Stage 2 means the construction of the second hotel and other developments facilities and amenities referred to in the Development Proposals;
Stage 1 means the area at Port Xxxxxxx which is the subject of this Agreement and of the ERMP and which is shown bordered in purple as “stage 1” on Department of Land Administration 4 Miscellaneous Plan No. 1743;
Phase 3 means the period commencing on the day after the Phase 2 implementation date and ending on the Phase 3 implementation date (as defined below).
Study Completion means the database for the Study has been locked and all Essential Documents have been provided to the Sponsor, including a copy of the letter from the Reviewing HREC acknowledging receipt of the final report and/or closure letter from the Principal Investigator.
Development Phase means the period before a vehicle type is type approved.
Phase 1 means the first implementation phase of this section, beginning June 1, 2018 and ending May 31, 2022.
Completion Period means the period starting from the date of issue of "Order" and required to complete the work in all respect.
project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;
Year 3 means the tax year preceding the current tax year.
Live Date means the date on which the Trust is converted onto the Administrator’s system and the Administrator begins calculating the Trust’s official net asset values (“NAV”).
Phase 2 means the second implementation phase of this section, beginning June 1, 2022 and continuing thereafter.
Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.
Milestone Dates means the dates for completion of specified Project activities as contained in the Project Schedule.
Phase III means Phase I (or Phase I/II), Phase II (or Phase II/III) and Phase III clinical trials, respectively, in each case as prescribed by applicable FDA IND Regulations, or any corresponding foreign statutes, rules or regulations.
Milestone 2 means achievement of annual Net Sales of at least $35,000,000 during any Calendar Year ending on or before December 31, 2024.
Milestone Date means the date set against the relevant Milestone in the Implementation Plan;
Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:
Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity
Project Year means the 12 month period beginning from the Effective Date and ending 12 months thereafter and each successive 12 month period following thereafter;
Milestone 1 means achievement of annual Net Sales of at least $20,000,000 during the Calendar Year ending on December 31, 2021.
Commissioning Period means, with respect to each Subproject, the period commencing upon the first delivery of Feed Gas to the Subproject in accordance with Sections 4.8 and 11.1 of the Agreement continuing through achievement of RFSU, commissioning, Start Up, Performance Testing and achievement of Substantial Completion for such Subproject.
Stage means level of progress of the works identified as such and more particularly described in the Employer’s Requirements for which a Key Date for the achievement thereof is stipulated in the Contract.
Commencement of Development means the date on which any material operation (as defined in Section 56(4) of the Act) forming part of the Development is begun other than (for the purposes of this Deed and for no other purpose) operations consisting of site clearance, demolition work, archaeological investigations for the purpose of assessing ground conditions, remedial work in respect of any contamination or other adverse ground conditions, diversion and laying out of services, erection of any temporary display of site notices or advertisements and “Commence Development” shall be construed accordingly
Framework Commencement Date means [insert date dd/mm/yyyy];
Practical Completion means that stage in the execution of a Named Project when the Works have been completed in accordance with the terms of the relevant Building Contract and/or the terms of this Agreement such that the AHP Dwellings comprised within the Named Project are fit for beneficial occupation as a residential development in accordance with applicable NHBC or equivalent requirements current at the date of inspection subject only to the existence of minor defects and/or minor omissions at the time of inspection which are capable of being made good or carried out without materially interfering with the beneficial use and enjoyment of the Named Project and which would be reasonable to include in a snagging list, and Practically Complete shall be construed accordingly; Process has the meaning ascribed to it in the DPA; Procurement Law means (as the case may be):
Final Completion Date means the date on which Final Completion occurs.