Government Code Claim Requirements Sample Clauses

Government Code Claim Requirements. For all Claims not resolved as a result of these Article 17 procedures, ENGINEER must submit each Claim in a Government Code Section 910 form of claim for final investigation and consideration of its settlement prior to initiation of any litigation on any such Claim, as required by Government Code Section 945.4. Pursuant to Government Code Section 930.2, the one-year period in Government Code Section 911.2 is hereby reduced to 150 days. This time deadline is measured from the accrual date of each separate cause of action. The time deadline for filing a Government Code claim shall not be tolled by any action or inaction by ENGINEER or DISTRICT, including but not limited to any action or inaction to try to resolve the Claim through negotiation, mediation, settlement, agreement (including Change Order), or by any other means, other than by a separate written tolling agreement expressly approved as to form (on the face of the agreement) by the County Counsel’s Office.
Sample 1Sample 2See All (6)
AutoNDA by SimpleDocs
Government Code Claim Requirements. Pursuant to Government Code §930.6, Claims asserted by the Contractor against the District for money or damages, including without limitation Claims remaining after completion of the non-binding mediation resolution procedures described above are deemed a “suit for money or damages” and shall be subject to the provisions of Government Code §§945.4, 945.6 and 946 (“Government Code Claims Process”). An express condition precedent to the Contractor’s initiation of binding arbitration proceedings relating to Claims is the Contractor’s compliance with the Government Code Clams Process, including without limitation, presentation of the Claims and action thereon by the District or deemed rejected by the District in accordance with Government Code §900, et seq.
Sample 1Sample 2Sample 3
Government Code Claim Requirements. Pursuant to Government Code §930.6, any claim, demand, dispute, disagreement or other matter in controversy asserted by the Contractor, whether on behalf of itself or a Subcontractor, against the District for money or damages, including without limitation claims or portions thereof remaining in dispute after completion of the Section 9204 procedures (“Claims”) are deemed a “suit for money or damages” and shall be subject to the provisions of Government Code §§945.4, 945.6 and 946 (“Government Code Claims Process”). An express condition precedent to the Contractor’s initiation of Section 20104.4 Dispute Resolution Procedures or binding arbitration proceedings pursuant to the following is the Contractor’s compliance with the Government Code Clams Process, including without limitation, presentation of the claim, demand, dispute, disagreement or other matter in controversy between the Contractor and the District seeking money or damages to the District and acted upon or deemed rejected by the District in accordance with Government Code §900, et seq.
Sample 1
Government Code Claim Requirements. Pursuant to Government Code section 930.6, any claim, demand, dispute, disagreement or other matter in controversy asserted by the Architect against the District for money or damages, including, without limitation, a Demand for Arbitration, shall be deemed a “suit for money or damages” and shall be subject to the provisions of Government Code sections 945.4, 945.6 and 946. Notwithstanding the resolution of disputes pursuant to the arbitration provisions set forth in this Paragraph 12.4.4, any claim, demand, dispute, disagreement or other matter in controversy between the Architect and the District seeking money or damages in excess of $375,000 shall first be presented to the District and acted upon or deemed rejected by the District in accordance with Government Code section 900, et seq., as an express condition precedent to the Architect’s commencement of legal proceedings.
Sample 1
Government Code Claim Requirements. Pursuant to Government Code §930.6, any claim, demand, dispute, disagreement or other matter in controversy asserted by the Contractor, whether on behalf of itself or a Subcontractor, against the District for money or damages, including without limitation claims or portions thereof remaining in dispute after completion of the Section 9204 procedures s Government Code Clams Process, including without limitation, presentation of the claim, demand, dispute, disagreement or other matter in controversy between the Contractor and the District seeking money or damages to the District and acted upon or deemed rejected by the District in accordance with Government Code §900, et seq.
Sample 1
Government Code Claim Requirements. For all Claims not resolved as a result of these Article 16 procedures, Consultant must submit each Claim in a Government Code Section 910 form of claim for final investigation and consideration of its settlement prior to initiation of any litigation on any such Claim, as required by Government Code Section 945.4. Pursuant to Government Code Section 930.2, the one-year period in Government Code Section 911.2 is hereby reduced to 150 calendar days. This time deadline is measured from the accrual date of each separate cause of action. The time deadline for filing a Government Code claim shall not be tolled by any action or inaction by Consultant or County, including but not limited to any action or inaction to try to resolve the Claim through negotiation, mediation, settlement, agreement (including Change Order), or by any other means, other than by a separate written tolling agreement expressly approved as to form (on the face of the agreement) by the County Counsel’s Office.
Sample 1

Related to Government Code Claim Requirements

  • Government Code Claim Requirement No suit for money or damages may be brought against the City until a written claim therefor has been presented to and rejected by the City in conformity with the provisions of San Francisco Administrative Code Chapter 10 and California Government Code Section 900, et seq. Nothing set forth in this Agreement shall operate to toll, waive or excuse Contractor’s compliance with the California Government Code Claim requirements set forth in San Francisco Administrative Code Chapter 10 and California Government Code Section 900, et seq.

  • LABOR CODE REQUIREMENTS Provided that the Contract Price is more than $1,000, and the Work is a “public works” under the Labor Code, the parties agree as follows:  The Work is subject to compliance monitoring and enforcement by the Department of Industrial Relations.

  • GOVERNMENT REQUIREMENTS 29.1 The Union and the Employer recognize that an Employer should not lose jobs because of Government requirements, which are in conflict with the provisions of this Agreement. The Union and the Employer pledge their mutual cooperation in complying with provisions in any contract, which the Employer may bid for or enter into with any public or quasi-public or governmental body for the performance of work covered by this Agreement. If the Employer believes that a government requirement is in conflict with the Agreement, they shall request a pre-job meeting with the Union to seek alternatives. The Union will not withhold agreement unnecessarily.

  • Government Approval, Regulation, etc No authorization or approval or other action by, and no notice to or filing with, any governmental authority or regulatory body or other Person is required for the due execution, delivery or performance by the Borrower of this Amendment.

  • Government Regulations Notwithstanding anything contained herein to the contrary, the Company’s obligation hereunder to issue or deliver certificates evidencing shares of Common Stock shall be subject to the terms of all applicable laws, rules and regulations and to such approvals by any governmental agencies or national securities exchanges as may be required.

  • Government Procurement ARTICLE 6.1

  • Government Standards The Contractor shall ensure that all items and services proposed conform to all local, State and Federal law concerning safety (OSHA and NOSHA) and environmental control (EPA and Bureau County Pollution Regulations) and any other enacted ordinance, code, law or regulation. The Contractor shall be responsible for all costs incurred for compliance with any such possible ordinance, code, law or regulation. No time extensions shall be granted or financial consideration given to the Contractor for time or monies lost due to violations of any such ordinance, code, law or regulations that may occur.

  • Submitting False Claims; Monetary Penalties The AOC shall be entitled to remedy any false claims, as defined in California Government Code section 12650 et seq., made to the AOC by the Contractor or any Subcontractor under the standards set forth in Government Code section 12650 et seq. Any Contractor or Subcontractor who submits a false claim shall be liable to the AOC for three times the amount of damages that the AOC sustains because of the false claim. A Contractor or Subcontractor who submits a false claim shall also be liable to the AOC for (a) the costs, including attorney fees, of a civil action brought to recover any of those penalties or damages, and (b) a civil penalty of up to $10,000 for each false claim.

  • Government Action Any government authority takes action that the Bank believes materially adversely affects the Borrower's (or any guarantor's) financial condition or ability to repay.

  • License Requirements The Hotel’s alcoholic beverage license requires that the Hotel shall: (i) request proper identification (photo ID) of any person of questionable age and refuse alcoholic beverage service if the person is either under age or proper identification cannot be produced, and (ii) refuse alcoholic beverage service to any person who, in the Hotel’s judgment, appears to be intoxicated; and (iii) instruct its personnel to avoid encouraging patrons to consume alcoholic beverages (commonly referred to as “over-pouring”).

Time is Money Join Law Insider Premium to draft better contracts faster.