Key definitions section will discuss about the definition of key terms that to be used in this study.
Project Completion Date means the date on which the Completion Certificate is issued;
Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity
Construction Completion Date means the date by which the overall development of the Project is completed in accordance with the provisions of this Agreement and when the Construction Completion Certificate is issued by the Independent Engineer as per Article 14.1.
Target Completion Date has the meaning given such term in Section 3.3(b).
The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.
Final Completion Date means the date on which Final Completion occurs.
project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;
Substantial Completion Date means the date on which Substantial Completion occurs.
Scheduled Completion Date shall be the date set forth in Clause 10.3;
Project Completion means completion of the Redevelopment in accordance with this Agreement to the state where the whole of the Morley Shopping Centre, as so redeveloped, is capable of occupation for its intended purpose;
Outside Completion Date shall have the meaning assigned to such term in Section 6.3(d).
Scheduled Project Completion Date shall have the meaning specified in Section 6.3 (c);
Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.
Completion Period means the period starting from the date of issue of "Order" and required to complete the work in all respect.
Project Implementation Unit or “PIU” means the unit referred to in Section I.A.1(b) of Schedule 2 to this Agreement.
Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:
Virtual Completion means the premise is in the opinion of the Employer fit for occupation.
Construction Period means the period commencing from the Appointed Date and ending on the date of the Completion Certificate;
Construction Completion means physical construction of a cleanup action component is complete.
Project Start Date means the first Milestone Start Date specified in Schedule B;
Construction Start Date means the later to occur of the date on which Seller delivers to Buyer (a) a copy of the Notice to Proceed that Seller has delivered to the EPC Contractor for the Project, and (b) a written Certification substantially in the form attached hereto as Appendix IV-1.
Milestone Date means the date set against the relevant Milestone in the Implementation Plan;
Initial compliance period means the first full three-year compliance period which begins at least 18 months after promulgation, except for the following contaminants: Dichloromethane; 1,2,4-Trichlorobenzene; 1,1,2- Trichloroethane; Benzo[a]pyrene; Dalapon; Di(2-ethylhexyl adipate; Di(2-ethylhexyl) phthalate; Dinoseb; Diquat; Endothall; Endrin; Glyphosate; Hexachlorobenzene; Hexachlorocyclopentadiene; Oxamyl (Vydate); Picloram; Simazine; 2,3,7,8-TCDD (Dioxin); Antimony; Beryllium; Cyanide; Nickel; and Thallium, initial compliance period means the first full three-year compliance period after promulgation for systems with 150 or more service connections (January 1993 -December 1995) and first full three-year compliance period after the effective date of regulation (January 1996 - December 1998) for systems having fewer than 150 service connections.
Project Milestone means the project milestone set forth in Schedule-J;
Improvement completion assurance means a surety bond, letter of credit,
Project Completion Schedule means the progressive Project Milestones set forth in Schedule-J for completion of the Project Highway on or before the Scheduled Completion Date;