CONSTRUCTION AND RENOVATION Construction of academic or residential buildings on the UC Berkeley campus may be scheduled for the term of this Lease in the vicinity of the apartments. Capital improvement and other major housing construction or repair projects will necessarily cause increased noise and dust in affected and nearby residences at certain times. There is the possibility of both planned and unplanned utility shutdowns and access to certain facilities, streets, parking lots, walking, and bike pathways may be limited, rerouted, or completely restricted. The University will work with building contractors to make every effort to minimize construction inconveniences. By agreeing to this Lease Agreement, the Resident acknowledges notice of the possibility of scheduled construction and access limitations, and acknowledges that there will be disturbances, disruptions, and inconveniences resulting from such constructions and has agreed to such. The Resident also acknowledges that increased noise, dust, potential reassignment, or loss of parking spaces related to construction or renovation are not grounds for cancellation or termination of this Lease.
DITCH CONSTRUCTION AND RECONSTRUCTION Purchaser shall construct ditches into the subgrade as specified on the TYPICAL SECTION SHEET. Ditches must be constructed concurrently with construction of the subgrade.
Construction Phase - Administration of the Construction Contract 1.6.1 The Construction Phase shall commence with the acceptance of the Construction Manager’s Guaranteed Maximum Price (or acceptance of a partial Guaranteed Maximum Price for a stage or phase) and issuance of a Notice to Proceed with Construction Services and terminate sixty (60) days after Final Payment to the Contractor is made, or when all of Architect/Engineer’s services have been satisfactorily performed, whichever occurs later.
Construction and Maintenance There are on-going maintenance, renovation and construction projects taking place in and around the residences. The work typically takes place during regular business hours, but may begin earlier or extend into evenings or weekends. On-going construction or renovation projects will continue through midterm and final exam periods. The University will take measures to ensure that prudent construction practices are followed, but there may be noise, dust and temporary interruption of some services. Residents may be required to temporarily or permanently relocate to facilitate construction or renovation to their residence area. There will be no compensation or reduction to your residence fees due to disruption and/or relocation.
Project Funding 8.1 The Project Funding for completion of this PFA is as follows:
Project Construction The Contractor agrees to provide continuous on-site supervision on each Job Order, while progress on the project is being accomplished. The Contractor’s Project Manager will ensure:
CONSTRUCTION AND IMPROVEMENTS Concessionaire shall not affix, alter, or erect any permanent or temporary equipment, structures, buildings, or additions to the Concession Premises without first obtaining the prior written approval of Department.
Construction and Delegation If any term of this Agreement is found by a court or arbitrator of competent jurisdiction to be invalid, illegal or unenforceable, it shall be construed in such a way as to eliminate the offending aspects while still giving as much effect as possible to the intentions of such term. If this cannot be done and the entire term is invalid, illegal or unenforceable and cannot be so repaired, then the term shall be considered to be stricken from this Agreement as if it had not been included from the beginning. In any such case, the balance of this Agreement shall remain in effect in accordance with its remaining terms notwithstanding such invalid, illegal or unenforceable term. Neither the course of conduct between parties nor trade practice shall act to modify the provisions of this Agreement. We may authorize or allow our contractors and other third parties to provide the services necessary or related to making the Service available and to perform obligations and exercise our rights under this Agreement, and we may collect payment on their behalf, if applicable.
CONSTRUCTION OF THE PROJECT/ APARTMENT The Allottee has seen the proposed layout plan, specifications, amenities and facilities of the [Apartment/Plot] and accepted the floor plan, payment plan and the specifications, amenities and facilities [annexed along with this Agreement] which has been approved by the competent authority, as represented by the Promoter. The Promoter shall develop the Project in accordance with the said layout plans, floor plans and specifications, amenities and facilities. Subject to the terms in this Agreement, the Promoter undertakes to strictly abide by such plans approved by the competent Authorities and shall also strictly abide by the bye-laws, FAR and density norms and provisions prescribed by the [Please insert the relevant State laws]and shall not have an option to make any variation /alteration / modification in such plans, other than in the manner provided under the Act, and breach of this term by the Promoter shall constitute a material breach of the Agreement.
Routine Maintenance, Construction, and Repair The NYISO or Connecting Transmission Owner may interrupt interconnection service or curtail the output of the Small Generating Facility and temporarily disconnect the Small Generating Facility from the New York State Transmission System or Distribution System when necessary for routine maintenance, construction, and repairs on the New York State Transmission System or Distribution System. The NYISO or the Connecting Transmission Owner shall provide the Interconnection Customer with five Business Days notice prior to such interruption. The NYISO and Connecting Transmission Owner shall use Reasonable Efforts to coordinate such reduction or temporary disconnection with the Interconnection Customer.
