Prior Occupancy definition

Prior Occupancy means Owner’s use of all or parts of the Project before Substantial Completion, as more fully set forth in Section 6.08 A.
Sample 1Sample 2Sample 3
Prior Occupancy means Owner's use of all or parts of the Project before Substantial Completion.
Sample 1Sample 2Sample 3
Prior Occupancy means Owner’s use of all or parts of the Project before Substantial Completion.
Sample 1Sample 2Sample 3

Examples of Prior Occupancy in a sentence

  • Notwithstanding the above, Owner shall be responsible for loss of or damage to the Work resulting from Prior Occupancy.

  • Owner may, upon written notice thereof to Design-Builder, take possession of or use any completed or partially completed portion of the Work ("Prior Occupancy") at any time prior to Substantial Completion.

  • In the event that the Chargers are not willing to approve such Revised Plans, then the Chargers shall have the right to terminate this Agreement, in which event the Prior Occupancy Agreement shall be reinstated and be in full force and effect.

  • Unless otherwise agreed in writing, Prior Occupancy shall not: be deemed an acceptance of any portion of the Work; accelerate the time for any payment to Contractor; prejudice any rights of Owner provided by any insurance, bond, guaranty, or the Contract Documents; relieve Contractor of the risk of loss or any of the obligations established by the Contract Documents; establish a date for termination or partial termination of the assessment of liquidated damages; or constitute a waiver of claims.

  • Notwithstanding the foregoing, in the event that the Chargers do not approve any Revised Plans in accordance with Section 3(a) above, then this Agreement shall be considered to be null and void and the Prior Occupancy Agreement shall continue to govern the relationship between the parties.

  • Chargers under the "Prior Occupancy Agreement", which is located on the B-2 Level of the "Stadium Premises" across from Elevator 3 and indicated on Exhibit E.

  • Except as otherwise provided in Sections 3(c) and 8(b)(i) hereof, this Agreement supersedes and replaces in its entirety the Prior Occupancy Agreement, with the exception of the Scoreboard Supplement.

  • Unless otherwise agreed in writing, Prior Occupancy shall not: be deemed an acceptance of any portion of the Work; accelerate the time for any payment to the CM/GC; prejudice any rights of Owner provided by any insurance, bond, guaranty, or the Contract Documents; relieve the CM/GC of the risk of loss or any of the obligations established by the Contract Documents; establish a date for termination or partial termination of the assessment of liquidated damages; or constitute a waiver of claims.

  • Notwithstanding anything in the preceding paragraph, Owner shall be responsible for loss of or damage to the Work resulting from Prior Occupancy.

  • Duty to repair and warranties: Notwithstanding anything in the preceding paragraph, Owner shall be responsible for loss of or damage to the Work resulting from Prior Occupancy.


More Definitions of Prior Occupancy

Prior Occupancy means Owner’s use of all or parts of the Project before Substantial Completion, as more fully set forth in Part 6.7A.
Sample 1Sample 2Sample 3
Prior Occupancy means Ecology or property owner use of all or parts of the Project before Substantial Completion, as more fully set forth in Section 6.08A.
Sample 1
Prior Occupancy. Tenant shall not occupy the Leased Premises prior to Lease Commencement Date except with the express prior written consent of Landlord. If with Landlord's consent Tenant occupies the Leased Premises, Tenant shall pay Landlord for the period from the first day of such occupancy rent in the amount specified in Article 1.1 to be payable on the first day of such occupancy and thereafter on the first day of every calendar month until the first day of the Lease Term. A prorated monthly installment shall be paid for the fraction of the month if Tenant's occupancy of the Leased Premises commences on any day other than the first day of the month. If Tenant shall occupy the Leased Premises prior to Lease Commencement Date, all covenants and conditions of this Lease shall be binding on the parties commencing at such prior occupancy.
Sample 1
Prior Occupancy. Tenant shall not occupy any portion of the Leased Premises prior to Lease Commencement Date except with the express prior written consent of Landlord. If with Landlord's consent, Tenant occupies the Leased Premises prior to the Lease Commencement Date, Tenant shall pay Landlord Base Rent in the amounts specified in Paragraph 1.1 and Tenant's Pro Rata Share of Operating Costs, as defined in Paragraph 3.3, from the first day of such occupancy. These amounts will be payable on the first day of such occupancy and thereafter on the first day of every calendar month until the first day of the Lease Term. A prorated monthly installment shall be paid for the fraction of the month if Tenant's occupancy of the Leased Premises commences on any day other than the first day of the month. If Tenant shall occupy the Leased Premises prior to Lease Commencement Date, all covenants and conditions of this Lease shall be binding on Tenant commencing at such prior occupancy.
Sample 1

Related to Prior Occupancy

  • Transient occupancy means occupancy in transient lodging that has all of the following

  • Ready for Occupancy means the date upon which (i) the Leased Premises are available for Tenant's occupancy in a broom clean condition and (ii) the improvements, if any, to be made to the Leased Premises by Landlord as a condition to Tenant's obligation to accept possession of the Leased Premises have been substantially completed and the appropriate governmental building department (i.e., the City building department, if the Property is located within a City, or otherwise the County building department) shall have approved the construction of such improvements as substantially complete or is willing to so approve the construction of the improvements as substantially complete subject only to compliance with specified conditions which are the responsibility of Tenant to satisfy or is willing to allow Tenant to occupy subject to its receiving assurances that specified work will be completed.

  • Single Room Occupancy or “SRO” means housing consisting of single room dwelling units that is the primary residence of its occupant or occupants. An SRO does not include facilities for students.

  • Owner-occupied means property that is the principal

  • Child-occupied facility means a building or portion of a building constructed prior to 1978, visited regularly by the same child, age six years or younger on at least two different days within any week (Sunday through Saturday period), provided that each day’s visit lasts at least three hours and the combined weekly visit lasts at least six hours, and the combined annual visits last at least 60 hours. Child-occupied facilities may include, but are not limited to, day-care centers, preschools and kindergarten classrooms.

  • Landlord’s Work means the work of constructing the Tenant Improvements.

  • Occupancy means the use or intended use of a building or part thereof for the shelter or support of persons, animals or property.

  • Landlord Work means the work, if any, that Landlord is obligated to perform in the Premises pursuant to a separate agreement (the “Work Letter”), if any, attached to this Lease as Exhibit C.

  • Occupancy Date means the date on which occupancy of all Units in a Project is permitted;

  • Expansion Space means any space in the Building which, at any time during the Lease Term, is occupied by a Person other than Landlord under a written lease with Landlord, and the term “Tenant’s Expansion Space” means Expansion Space which Tenant has elected to lease as provided in this paragraph. Landlord agrees to notify Tenant promptly after Landlord learns that any Expansion Space is or will become available. Subject to the prior rights of other tenants to whom Landlord has granted substantially similar rights, Tenant has the option to lease any Expansion Space which Landlord notifies Tenant is or will become available. If Tenant gives Landlord notice of its exercise of this option within thirty (30) days after notification from Landlord of the availability of the Expansion Space and if no Event of Default exists when Tenant’s notice is given, this Lease will be deemed to be amended to include Tenant’s Expansion Space as part of the Premises for the remainder of the Lease Term upon all of the same terms contained in this Lease except that (i) the Rentable Area of the Premises will be amended to include Tenant’s Expansion Space; (ii) Tenant’s Share will be increased to include the rentable area of Tenant’s Expansion Space; (iii) the Term Commencement Date with respect to Tenant’s Expansion Space will be the earlier of sixty (60) days after the date on which Tenant’s Expansion Space becomes vacant and ready for occupancy (provided that date is at least sixty (60) days after Tenant exercises its option to lease the Expansion Space), or the date on which the Expansion Space is first occupied by Tenant; (iv) if Tenant’s Expansion Space contains a rentable area of 10,000 square feet or more, and if there are less than three (3) Lease Years remaining in the Lease Term, the Lease Term will be extended to include three (3) full years from the Term Commencement Date with respect to Tenant’s Expansion Space; and (v) subject to adjustment during each Fixed Rental Period as provided in Exhibit E, Basic Rent for each year of the remaining Lease Term (as it may be extended) will be the greater of (a) the Basic Rent last paid by the Person most recently occupying Tenant’s Expansion Space or (b) Market Rent determined as provided in the Rent Rider attached as Exhibit E. If Tenant exercises this option, Tenant’s Expansion Space will be leased to Tenant in its “as is” condition and Tenant will, at its expense and in compliance with the provisions of Section 7.06, design and construct all Improvements desired by Tenant for its use and occupancy. Landlord and Tenant agree to execute such amendments to this Lease and other instruments as either of them considers necessary or desirable to reflect Tenant’s exercise of this option.

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • bicycle parking space – occupant means an area that is equipped with a bicycle rack or locker for the purpose of parking and securing bicycles, and:

  • Permitted Occupier means if used in the Agreement, any person who is licensed or permitted by the Landlord to reside at the Property together with the Tenant and who does so as a rent free licensee of the Tenant.

  • Certificate of Occupancy means a certificate of occupancy, governmental sign-off or other document, permit or approval (whether conditional, unconditional, temporary or permanent) which must be obtained by Landlord from the appropriate governmental authority as a condition to the lawful initial occupancy by Tenant of the Expansion Space that is the subject of the Work.

  • Subleased Premises means such portions of the Leased Premises being particularly identified on Schedule B, which the parties agree, for the purposes of this Sublease and any square footage calculations pursuant hereto, is approximately 42,244 square feet of office (21,068 square feet on the third floor and 21,176 square feet on the seventh floor) and approximately 9.4312% of common space (building rentable area is 447,917 square feet).

  • the Premises means the building or part of the building booked and referred to in the contract

  • Tenant Work All work installed or furnished to the Premises by Tenant in connection with Tenant’s initial occupancy pursuant to Rider 2 and the Workletter.

  • Leased space means individual storage space at a self-service storage facility which is rented to an occupant pursuant to a rental agreement.

  • Tenant Delays means delays caused by: (i) requirements of the Plans and Specifications requested by Tenant that do not conform to Landlord’s building standards for office and lab build-out, or which contain long lead-time or non-standard items requested by Tenant; provided that Landlord has notified Tenant of such deviations upon execution of this Lease (ii) any material change in the Plans and Specifications requested by Tenant and agreed to by Landlord; (iii) any request by Tenant for a delay in the commencement or completion of the Initial Tenant Improvements for any reason; (iv) Tenant delay in finalizing and approving the design of the vivarium and value engineering of same or (v) any other act or omission of Tenant or its employees, agents or contractors which reasonably inhibits the Landlord from timely completing the Initial Tenant Improvements including, without limitation any delays caused by Tenant’s presence in the Premises prior to the Term Commencement Date. The Premises shall not be deemed to be incomplete if only minor or insubstantial details of construction, decoration or mechanical adjustments remain to be done which do not unreasonably interfere with Tenant’s occupancy of the Premises. If as a result of Tenant Delays the Premises are deemed ready for Tenant’s occupancy, pursuant to the foregoing (and the term shall have commenced by reason thereof), but the Premises are not in fact actually ready for Tenant’s occupancy, Tenant shall not (except with Landlord’s consent not to be unreasonably withheld, conditioned or delayed) be entitled to take possession of the Premises for the permitted use until the Premises are in fact actually ready for such occupancy.

  • Leased Premises means the Leased Premises as defined in Paragraph 1.

  • Storage Space means a space where goods of non-hazardous nature are stored and includes cold storage and banking safe vaults;

  • Unoccupied means the dwelling is not being inhabited as a residence.

  • Tenant Delay as used in the Lease or this Agreement shall mean any delay that Landlord may encounter in the performance of Landlord’s obligations under the Lease or this Agreement because of any act or omission of any nature by Tenant or its agents or contractors, including any: (1) delay attributable to changes in or additions to the Approved Plans or to the Landlord’s Work requested by Tenant; (2) delay attributable to the postponement of any Landlord’s Work at the request of Tenant; (3) delay caused by a Change Order requested by Tenant; (4) delay attributable to the failure of Tenant to pay, when due, any amounts required to be paid by Tenant pursuant to the Lease; or (5) delay attributable to a failure of Tenant to employ union labor for Tenant’s work at the Premises during the time the Landlord’s Work is being constructed. Tenant shall pay all actual costs and expenses incurred by Landlord which result from any Tenant Delay and the Commencement Date of the Lease shall be accelerated one (1) day for each day the Premises is not Ready for Occupancy as a result of a Tenant Delay. No Tenant Delay shall be deemed to have occurred unless Landlord gives Tenant prior written notice or written notice within five (5) days of the occurrence, as reasonable under the circumstances, specifying the claimed reasons for such Tenant Delay, and Tenant shall fail to promptly correct or cure such Tenant Delay. There shall be excluded from the number of days of any Tenant Delay, or any of the following events of force majeure: labor disputes, fire, unusual delay in transportation, adverse weather conditions not reasonably anticipatable, unavoidable casualties, delays in obtaining permits or governmental approvals or any other causes beyond Landlord’s or its contractor’s reasonable control (and other than for financial reasons) (collectively, “Force Majeure Delays”).

  • Building Work has the meaning given to it in section 6 of the Building and Construction Industry (Improving Productivity) Act 2016 (Cth);

  • residential premises means a house, building, structure, shelter, or mobile home, or portion thereof, used as a dwelling, home, residence, or living place by 1 or more human beings. “Residential premises” includes an apartment unit, a boardinghouse, a rooming house, a mobile home, a mobile home space, and a single or multiple family dwelling, but does not include a hotel, a motel, motor home, or other tourist accommodation, when used as a temporary accommodation for guests or tourists, or premises used as the principal place of residence of the owner and rented occasionally during temporary absences including vacation or sabbatical leave.