays.

Related to Railroad Improvements

  • Leasehold Improvements means all buildings, structures, improvements and fixtures located on any Leased Real Property which are owned by Company or any Company Subsidiary, regardless of whether title to such buildings, structures, improvements or fixtures are subject to reversion to the landlord or other third party upon the expiration or termination of the lease for such Leased Real Property.

  • Infrastructure Improvements means a street, road, sidewalk, parking facility, pedestrian mall, alley, bridge, sewer, sewage treatment plant, property designed to reduce, eliminate, or prevent the spread of identified soil or groundwater contamination, drainage system, waterway, waterline, water storage facility, rail line, utility line or pipeline, transit-oriented development, transit-oriented property, or other similar or related structure or improvement, together with necessary easements for the structure or improvement, owned or used by a public agency or functionally connected to similar or supporting property owned or used by a public agency, or designed and dedicated to use by, for the benefit of, or for the protection of the health, welfare, or safety of the public generally, whether or not used by a single business entity, provided that any road, street, or bridge shall be continuously open to public access and that other property shall be located in public easements or rights-of-way and sized to accommodate reasonably foreseeable development of eligible property in adjoining areas. Infrastructure improvements also include 1 or more of the following whether publicly or privately owned or operated or located on public or private property:

  • Site Improvements means any construction work on, or improvement to, streets, roads, parking facilities, sidewalks, drainage structures and utilities.

  • Improvements shall have the meaning set forth in the granting clause of the Mortgage.

  • Substitute Improvements means the substitute or additional improvements of the Issuer described in Article V hereof.

  • Project Improvements means site improvements and facilities that are:

  • Private Improvements means the improvements to be constructed on the Property that are not Public Improvements.

  • Leased Improvements shall have the meaning given such term in Section 2.1(b).

  • Buildings means any and all buildings, structures, garages, utility sheds, workrooms, air conditioning towers, open parking areas and other improvements, and any and all additions, alterations, betterments or appurtenances thereto, now or at any time hereafter situated, placed or constructed upon the Land or any part thereof.

  • Tenant Improvements Defined in Exhibit B, if any.

  • Home improvement means the remodeling, altering,

  • Infrastructure improvement means permanent infrastructure that is essential for the public health and safety or that:

  • Building Project means the aggregate combined parcel of land on a portion of which are the improvements of which the Premises form a part, with all the improvements thereon, said improvements being a part of the block and lot for tax purposes which are applicable to the aforesaid land.

  • Common Area means all areas and facilities within the Project that are not designated by Landlord for the exclusive use of Tenant or any other lessee or other occupant of the Project, including the parking areas, access and perimeter roads, pedestrian sidewalks, landscaped areas, trash enclosures, recreation areas and the like.

  • Capital Improvements mean the purchase, renovation, rehabilitation, or construction of permanent land, buildings, structures, equipment and furnishings used directly for or in the Project, and any goods or services for the Project that are purchased and capitalized under GAAP, including any organizational costs and research and development costs incurred in Illinois. Capitalized lease costs for land, buildings, structures or equipment shall be included in “Capital Improvements” only if the lease term, including any extensions or options to extend, equals or exceeds the term of this Agreement, and provided that such lease costs are valued at their present value using the corporate interest rate prevailing at the time the Company filed its Application with the Department.

  • Building Common Areas means with respect to the Tower, the areas, facilities and amenities specified in Schedule [E] which are to be used and enjoyed in common with all the other Apartment Acquirers of the Units in the Building; and

  • Project means the goods or Services described in the Signature Document or a Work Order of this Contract.

  • Project Site(s) means the place(s) specified in the SCC for the supply and installation of the System.

  • Common Areas and Facilities means collectively the Development Common Areas and Facilities and the Residential Common Areas and Facilities and all those parts and such of the facilities of the Development designated as common areas and facilities in any Sub-Deed;

  • Project site, where applicable, means the place indicated in bidding documents.

  • mixed-use building means a building or structure containing a residential and non- residential use other than a home occupation;

  • Base Building shall include the structural portions of the Building, the public restrooms and the Building mechanical, electrical and plumbing systems and equipment located in the internal core of the Building on the floor or floors on which the Premises are located. Tenant shall promptly provide Landlord with copies of any notices it receives regarding an alleged violation of Law. Tenant shall comply with the rules and regulations of the Building attached as Exhibit E and such other reasonable rules and regulations adopted by Landlord from time to time, including rules and regulations for the performance of Alterations (defined in Section 9).

  • Non-Public Works and Improvements means all competitively solicited procurement of Supplies and/or Services by the City not solicited as Public Works.

  • Building means any structure used or intended for supporting or sheltering any use or occupancy.

  • drainage work means any construction or reconstruction of or any alteration or addition to, or any work done in connection with a drainage installation but shall not include any work undertaken solely for purposes of repair or maintenance;

  • Common Areas is defined as all areas and facilities outside the Premises and within the exterior boundary line of the Project and interior utility raceways and installations within the Unit that are provided and designated by the Lessor from time to time for the general non-exclusive use of Lessor, Lessee and other tenants of the Project and their respective employees, suppliers, shippers, customers, contractors and invitees, including parking areas, loading and unloading areas, trash areas, roadways, walkways, driveways and landscaped areas.