Rate Redetermination for Market Change Sample Clauses

Rate Redetermination for Market Change. In the event of delay or interruption, exceeding 90 days, under B8.33, Contracting Officer shall make an appraisal to determine for each species the difference between the appraised unit value of Included Timber immediately prior to the delay or interruption and the appraised unit value of Included Timber immediately after the delay or interruption. The appraisal shall be done after any rate redetermination done pursuant to B3.31, using remaining volumes. Tentative Rates and Flat Rates in effect at the time of delay or interruption or established pursuant to B3.31 will be reduced, if appraised rates declined during the delay or interruption, to become Current Contract Rates. Increases in rates will not be considered. Accordingly, Base Rates shall be adjusted to correspond to the redetermined rates if redetermined rates are less than the original Base Rates, subject to a new Base Rate limitation of the cost of essential reforestation or 25 cents per hundred cubic feet or equivalent, whichever is larger. However, existing Base Indices shall not be changed under this Subsection. Redetermined rates shall be considered established under B3.1 for timber Scaled subsequent to the delay or interruption.
Sample 1Sample 2Sample 3See All (189)
AutoNDA by SimpleDocs
Rate Redetermination for Market Change. In the event of delay or interruption, exceeding 90 days, under BT8.33, Contracting Officer shall make an appraisal to determine for each species the difference be- tween the appraised unit value of Included Timber imme- diately prior to the delay or interruption and the appraised unit value of Included Timber immediately after the delay or interruption. The appraisal shall be done after any rate redetermination done pursuant to BT3.31, for using re- maining volumes. Tentative Rates and Flat Rates in effect at the time of delay or interruption or established pursuant to BT3.31 will be reduced, if appraised rates declined during the delay or interruption, to become Current Contract Rates. Increases in rates will not be considered. Accordingly, Base Rates shall be adjusted to correspond to the redetermined rates if redetermined rates are less than the original Base Rates, subject to a new Base Rate limitation of the cost of essen- tial reforestation or 25 cents per hundred cubic feet or equivalent, whichever is larger. However, existing Base In- dices shall not be changed under this Subsection. Redetermined rates shall be considered established under BT3.1 Included Timber removed subsequent to the delay or interruption.
Sample 1Sample 2Sample 3See All (8)
Rate Redetermination for Market Change. In the event of delay or interruption, exceeding 90 days, un- der BT8.33, Contracting Officer shall make an appraisal to determine for each species the difference between the ap- praised unit value of Included Timber immediately prior to the delay or interruption and the appraised unit value of In- cluded Timber immediately after the delay or interruption. The appraisal shall be done after any rate redetermination done pursuant to BT3.31, using remaining volumes. Current Contract Rates in effect at the time of delay or interruption or established pursuant to BT3.31 will be reduced, if appraised rates declined during the delay or interruption. Increases in rates will not be considered. Accordingly, Base Rates shall be adjusted to correspond to the redetermined rates if redetermined rates are less than the original Base Rates, subject to a new Base Rate limitation of the cost of essential reforestation or 25 cents per hundred cubic feet or equivalent, whichever is larger. Redetermined rates shall be considered established under BT3.1 for timber removed subsequent to the delay or inter- ruption.
Sample 1Sample 2
Rate Redetermination for Market Change. In the event of delay or interruption, exceeding 90 days, under BT8.33, Contracting Officer shall make an appraisal to determine for each species the difference between the appraised unit value of Included Timber immediately prior to the delay or interruption and the appraised unit value of Included Timber immediately after the delay or interruption. The appraisal shall be done after any rate redetermination done pursuant to BT3.31, using remaining volumes. Current Contract Rates in effect at the time of delay or interruption or established pursuant to BT3.31 will be reduced, if appraised rates declined during the delay or interruption. Increases in rates will not be considered. Accordingly, Base Rates shall be adjusted to correspond to the redetermined rates if redetermined rates are less than the original Base Rates, subject to a new Base Rate limitation of the cost of essential reforestation or 25 cents per hundred cubic feet or equivalent, whichever is larger. Redetermined rates shall be considered established under BT3.1 for timber removed subsequent to the delay or interruption. BT3.4 Other Payment Rates. BT3.41 Material and Quantities Not on Page 1. Incidental amounts of products or portions of trees of species listed on Page 1 that do not meet Utilization Standards may be removed without charge. Such material may be purposely removed in more than incidental amounts without charge upon written approval of Contracting Officer, and subject to agreement on deposits if needed for road maintenance and use. Other species or products not listed on Page 1 may be cut and removed upon written approval of Contracting Officer and subject to agreement on rates of payment and deposits if needed for road maintenance and use. When any material suitable for use in a product form included on Page 1 is removed in another product form, the rates of payment shall be not less than but approximately equivalent to Current Contract Rates and Required Deposits. BT3.42 Timber Cut Through Mistake. Undesignated timber meeting Utilization Standards, cut by Purchaser through mistake and included by Contracting Officer under BT2.14, shall be removed and paid for at Current Contract Rates and Required Deposits, unless such material is not listed on Page 1. In such event, Contracting Officer, in accord with standard Forest Service methods, shall establish rates to be paid. BT3.43 Undesignated Timber Damaged Without Negligence. Undesignated timber meeting Utilization Standards, damag...
Sample 1
Rate Redetermination for Market Change. In the event of delay or interruption, exceeding 90 days, under B8.33, Contracting Officer shall make an appraisal to determine for each species the difference between the appraised unit value of Included Timber immediately prior to the delay or interruption and the appraised unit value of Included Timber immediately after the delay or interruption. The appraisal shall be done after any rate redetermination done pursuant to B3.31, using remaining volumes. SAMPLE Tentative Rates and Flat Rates in effect at the time of delay or interruption or established pursuant to B3.31 will Other species or products not listed in A2 may be cut and removed upon written approval of Contracting Officer and subject to agreement on rates of payment and deposits if needed for road maintenance and use. When any material suitable for use in a product form included in A2 is removed in another product form, the rates of payment shall be not less than but approximately equivalent to Current Contract Rates and Required De- posits.
Sample 1

Related to Rate Redetermination for Market Change

  • Rate Redetermination Rates may be redetermined as set forth in this Section. Bid Premium Rates shall be added to all redetermined rates, except as provided in B3.31, B3.32, and B3.33. Rate redeterminations shall be made in accordance with the standard Forest Service methods in effect 45 days prior to rate redetermination. Such methods shall take into consideration factors that may affect timber value at rate redetermination date. Redetermined rates shall not be less than Base Rates listed in A4, except for reduction under B3.31, B3.32, or B3.33. Required Deposits shall be redetermined. Redetermined Specified Road construction cost is subject to the limitations of B5.26.

  • Rate Redetermination for Environmental Modification In the event of a contract modification under B8.33 or partial termination under B8.34, Contracting Officer shall make an appraisal to determine for each species the difference between the appraised unit value of Included Timber remaining immediately prior to the revision and the appraised unit value of Included Timber to be cut under the modification. The appraisal shall consider the estimated cost of any construction work listed in the Schedule of Items that was performed and abandoned. Tentative Rates and Flat Rates in effect at the time of the revision will be adjusted by said differences to become Current Contract Rates. Accordingly, Base Rates shall be adjusted to correspond to the redetermined rates if redetermined rates are less than the original Base Rates, subject to a new Base Rate limitation of the cost of essential reforestation or 25 cents per hundred cubic feet or equivalent, whichever is larger. However, existing Base Indices shall not be changed under this Subsection. Redetermined rates, or differences for rates subject to B3.2, and Required Deposits shall be considered established under B3.1 for timber Scaled subsequent to the contract revision.

  • Emergency Rate Redetermination Forest Service shall redetermine rates if, upon Purchaser's application, Forest Service determies that, because of changes in the timber market since the award date or the last rate redetermination under this provision, the Producer Price Index identified in A20 has declined by 25 percent. Rates shall be redetermined under B3.3 and shall be considered established under B3.1 for timber Scaled subsequent to Purchaser's application. This Subsection shall not apply during Contract Term Extension.

  • Termination for Market Change (a) In the event of delay or interruption under B8.33, exceeding 90 days, and Contract has not been modified to include replacement timber, this contract may be terminated upon election and written notice by Purchaser, if (i) a rate redetermination for market change under B3.33 shows that the appraised weighted average Indicated Advertised Rate of all Included Timber remaining immediately prior to the delay or interruption has been reduced through a market change by an amount equal to or more than the the weighted average Current Contract Rate, or (ii) the appraised value of the remaining timber is insufficient to cover the adjusted base rates as determined under B3.33.

  • Interest Determination Dates The interest rate applicable to a Floating Rate Note for an Interest Reset Period commencing on the related Interest Reset Date will be determined by reference to the applicable Interest Rate Basis as of the particular “Interest Determination Date”, which will be: (1) with respect to the Federal Funds Open Rate—the related Interest Reset Date; (2) with respect to the Commercial Paper Rate, the Federal Funds Rate and the Prime Rate—the Business Day immediately preceding the related Interest Reset Date; (3) with respect to the CD Rate and the CMT Rate—the second Business Day preceding the related Interest Reset Date; (4) with respect to the Constant Maturity Swap Rate—the second U.S. Government Securities business day preceding the related Interest Reset Date, provided, however, that if after attempting to determine the Constant Maturity Swap Rate, such rate is not determinable for a particular Interest Determination Date, then such Interest Determination Date shall be the first U.S. Government Securities business day preceding the original interest determination date for which the Constant Maturity Swap Rate can be determined; (5) with respect to LIBOR—the second London Banking Day (as defined below) preceding the related Interest Reset Date; and (6) with respect to the Treasury Rate—the day of the week in which the related Interest Reset Date falls on which day Treasury Bills (as defined below) are normally auctioned (i.e., Treasury Bills are normally sold at auction on Monday of each week, unless that day is a legal holiday, in which case the auction is normally held on the following Tuesday, except that the auction may be held on the preceding Friday); provided, however, that if an auction is held on the Friday of the week preceding the related Interest Reset Date, the Interest Determination Date will be the preceding Friday. The Interest Determination Date pertaining to a Floating Rate Note, the interest rate of which is determined with reference to two or more Interest Rate Bases, will be the latest Business Day which is at least two Business Days before the related Interest Reset Date for the applicable Floating Rate Note on which each Interest Reset Basis is determinable. “London Banking Day” means a day on which commercial banks are open for business (including dealings in the LIBOR Currency) in London.

  • Inability to Determine Applicable Interest Rate In the event that Administrative Agent shall have determined (which determination shall be final and conclusive and binding upon all parties hereto), on any Interest Rate Determination Date with respect to any Eurodollar Rate Loans, that by reason of circumstances affecting the London interbank market adequate and fair means do not exist for ascertaining the interest rate applicable to such Loans on the basis provided for in the definition of Adjusted Eurodollar Rate, Administrative Agent shall on such date give notice (by telefacsimile or by telephone confirmed in writing) to Borrower and each Lender of such determination, whereupon (i) no Loans may be made as, or converted to, Eurodollar Rate Loans until such time as Administrative Agent notifies Borrower and Lenders that the circumstances giving rise to such notice no longer exist, and (ii) any Funding Notice or Conversion/Continuation Notice given by Borrower with respect to the Loans in respect of which such determination was made shall be deemed to be rescinded by Borrower.

  • Interest Rate Determination (a) The Administrative Agent shall give prompt notice to the Borrower and the Lenders of the applicable interest rate determined by the Administrative Agent for purposes of Section 2.11(a) or (b), and, if applicable, the rate for the purpose of determining the applicable interest rate under Section 2.11(c).

  • Performance Adjustment Rate Except as otherwise provided in sub-paragraph (e) of this paragraph 3, the Performance Adjustment Rate is 0.02% for each percentage point (the performance of the Portfolio and the Index each being calculated to the nearest .01%) that the Portfolio's investment performance for the performance period was better or worse than the record of the Index as then constituted. The maximum performance adjustment rate is 0.20%. For purposes of calculating the performance adjustment of the portfolio, the portfolio's investment performance will be based on the performance of the retail class. The performance period will commence with the first day of the first full month following the retail class's commencement of operations. During the first eleven months of the performance period for the retail class, there will be no performance adjustment. Starting with the twelfth month of the performance period, the performance adjustment will take effect. Following the twelfth month a new month will be added to the performance period until the performance period equals 36 months. Thereafter the performance period will consist of the current month plus the previous 35 months. The Portfolio's investment performance will be measured by comparing (i) the opening net asset value of one share of the retail class of the Portfolio on the first business day of the performance period with (ii) the closing net asset value of one share of the retail class of the Portfolio as of the last business day of such period. In computing the investment performance of the retail class of the Portfolio and the investment record of the Index, distributions of realized capital gains, the value of capital gains taxes per share paid or payable on undistributed realized long-term capital gains accumulated to the end of such period and dividends paid out of investment income on the part of the Portfolio, and all cash distributions of the securities included in the Index, will be treated as reinvested in accordance with Rule 205-1 or any other applicable rules under the Investment Advisers Act of 1940, as the same from time to time may be amended.

  • Scheduled and Interim Redetermination Procedure (i) Each Scheduled Redetermination and each Interim Redetermination shall be effectuated as follows: Upon receipt by the Administrative Agent of (A) the Reserve Report and the certificate required to be delivered by the Borrower to the Administrative Agent, in the case of a Scheduled Redetermination, pursuant to Section 8.12(a) and (c), and, in the case of an Interim Redetermination, pursuant to Section 8.12(b) and (c), and (B) such other reports, data and supplemental information, including, without limitation, the information provided pursuant to Section 8.12(c), as may, from time to time, be reasonably requested by the Majority Lenders (the Reserve Report, such certificate and such other reports, data and supplemental information being the “Engineering Reports”), the Administrative Agent shall evaluate the information contained in the Engineering Reports and shall, in good faith, propose a new Borrowing Base (the “Proposed Borrowing Base”) based upon such information and such other information (including, without limitation, the status of title information with respect to the Oil and Gas Properties as described in the Engineering Reports and the existence of any other Debt) as the Administrative Agent deems appropriate in its sole discretion and consistent with its normal oil and gas lending criteria as it exists at the particular time. In no event shall the Proposed Borrowing Base exceed the Aggregate Maximum Credit Amounts.

  • Determination of Applicable Interest Rate As soon as practicable on each Interest Rate Determination Date, Bank shall determine (which determination shall, absent manifest error in calculation, be final, conclusive and binding upon all parties) the interest rate that shall apply to the LIBOR Advances for which an interest rate is then being determined for the applicable Interest Period and shall promptly give notice thereof (in writing or by telephone confirmed in writing) to Borrower.

Time is Money Join Law Insider Premium to draft better contracts faster.