Periodic Certifications Sample Clauses

Periodic Certifications. Beginning (***) prior to the start of the Launch Period and on each (***) anniversary thereafter (***). In the event of an anticipated delay in production of the Launch Vehicle or Payload (as applicable), the Party experiencing the delay shall provide a bona fide estimate of the duration of the delay. Any delay notice provided in accordance with this Section 6.4 (Periodic Certifications) shall not be deemed as an approval or waiver by Customer or Contractor, respectively, for a delay of the Launch Date or delivery of the Payload, as applicable. Notwithstanding the foregoing, the Parties acknowledge and agree that delay fees (described in Section 11 (Delays)) shall only apply to actual Launch delays and not anticipated production delays and any certification provided under this Section 6.4 (Periodic Certifications) shall not constitute a request by either Party for postponement of the Launch Date.
Sample 1Sample 2
AutoNDA by SimpleDocs
Periodic Certifications. (a) No later than five Business days following the date on which Wellington enters into an agreement with respect to an engagement described in Section 2.3(b), Wellington shall deliver a certificate to Hartford, signed by an Executive Officer of Wellington, setting forth, to the knowledge of such Executive Officer, the amount of Non-Hartford Covered Fund AUM and WAUM (which the Parties acknowledge will be based upon information obtained from third parties and thus will be subject to any errors or omissions that may be contained therein) and indicating the date(s) as of which such amounts were determined.
Sample 1Sample 2
Periodic Certifications. At the sole discretion and request of Xxxxxxxxxxx'x Law Department, Xxxxxx agrees to re-affirm the commitments and representations contained herein on periodic certifications. If Seller fails to comply with this clause, Halliburton may terminate this Agreement immediately by written notice for cause.
Sample 1
Periodic Certifications. Beginning [***…***] 2013, and every [***…***] thereafter until the relevant Launch, for each Launch Service, each Party shall certify (in writing) to the other if production of the Launch Vehicle or Satellite Batch (as applicable) is on schedule for the relevant Launch Date or not. With respect to a Satellite Batch, the [***…***] certification must include the launch readiness date as well as the status of each Satellite of the relevant Satellite Batch as of the date of certification. With respect to the Launch Vehicle, the certification must include the launch readiness date as well as the status of the relevant Launch Vehicle prior to the relevant Launch. In the event of an anticipated delay in production of the Launch Vehicle or a Satellite Batch (as applicable), the Party experiencing the delay shall provide a bona fide estimate of the duration of the delay. Notwithstanding the foregoing, the Parties acknowledge and agree that any delay fees (described in Section 9 (Delays)) shall apply only to actual Launch delays beyond the First Launch Period or Second Launch Period, as applicable, and not anticipated production or other delays.
Sample 1
Periodic Certifications. Without limitation to the foregoing, Licensee will be required to submit certifications of compliance with Compliance Standards and the relevant policies and procedures as set forth in this nHCM Supplemental Agreement at the frequency required by Company, but at least [***] during the Term (or, with respect to the [***], for so long as the [***]), in substantially the form of Exhibit 5.2 attached hereto.
Sample 1
Periodic Certifications. Beginning [***…***] 2013, and every [***…***] thereafter until the relevant Launch, for each Launch Service, each Party shall certify (in writing) to the other if production of the Launch Vehicle or Satellite Batch (as applicable) is on schedule for the relevant Launch Date or not. With respect to a Satellite Batch, the [***…***] certification must include the launch readiness date as well as the status of each Satellite of the relevant Satellite Batch as of the date of certification. With respect to the Launch Vehicle, the certification must include the launch readiness date as well as the status of the relevant Launch Vehicle prior to the relevant Launch. In the event of an anticipated delay in production of the Launch Vehicle or a Satellite Batch (as applicable), the Party experiencing the delay shall provide a bona fide estimate of the duration of the delay. Notwithstanding the foregoing, the Parties acknowledge and agree that any delay fees (described in Section 9 (Delays)) shall apply only to actual Launch delays beyond the First Launch Period or Second Launch Period, as applicable, and not anticipated production or other delays. CONFIDENTIAL TREATMENT HAS BEEN REQUESTED FOR PORTIONS OF THIS EXHIBIT. THE COPY FILED HEREWITH OMITS THE INFORMATION SUBJECT TO A CONFIDENTIALITY REQUEST. OMISSIONS ARE DESIGNATED [***. . .***]. A COMPLETE VERSION OF THIS EXHIBIT HAS BEEN FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
Sample 1

Related to Periodic Certifications

  • CLEC Certification 8.1 Notwithstanding any other provision of this Agreement, CenturyLink shall have no obligation to perform under this Agreement until such time as CLEC has obtained such FCC and Commission authorization(s) as may be required by Applicable Law for conducting business in the State as a competitive local exchange carrier. CLEC shall not be permitted to establish its account nor place any orders under this Agreement until it has obtained such authorization and provided proof of such to CenturyLink. For the life of this Agreement, CLEC must represent and warrant to CenturyLink that it remains a certified local provider of Telephone Exchange Service within CenturyLink’s Local Calling Area(s) in the State. At any time during the life of this Agreement, CLEC will provide a copy of its current Certificate of Operating Authority or other evidence of its status to CenturyLink upon request. CLEC’s failure to maintain such authorization(s) as may be required by Applicable Law for conducting business in the State as a CLEC shall be considered a Default of Agreement.

  • New Certifications If a participating Employer is newly certified by ONA at one of its owned nursing homes for its registered nurses, the existing standard non-monetary provisions in the central ONA/RN agreements will automatically apply to the nurses effective nine (9) months after the Employer receives notice to bargain from the Union or a Memorandum of Agreement or Interest Arbitration Award is received, whichever is earlier. These provisions include: Article 1 Article 2.03 Articles 2.05, 2.07-2.12 Articles 3-8 Articles 9.01(d) only, 9.03-9.13, 9.15, 9.16, 9.17 Article 10

  • AS9100 Certification ‌ AS9100 Certification, specifies requirements for a quality management system to demonstrate the Contractor’s ability to consistently meet the customer requirements as well as statutory and regulatory requirements for the aerospace industry. An AS9100 Certification, is not mandatory; however, Contractors who desire to compete for work within the aerospace industry are encouraged to have AS9100 Certification, during the entire term of OASIS. The Contractor shall notify the OASIS CO, in writing, if there are any changes in the status of their AS9100 Certification, and provide the reasons for the change and copies of audits from an AS9100 Certification Body, as applicable. If only part of a Contractor’s organization is AS9100, certified, the Contractor shall make the distinction between which business units or sites and geographic locations have been certified.

  • Additional Certifications Any certificate signed by any director or officer of the Corporation and delivered to an Agent or to counsel for such Agent in connection with an offering of Notes or the sale of Notes to an Agent as principal shall be deemed a representation and warranty by the Corporation to such Agent as to the matters covered thereby on the date of such certificate and at each Representation Date subsequent thereto.

  • Invoice Certification When and if requested by DXC, as a condition precedent to payment thereof, Supplier shall separately certify each invoice as follows: “We certify that contract deliverables listed hereon were produced in compliance with all applicable requirements of Sections 6, 7, and 12 of the Fair Labor Standards Act, as amended, and of regulations and orders of the U.S. Department of Labor issued under Section 14 thereof. We further certify that any and all additional contract deliverables will be produced in compliance with same.”

  • Required Certifications A bidder who makes a false certification on the Bidder Certification of the Prequalification Classification and Work Capacity Form will be subject to forfeiture of his bid bond and/or disqualification from bidding on future work for a 90 day period, or both. The Contracting Officer will determine the imposition and the extent of such sanctions. A sworn statement shall be executed by the bidder or his agent on behalf of each person, firm, association, or corporation submitting a bid. The statement shall certify that the person, firm, association, or corporation has not, either directly or indirectly, entered into any agreement, participated in any collusion, or otherwise taken any action to restrain free competitive bidding in connection with the proposal. The sworn statement shall be part of the bid or in the form of an affidavit and shall be sworn to before a person who is authorized by the laws of the State to administer oaths. The bids shall contain the identical sworn statement. For the purpose of this Section, affixing digital ID to the bid will be considered by the Department conditional evidence of signing before a person who is authorized by the laws of the Commonwealth to administer oaths. The original of the sworn statement shall be filed with the Department when the bid is submitted.

  • Owner Certification During the term of this Contract, the Owner certifies that:

  • Remittance Reports; Advances (a) On the second Business Day following each Determination Date but in no event later than the earlier of (i) such date which would allow the indenture trustee to submit a claim to the NIMS Insurer under the Indenture so as to allow a timely payment by the NIMS Insurer under the insurance policy related to the notes insured by the NIMS Insurer and (ii) the 20th day of each month (or if such 20th day is not a Business Day, the preceding Business Day), the Master Servicer shall deliver to the Trustee and the NIMS Insurer by telecopy or electronic mail (or by such other means as the Master Servicer and the Trustee may agree from time to time) a Remittance Report with respect to the related Distribution Date. Not later than the 20th day of each month (or if such 20th day is not a Business Day, the preceding Business Day), the Master Servicer shall deliver or cause to be delivered to the Trustee in addition to the information provided on the Remittance Report, such other information reasonably available to it with respect to the Mortgage Loans as the Trustee may reasonably require to perform the calculations necessary to make the distributions contemplated by Section 4.01 and to prepare the statements to Certificateholders contemplated by Section 4.03. The Trustee shall not be responsible to recompute, recalculate or verify any information provided to it by the Master Servicer.

  • Management Certifications In addition to the responsibilities set forth in this CIA for all Covered Persons, certain Progenity employees (Certifying Employees) are specifically expected to monitor and oversee activities within their areas of authority and shall annually certify that the applicable Progenity department is in compliance with applicable Federal health care program requirements and with the obligations of this CIA. These Certifying Employees shall include, at a minimum, the following: Chief Executive Officer; Chief Financial Officer; Chief Operating Officer; Chief Commercial Officer; Chief Scientific Officer; Chief Medical Officer; and Chief Information Officer. For each Reporting Period, each Certifying Employee shall sign a certification that states: “I have been trained on and understand the compliance requirements and responsibilities as they relate to [insert name of department], an area under my supervision. My job responsibilities include ensuring compliance with regard to the [insert name of department] with all applicable Federal health care program requirements, obligations of the Corporate Integrity Agreement, and Progenity policies, and I have taken steps to promote such compliance. To the best of my knowledge, the [insert name of department] of Progenity is in compliance with all applicable Federal health care program requirements and the obligations of the Corporate Integrity Agreement. I understand that this certification is being provided to and relied upon by the United States.” If any Certifying Employee is unable to provide such a certification, the Certifying Employee shall provide a written explanation of the reasons why he or she is unable to provide the certification outlined above. Within 90 days after the Effective Date, Progenity shall develop and implement a written process for Certifying Employees to follow for the purpose of completing the certification required by this section (e.g., reports that must be reviewed, assessments that must be completed, sub-certifications that must be obtained, etc. prior to the Certifying Employee making the required certification). Progenity, Inc. Corporate Integrity Agreement

  • Remittance Reports; P&I Advances (a) On the second Business Day prior to the related Distribution Date, the Master Servicer shall deliver to the Trust Administrator, the Paying Agent and the Trustee by telecopy (or by such other means as the Master Servicer, the Paying Agent and the Trust Administrator and the Trustee may agree from time to time) a Remittance Report with respect to the related Distribution Date. Such Remittance Report will include (i) the amount of P&I Advances to be made by the Master Servicer in respect of the related Distribution Date, the aggregate amount of P&I Advances outstanding after giving effect to such P&I Advances, and the aggregate amount of Nonrecoverable P&I Advances in respect of such Distribution Date and (ii) such other information with respect to the Mortgage Loans as the Trust Administrator or the Paying Agent may reasonably require to perform the calculations necessary for the Paying Agent to make the distributions contemplated by Section 4.01 and for the Trust Administrator to prepare the statements to Certificateholders contemplated by Section 4.02; provided, however, that if the Master Servicer is not the Trust Administrator, the Master Servicer will forward to the successor Trust Administrator the information set forth in clause (i) above on the next Business Day following the latest related Determination Date and the information set forth in clause (ii) above on the fifth Business Day following the last day of the related calendar month. Neither the Trustee, the Paying Agent nor the Trust Administrator shall be responsible to recompute, recalculate or verify any information provided to it by the Master Servicer.

Time is Money Join Law Insider Premium to draft better contracts faster.