Yearly Recomputation of Rates After Sample Clauses

Yearly Recomputation of Rates After. 1970 The rates to be used in determining the components of the Delta Water Charge pursuant to subdivision (d) of this article and to become effective on January 1, 1970, shall be computed by the State in accordance with subdivision (c) of this article prior to that date. Such computation shall include an adjustment which shall account for the difference, if any, between revenues received by the State under the Delta Water Charge prior to January 1, 1970, and revenues which would have been received under the charge prior to that date had it been computed and charged in accordance with subdivisions (c) and (d) of this article. Upon such computation, a document establishing such rates shall be prepared by the State and attached to this contract as an amendment of this article. The State shall recompute such rates each year thereafter, and each such recomputation shall take account of and reflect increases or decreases from year to year in projected costs, outstanding reimbursable indebtedness of the State incurred to construct the project conservation facilities described in subdivision (e) of this article, annual entitlements, deliveries of project water, project interest rate, revenues from the sale or other disposal of electrical energy, and all other factors which are determinative of such rates. In addition, each such recomputation shall include an adjustment of the rates for succeeding years which shall account for the differences, if any, between projections of costs used by the State in determining said rates for all preceding years, and actual costs incurred by the State during such years. Upon each such recomputation, an appropriately revised copy of the document establishing such rates shall be prepared by the State and attached to this contract as an amendment of this article.
Sample 1Sample 2Sample 3See All (41)
AutoNDA by SimpleDocs

Related to Yearly Recomputation of Rates After

  • Rate Redetermination for Market Change In the event of delay or interruption, exceeding 90 days, under B8.33, Contracting Officer shall make an appraisal to determine for each species the difference between the appraised unit value of Included Timber immediately prior to the delay or interruption and the appraised unit value of Included Timber immediately after the delay or interruption. The appraisal shall be done after any rate redetermination done pursuant to B3.31, using remaining volumes. Tentative Rates and Flat Rates in effect at the time of delay or interruption or established pursuant to B3.31 will be reduced, if appraised rates declined during the delay or interruption, to become Current Contract Rates. Increases in rates will not be considered. Accordingly, Base Rates shall be adjusted to correspond to the redetermined rates if redetermined rates are less than the original Base Rates, subject to a new Base Rate limitation of the cost of essential reforestation or 25 cents per hundred cubic feet or equivalent, whichever is larger. However, existing Base Indices shall not be changed under this Subsection. Redetermined rates shall be considered established under B3.1 for timber Scaled subsequent to the delay or interruption.

  • Rental Rates and Wage Rates for Change Orders As soon as is practical, but prior to the completion of the Construction Preparation Period and in any event prior to the commencement of any Work on the Site, the Contractor shall submit in accordance with the style and format of a specimen to be furnished by the Owner for consideration of the Owner the following: (1) a proposal for rental rates on heavy construction equipment that shall apply in the event Change Order Work is performed, and (2) a proposal for wage rates for the types of project labor that shall apply in the event of the execution of any Change Order Work. Under penalty of false swearing, a principal of the contracting firm shall certify that the proposal for rental rates and proposal for wage rates do not exceed current costs for like services. The Owner will in no event consider a rental rate in excess of eighty percent of the rate set forth in the latest edition of the "Compilation of Nationally Averaged Rental Rates for Construction Equipment" of the Associated Equipment Distributors unless the rates proposed in excess of eighty percent are supported by proof satisfactory to the Owner that the excess rates are reasonable. If the equipment is owned by the Contractor the costs shall be charged at a maximum of eighty percent of market monthly rental rates for the amount of time used. If applicable, transportation costs may be included. The decision of the Owner shall be final, binding and conclusive on all parties. Rental rates shall be payable only for the actual time the equipment is required on the Site.

  • Interest Calculation Interest on the outstanding principal balance of the Loan shall be calculated by multiplying (a) the actual number of days elapsed in the period for which the calculation is being made by (b) a daily rate based on a three hundred sixty (360) day year by (c) the outstanding principal balance.

  • COMPUTATION OF BACK WAGES No claim for back wages shall exceed the amount of wages the employee would otherwise have earned at the employee's regular rate less:

  • COMPUTATION OF BENEFITS All hours paid to an employee shall be considered as hours worked for the purpose of computing any of the benefits under this Agreement.

  • Interest Eligibility and Computation If NYSERDA fails to make Prompt Payment, NYSERDA shall pay interest to the Contractor on the Payment when such interest computed as provided herein is equal to or more than ten dollars ($10.00). Interest shall be computed and accrue at the daily rate in effect on the Date of Payment, as set by the New York State Tax Commission for corporate taxes pursuant to Section 1096(e)(1) of the Tax Law. Interest on such a Payment shall be computed for the period beginning on the day after the Payment Due Date and ending on the Date of Payment.

  • Computation of Overtime In computing overtime a period of thirty (30) minutes or less shall be counted as one-half (½) hour and a period of more than thirty (30) minutes but less than sixty (60) minutes shall be counted as one (1) hour.

  • Supplementation of Compensation Award ‌ If an employee is prevented from performing the employee's regular work with the City on account of an occupational accident that is recognized by the Workers' Compensation Board as compensable within the meaning of the Workers' Compensation Act, the City will supplement the award made by the Workers' Compensation Board for loss of wages to the employee by such an amount that the award of the Workers' Compensation Board for loss of wages (excluding non- economic loss payment), together with the supplementation by the City, will equal 100% of the employee's regular net wage (gross pay less statutory deductions, union dues and required benefit plan contributions). The said supplementation shall not be payable to any employee entitled to compensation after pension age if such an employee is entitled to an unreduced pension as provided under the Local Authorities Pension Plan or after the full age of 65 years if such an employee is not entitled to a pension. Subject to the foregoing limitation, the procedure to be followed in operating this policy shall be as follows:

  • Determination of Rate of Interest and calculation of Interest Amounts The Agent will at or as soon as practicable after each time at which the Rate of Interest is to be determined, determine the Rate of Interest for the relevant Interest Period. The Agent will calculate the amount of interest (the Interest Amount) payable on the Floating Rate Notes for the relevant Interest Period by applying the Rate of Interest to:

  • INTEREST CALCULATION COSTS 10.1 As set forth in 31 CFR 205.27, interest calculation costs are defined as those costs necessary for the actual calculation of interest, including the cost of developing and maintaining clearance patterns in support of the interest calculations. Interest calculation costs do not include expenses for normal disbursing services, such as processing of checks or maintaining records for accounting and reconciliation of cash balances, or expenses for upgrading or modernizing accounting systems. Interest calculation costs in excess of $50,000 in any year are not eligible for reimbursement, unless the State provides justification with the annual report.

Time is Money Join Law Insider Premium to draft better contracts faster.