Claim Certification Sample Clauses

Claim Certification. 2 Entity acknowledges that it has read and is familiar with the provisions of the False Claims Act (California 3 Government Code Sections 12650 et seq.). Submission by Entity of any claim (as the term “claim” is defined 4 in False Claims Act) to the District in connection with the Project, whether on its behalf or on behalf of a 5 subcontractor or material supplier, shall constitute a representation by Entity to the District that submission of 6 the claim does not, in any respect, violate the False Claims Act. Any party with an interest in the claim, 7 including Entity and any subcontractor or material supplier, shall certify under penalty of perjury the validity 8 and accuracy of any claim submitted to the District, as provided below. Compliance with this claims 9 certification requirement shall be a condition precedent to any obligation District might otherwise have to 10 review the claim and failure to provide such certification shall constitute a waiver of the claim. 11 13 CLAIM CERTIFICATION 14 15 Under penalty of perjury, and with specific reference to the California False Claims Act, 16 Government Code sections 12650 et seq., I certify that submission of the attached claim is made in good 17 faith; that the supporting data prepared by the undersigned company are accurate and complete to the best of 18 my knowledge and belief; that submission of the claim to the District does not violate the False Claims Act; 19 and that I am duly authorized to certify the claim on behalf of the claimant. 20 22 Dated: 23 (Company) 24 25 26 27
Sample 1Sample 2Sample 3
AutoNDA by SimpleDocs
Claim Certification. Contractor acknowledges that it has read and is familiar with the provisions of the False Claims Act (Gov. Code, § 12650 et seq.). Submission by Contractor of any Claim (as the term “claim” is defined in False Claims Act) to District in connection with the Project, whether on its behalf or on behalf of a Subcontractor or material supplier, shall constitute a representation by Contractor to District that to the best of its knowledge, submission of the Claim does not in any respect, violate the False Claims Act. Any party with an interest in the Claim, including Contractor and any Subcontractor or material supplier, shall certify under penalty of perjury the validity and accuracy of any Claim submitted to District, as provided below. In the event of a pass-through Claim from a Subcontractor or supplier, Contractor may qualify its Claim certification to certify that the Claim is made in good faith, the supporting data is complete and accurate to the best of Subcontractor’s knowledge and belief, and that the amount requested accurately reflects the contract adjustment for which Subcontractor believes District is liable. Subcontractor shall execute any pass-through Claim pursuant to the language of this Section.
Sample 1Sample 2Sample 3
Claim Certification. Compliance with this Claims certification requirement shall be a condition precedent to any obligation District might otherwise have to review the Claim and failure to provide such certification shall constitute a waiver of the Claim.
Sample 1Sample 2Sample 3
Claim Certification. Claims exceeding $100,000.00 in value must be certified (FAR 33.207).
Sample 1
Claim Certification. If at any time prior to the Release Date (as defined below), either Company or any Indemnified Party (each a “Claim Party”)) shall claim that it is entitled to payment of all or a portion of the Escrow Deposit by the incurrence of a Covered Claim, such Claim Party shall give notice (the “Claim Notice”) to the Parent and the Committee by delivering such Claim Notice to the legal counsel of such party as set forth in Section 17.1 herein. The Claim Notice shall be in the form of an affidavit which shall (i) state the name and address of the Claim Party making the Claim Notice, (ii) describe the event or events giving rise to the Claim Notice and specifying the amount of the Escrow Deposit requested to be disbursed to the Claim Party to indemnify or reimburse the Claim Party for the Covered Claim, (iii) identify the relevant Indemnification Document(s) pursuant to which the Covered Claim arises together with a statement describing the nature of the Covered Claim, (iv) relevant invoices or other supporting documentation, to the extent available, establishing the amount of the Covered Claim and (v) instructions for the delivery of any payment of Escrow Deposit made in respect of such Covered Claim. The Committee and the Parent shall each promptly evaluate any and all Claim Notices delivered to the Committee and the Parent and determine in good faith the validity of each such Claim Notice. If both the Committee and the Parent approve the Claim Notice, a written notification to that effect and including instructions to deliver the amount certified as valid signed by two Indemnified Party Representatives and the Parent, (an “Approved Claim Notice”) shall be delivered to the Escrow Agent with copies of such Approved Claim Notice delivered to the Designated Indemnified Parties.
Sample 1
Claim Certification. Contractor acknowledges that it has read and is familiar with the provisions of the False Claims Act (California Government Code §12650 et seq.). Submission by Contractor of any claim (as the term “claim” is defined in False Claims Act) to District in connection with the Project, whether on its behalf or on behalf of a subcontractor or material supplier, shall constitute a representation by Contractor to District that submission of the claim does not in any respect, violate the False Claims Act. Any party with an interest in the claim, including Contractor and any subcontractor or material supplier, shall certify under penalty of perjury the validity and accuracy of any claim submitted to District, as provided below. Compliance with this claims certification requirement shall be a condition precedent to any obligation District might otherwise have to review the claim and failure to provide such certification shall constitute a waiver of the claim.
Sample 1
Claim Certification. All Claim Items submitted by you or on your behalf must be accompanied by a certification (in the form approved by us or Sector Services, from time to time) as to the truth and accuracy of the claim and that the provisions of this Agreement have been complied with by you prior to the submission of the claim. The certification must be dated and personally signed by you or approved by you and signed on your behalf. Claims will not be accepted for payment unless certification is complete. In this regard:
Sample 1
AutoNDA by SimpleDocs

Related to Claim Certification

  • Claim Notice A Party that seeks indemnity under this Article X (an “Indemnified Party”) will give written notice (a “Claim Notice”) to the Party from whom indemnification is sought (an “Indemnifying Party”), whether the Damages sought arise from matters solely between the Parties or from Third Party Claims. The Claim Notice must contain (i) a description and, if known, estimated amount (the “Claimed Amount”) of any Damages incurred or reasonably expected to be incurred by the Indemnified Party, (ii) a reasonable explanation of the basis for the Claim Notice to the extent of facts then known by the Indemnified Party, and (iii) a demand for payment of those Damages. No delay or deficiency on the part of the Indemnified Party in so notifying the Indemnifying Party will relieve the Indemnifying Party of any liability for Damages or obligation hereunder except to the extent of any Damages caused by or arising out of such failure.

  • Claims Notice (a) In the event that either Purchaser or LLANY or one of the Sellers wishes to assert a claim for indemnification hereunder (including, but not limited to, claims arising from a claim or demand made, or an action, proceeding or investigation instituted, by any Person not a party to this Agreement that may result in a Loss for which indemnification is claimed under this Article IX (a "Third Party Claim")), such party seeking indemnification (the "Indemnified Party") shall give written notice (a "Claims Notice") to the other party (the "Indemnifying Party"). Such Claims Notice shall be delivered to the Indemnifying Party as promptly as practicable, specifying in detail the facts constituting the basis for, and the amount of, the claim asserted. The failure by any Indemnified Party to notify the Indemnifying Party as promptly as practicable shall relieve any Indemnifying Party from its indemnification obligations only to the extent such failure or other actions taken by the Indemnified Party in response to such claim shall actually prejudice an Indemnifying Party; provided however, that notwithstanding the foregoing, an Indemnifying Party shall have no obligations to indemnify an Indemnified Party if a Claims Notice containing the information specified above is not received by the Indemnifying Party prior to the termination of the applicable periods described in Sections 8.01(a) and 8.01(c).

  • Claim Decision Upon receipt of such claim, the Plan Administrator shall respond to such claimant within ninety (90) days after receiving the claim. If the Plan Administrator determines that special circumstances require additional time for processing the claim, the Plan Administrator can extend the response period by an additional ninety (90) days for reasonable cause by notifying the claimant in writing, prior to the end of the initial ninety (90) day period, that an additional period is required. The notice of extension must set forth the special circumstances and the date by which the Plan Administrator expects to render its decision. If the claim is denied in whole or in part, the Plan Administrator shall notify the claimant in writing of such denial. The Plan Administrator shall write the notification in a manner calculated to be understood by the claimant. The notification shall set forth:

  • Notice of Claims, etc Promptly after receipt by an indemnified party of notice of the commencement of any action or proceeding involving a claim referred to in the preceding subdivisions of this Section 5, such indemnified party will, if a claim in respect thereof is to be made against an indemnifying party, give written notice to the latter of the commencement of such action, provided, however, that the failure of any indemnified party to give notice as provided herein shall not relieve the indemnifying party of its obligations under the preceding subdivisions of this Section 5. In case any such action is brought against an indemnified party, unless in such indemnified party's reasonable judgment a conflict of interest between such indemnified and indemnifying party may exist in respect of such claim, the indemnifying party shall be entitled to participate in, and to assume the defense thereof, jointly with any other indemnifying party similarly notified, to the extent that it may wish, with counsel reasonably satisfactory to such indemnified party, and after notice from the indemnifying party to such indemnified party of its election so to assume the defense thereof, the indemnifying party shall not be liable to such indemnified party for any legal or other expenses subsequently incurred by the latter in connection with the defense thereof other than reasonable costs of investigation. No indemnifying party shall, without the consent of the indemnified party, consent to entry of any judgment or enter into any settlement of such proceedings which does not include as an unconditional term thereof the giving by the claimant or plaintiff to such indemnified party of a complete and unconditional release from all liability in respect to such claim or litigation.

  • Indemnification Claim Procedures (a) If any Action is commenced or threatened that may give rise to a claim for indemnification (an “Indemnification Claim”) by any person entitled to indemnification under this Agreement (each, an “Indemnified Party”) against any person obligated to indemnify an Indemnified Party (an “Indemnitor”), then such Indemnified Party will promptly give notice to the Indemnitor. Failure to notify the Indemnitor will not relieve the Indemnitor of any liability that it may have to the Indemnified Party, except to the extent the defense of such Action is materially and irrevocably prejudiced by the Indemnified Party’s failure to give such notice. An Indemnitor may elect at any time to assume and thereafter conduct the defense of the Indemnification Claim with counsel of the Indemnitor’s choice reasonably satisfactory to the Indemnified Party; provided, however, that the Indemnitor will not approve of the entry of any judgment or enter into any settlement with respect to the Indemnification Claim without the Indemnified Party’s prior written approval (which must not be withheld unreasonably). Until an Indemnitor assumes the defense of the Indemnification Claim, the Indemnified Party may defend against the Indemnification Claim in any manner the Indemnified Party reasonably deems appropriate. If the Indemnified Party gives an Indemnitor notice of an Indemnification Claim and the Indemnitor does not, within ten (10) days after such notice is given, give notice to the Indemnified Party of its election to assume the defense of such Indemnification Claim and thereafter promptly assume such defense, then the Indemnitor will be bound by any judicial determination made with respect to such Indemnification Claim or any compromise or settlement of such Indemnification Claim effected by the Indemnified Party.

  • Notice of Claim Promptly after receipt by an Investor Indemnitee or Company Indemnitee of notice of the commencement of any action or proceeding (including any governmental action or proceeding) involving an Indemnified Liability, such Investor Indemnitee or Company Indemnitee, as applicable, shall, if a claim for an Indemnified Liability in respect thereof is to be made against any indemnifying party under this Article V, deliver to the indemnifying party a written notice of the commencement thereof; but the failure to so notify the indemnifying party will not relieve it of liability under this Article V except to the extent the indemnifying party is prejudiced by such failure. The indemnifying party shall have the right to participate in, and, to the extent the indemnifying party so desires, jointly with any other indemnifying party similarly noticed, to assume control of the defense thereof with counsel mutually reasonably satisfactory to the indemnifying party and the Investor Indemnitee or Company Indemnitee, as the case may be; provided, however, that an Investor Indemnitee or Company Indemnitee shall have the right to retain its own counsel with the actual and reasonable third party fees and expenses of not more than one counsel for such Investor Indemnitee or Company Indemnitee to be paid by the indemnifying party, if, in the reasonable opinion of counsel retained by the indemnifying party, the representation by such counsel of the Investor Indemnitee or Company Indemnitee and the indemnifying party would be inappropriate due to actual or potential differing interests between such Investor Indemnitee or Company Indemnitee and any other party represented by such counsel in such proceeding. The Investor Indemnitee or Company Indemnitee shall cooperate fully with the indemnifying party in connection with any negotiation or defense of any such action or claim by the indemnifying party and shall furnish to the indemnifying party all information reasonably available to the Investor Indemnitee or Company Indemnitee which relates to such action or claim. The indemnifying party shall keep the Investor Indemnitee or Company Indemnitee reasonably apprised as to the status of the defense or any settlement negotiations with respect thereto. No indemnifying party shall be liable for any settlement of any action, claim or proceeding effected without its prior written consent, provided, however, that the indemnifying party shall not unreasonably withhold, delay or condition its consent. No indemnifying party shall, without the prior written consent of the Investor Indemnitee or Company Indemnitee, consent to entry of any judgment or enter into any settlement or other compromise which does not include as an unconditional term thereof the giving by the claimant or plaintiff to such Investor Indemnitee or Company Indemnitee of a release from all liability in respect to such claim or litigation. Following indemnification as provided for hereunder, the indemnifying party shall be subrogated to all rights of the Investor Indemnitee or Company Indemnitee with respect to all third parties, firms or corporations relating to the matter for which indemnification has been made. The indemnification required by this Article V shall be made by periodic payments of the amount thereof during the course of the investigation or defense, as and when bills are received and payment therefor is due.

  • Direct Claim Procedures In the event an Indemnified Party has a claim for indemnity under Section 7.02 against the Indemnifying Party that does not involve a Third Party Claim, the Indemnified Party agrees to give notice in writing of such claim to the Indemnifying Party. Such notice shall set forth in reasonable detail such claim and the basis for indemnification (taking into account the information then available to the Indemnified Party). The failure to so notify the Indemnifying Party shall not relieve the Indemnifying Party of its obligations hereunder, except to the extent such failure shall have actually materially and adversely prejudiced the Indemnifying Party. If the Indemnifying Party does not notify the Indemnified Party within thirty (30) days following the receipt of a notice with respect to any such claim that the Indemnifying Party disputes its indemnity obligation to the Indemnified Party for any Losses with respect to such claim, such Losses shall be conclusively deemed a liability of the Indemnifying Party and the Indemnifying Party shall promptly pay to the Indemnified Party any and all Losses arising out of such claim. If the Indemnifying Party has timely disputed its indemnity obligation for any Losses with respect to such claim, the parties shall proceed in good faith to negotiate a resolution of such dispute and, if not resolved through such negotiations, such dispute shall be resolved by arbitration determined pursuant to Section 9.06.

  • Notice of Indemnification Claim Promptly after receipt by an indemnified party under Section 5.1 or Section 5.2 of notice of the commencement of any action (including any governmental action), such indemnified party will, if a claim in respect thereof is to be made against any indemnifying party under Section 5.1 or Section 5.2, deliver to the indemnifying party a written notice of the commencement thereof and the indemnifying party shall have the right to participate in, and, to the extent the indemnifying party so desires, jointly with any other indemnifying party similarly noticed, to assume the defense thereof with counsel mutually satisfactory to the indemnifying parties. An indemnified party (together with all other indemnified parties that may be represented without conflict by one counsel) shall have the right to retain one separate counsel, with the reasonably incurred fees and expenses to be paid by the indemnifying party, if representation of such indemnified party by the counsel retained by the indemnifying party would be inappropriate due to actual or potential differing interests between such indemnified party and any other party represented by such counsel in such proceeding. The failure to deliver written notice to the indemnifying party within a reasonable time of the commencement of any such action, if prejudicial to its ability to defend such action, shall relieve such indemnifying party, to the extent so prejudiced, of any liability to the indemnified party under this Section 5, but the omission to deliver written notice to the indemnifying party will not relieve it of any liability that it may have to any indemnified party otherwise than under this Section 5. No indemnifying party, in the defense of any such claim or litigation, shall, except with the consent of each indemnified party, consent to entry of any judgment or enter into any settlement which does not include as an unconditional term thereof the giving by the claimant or the plaintiff to such indemnified party of a release from all liability in respect to such claim or litigation.

  • Claim Procedure Any Person entitled to indemnification hereunder shall (i) give prompt written notice to the indemnifying party of any claim with respect to which it seeks indemnification (provided that the failure to give prompt notice shall impair any Person’s right to indemnification hereunder only to the extent such failure has prejudiced the indemnifying party) and (ii) unless in such indemnified party’s reasonable judgment a conflict of interest between such indemnified and indemnifying parties may exist with respect to such claim, permit such indemnifying party to assume the defense of such claim with counsel reasonably satisfactory to the indemnified party. If such defense is assumed, the indemnifying party shall not be subject to any liability for any settlement made by the indemnified party without its consent (but such consent shall not be unreasonably withheld, conditioned or delayed). An indemnifying party who is not entitled to, or elects not to, assume the defense of a claim shall not be obligated to pay the fees and expenses of more than one counsel for all parties indemnified by such indemnifying party with respect to such claim, unless in the reasonable judgment of any indemnified party a conflict of interest may exist between such indemnified party and any other of such indemnified parties with respect to such claim. In such instance, the conflicted indemnified parties shall have a right to retain one separate counsel, chosen by the Holders representing a majority of the Registrable Securities included in the registration if such Holders are indemnified parties, at the expense of the indemnifying party.

  • Indemnification Notice Each party entitled to indemnification under this Section 5 (the "Indemnified Party") shall give notice to the party required to provide indemnification (the "Indemnifying Party") promptly after such Indemnified Party has actual knowledge of any claim as to which indemnity may be sought, and shall permit the Indemnifying Party to assume the defense of any such claim or any litigation resulting therefrom, provided that counsel for the Indemnifying Party, who shall conduct the defense of such claim or litigation, shall be approved by the Indemnified Party (whose approval shall not unreasonably be withheld), and the Indemnified Party may participate in such defense at such party's expense; provided, however, that an Indemnified Party (together with all other Indemnified Parties which may be represented without conflict by one counsel) shall have the right to retain one separate counsel, with the reasonable fees and expenses of such counsel to be paid by the Indemnifying Party, if representation of such Indemnified Party by the counsel retained by the Indemnifying Party would be inappropriate due to actual or potential differing interests between such Indemnified Party and any other party represented by such counsel in such proceeding. The failure of any Indemnified Party to give notice as provided herein shall not relieve the Indemnifying Party of its obligations under this Section 5 unless the failure to give such notice is materially prejudicial to an Indemnifying Party's ability to defend such action. No Indemnifying Party, in the defense of any such claim or litigation, shall, except with the consent of each Indemnified Party (not to be unreasonably withheld), consent to entry of any judgment or enter into any settlement which does not include as an unconditional term thereof the giving by the claimant or plaintiff to such Indemnified Party of a release from all liability in respect to such claim or litigation.

Time is Money Join Law Insider Premium to draft better contracts faster.