Acceptance of System definition

Acceptance of System means the System, including the hardware, software, solution or any Deliverable accepted or deemed to have been accepted by the Authority, subsequent to its installation, rollout and deployment of trained manpower, when all the activities as defined in Scope of Work have been successfully executed and completed to the satisfaction of the Authority and the Authority has given its acceptance by signing the Acceptance Certificate.
Sample 1
Acceptance of System. The system shall be deemed to have been accepted by the Authority, subsequent to its installation, rollout & deployment of trained manpower, when all the activities as defined in Scope of Work have been successfully executed and completed to the satisfaction of Authority or when the authority uses the deliverables for its intended use, whichever is earlier. Refer Section 5 of RFP Volume II.
Sample 1
Acceptance of System. : means acceptance of the system by the purchaser as per section 5 of the RFP.
Sample 1

Examples of Acceptance of System in a sentence

  • Milestone Deliverable Milestone Completion Date Unisys Milestone Payment 1 Migration Plan TBD $492,703 3 Maintenance and Operations Plan TBD $328,468 2 Setup and Configuration TBD $328,468 4 User Acceptance of System TBD $328,468 5 Services Go-Live June 30, 2016 $164,234 EXHIBIT E to SOW SUPPORTED UTILITIES Utility Description Grubbyware ATAT Submit transparent control (@@) statements.

  • The Contractor shall meet the following escrow requirements: Contractor shall arrange for a complete copy of the version of the Source Code delivered to the Department to be deposited with the escrow agent ________ has under contract on the date of Acceptance of System by the Department (“Escrow Date”).

  • CONTRACTOR shall test the Baseline Application Software consistent with Paragraph 9 (Acceptance of System by COUNTY) of the body of the Agreement and this Exhibit A.1.

  • Neither Acceptance of the System and services or payment therefor, nor any provision in this Agreement, nor partial or entire use of the System and services by the Department shall constitute an Acceptance of System and services not performed in accordance with this Agreement or relieve the Vendor of liability for any express or implied warranties or responsibility for faulty materials or workmanship.

  • CONTRACTOR shall develop and execute System Test plans and scenarios consistent with Paragraph 9 (Acceptance of System by COUNTY) of the body of the Agreement and this Exhibit A.1. CONTRACTOR shall document the results of the System Test and certify, in writing, that CONTRACTOR has successfully System Tested the Operating Software and the Baseline Application Software and that it functions as specified in the Final Design Document.

  • The parties agree that Contractor may use the Placer County seal and name and/or Placer County Sheriff/Partnering Agency logo and name on its website and promotional literature after Final Acceptance of System and with written approval by County of specified use.

Related to Acceptance of System

  • Acceptance of Bid means the letter/fax or any memorandum communicating to the Bidder the acceptance of its Bid and includes an advance acceptance of his Bid.

  • Acceptance of Tender means the letter or memorandum communicating to the supplier the acceptance of his offer (Tender) and shall include advance acceptance of his offer i.e. Letter of Intent or Rate Contract.

  • Acceptance of offer means issue of letter of intent/award or memorandum or detailed Order/Contract communicating the acceptance of offer, to the successful Tenderer.

  • Acceptance Testing mean the tests, reviews and other activities that are performed by or on behalf of Agency to determine whether the Deliverables meet the Acceptance Criteria or otherwise satisfy the Agency, as determined by the Agency in its sole discretion.

  • Completion of work means completion of the entire contracted work. Exhaustion of quantity of any particular item mentioned in the bid document shall not imply completion of work or any component thereof.

  • Acceptance Tests means those tests performed during the Performance Period which are intended to determine compliance of Equipment and Software with the specifications and all other Attachments incorporated herein by reference and to determine the reliability of the Equipment.

  • Acceptance Letter means the letter from Adviser to BD pursuant to which the Adviser appoints BD as a Broker Dealer for each series of MuniPreferred issued by any Fund that has executed a Request Letter.

  • Construction Phase Services means the coordination, implementation and execution of the Work required by this Agreement, which are further defined in Article 8.

  • Acceptance Test is a test of the Features executed by the Customer to prepare the acceptance.

  • Subsystem means any subset of the System identified as such in the Contract that may be supplied, installed, tested, and commissioned individually before Commissioning of the entire System.

  • Acceptance Window shall have the meaning specified in paragraph 2B(5).

  • Statement of Work means the description of activities performed in completing the Project, as specified in the Contract and as may be amended.

  • Service Description means pre-defined descriptions of services found at http://www.sap.com/servicedescriptions current as of the effective date of the Order Form which in conjunction with a Scope Document (if any) defines the Services to be provided and becomes part of the Order Form.

  • Maintenance and Support Services means the services provided by Contractor under Appendix F.

  • Letter of Acceptance of Tender means letter giving intimation to the tenderer that his tender has been accepted in accordance with the provisions contained in that letter.

  • Service Desk means the single point of entry for all Service Tickets and Service Requests which can be accessed over the phone, by email or via our portal.

  • Design Manual means the MOHLTC design manual or manuals in effect and applicable to the development, upgrade, retrofit, renovation or redevelopment of the Home or Beds subject to this Agreement.

  • Service List means the list of persons designated by the hearing officer or Clerk in a regulatory or adjudicatory proceeding upon whom parties or participants must serve motions, prefiled questions and prefiled testimony and any other documents that the parties or participants file with the Clerk unless the hearing officer otherwise directs. (See definition of "notice list" in this Section.) (See also 35 Ill. Adm. Code 102.422.)

  • 911 system means the set of network, database and customer premise equipment (CPE) components required to provide 911 service.

  • Design Services means architect services, engineer services or landscape architect services.

  • DESCRIPTION OF WORK [INSERT] SUBMISSION DEADLINE: [INSERT] APPROXIMATE SPECIFICATIONS: [ ] words; [ ] pages; [ ] images/drawings/figures

  • maintenance order , in relation to a court, means an order made by a court —

  • Construction Service Agreement means either an Interconnection Construction Service Agreement or an Upgrade Construction Service Agreement.

  • Use of System Agreement means an agreement or arrangement between us and a Distribution Network Operator governing our use of their Distribution System to provide the Supply;

  • Office of the Interconnection Control Center means the equipment, facilities and personnel used by the Office of the Interconnection to coordinate and direct the operation of the PJM Region and to administer the PJM Interchange Energy Market, including facilities and equipment used to communicate and coordinate with the Market Participants in connection with transactions in the PJM Interchange Energy Market or the operation of the PJM Region. On-Site Generators:

  • Service Specification means and include detailed description, statements to technical data, performance characteristics, and standards (Indian as well as) as applicable and as specified in the Contract as well as those specifications relating to Industry standards and codes applicable to the performance of the work, work performance quality and the specifications affecting the works or any additional specification required to be produced by the DCO to meet the design criteria.