Related Tenant definition

Related Tenant means any Phase I Tenant, Phase II Tenant, Phase III Tenant, Phase IV Tenant or any other tenant under any Related Lease.
Sample 1Sample 2
Related Tenant which term shall mean the Tenant named in this Lease, PAINEWEBBER INCORPORATED, or a "Permitted Tenant" (as defined in Section 12.9(B)) provided, however, that if the Permitted Tenant is (or its predecessor in interest was) a Related Entity, such Related Entity must have been a "50% Related Entity", which term shall mean an affiliate corporation or other business entity "controlling", "controlled by" or "under common control with" Tenant but in the definition of the terms "controlling", "controlled by" or "under common control with" in Section 12.9(E), the figure twenty (20%) percent shall be deemed to be fifty (50%) percent, and shall not be deemed to include any other assignee or other successor-in-interest (immediate or remote) of Tenant; it being agreed and understood that the Renewal Options and the other rights set forth in this Section 1.3 have been granted only to Tenant named herein and/or a Related Tenant for its sole and exclusive benefit, for so long as such entity is the holder of Tenant's estate and interest granted by this Lease, and that neither the Renewal Options nor any other rights set forth in this Section 1.3 may be transferred or conveyed to any other person or entity.
Sample 1
Related Tenant means any Phase I Tenant, Phase II Tenant or Phase III Tenant.
Sample 1

Examples of Related Tenant in a sentence

  • No Person shall Constructively Own Capital Stock in excess of the Related Tenant Limit for more than thirty (30) days following the date such Person becomes a Related Tenant Owner.

  • Any Transfer that, if effective, would result in any Related Tenant Owner Constructively Owning Capital Stock in excess of the Related Tenant Limit shall be void ab initio as to the Transfer of such Capital Stock which would be otherwise Constructively Owned by such Related Tenant Owner in excess of the Related Tenant Limit, and the intended transferee shall Acquire no rights in such Capital Stock.

  • Upon request of the General Partner, such holder delivering the Exchange Notice shall provide to the General Partner in writing such information as the General Partner may reasonably request to determine whether any portion of the exchange by the delivering holder will result in the violation of the restrictions of Article 5 of the Charter, including the Ownership Limit and the Related Tenant Limit.

  • Upon request of the General Partner, such holder delivering the Exchange Notice shall provide to the General Partner in writing such information as the General Partner may reasonably request to determine whether any portion of the exchange by the delivering holder will result in the violation of the restrictions of Article 5 of the Articles of Incorporation, including the Ownership Limit and the Related Tenant Limit.

  • The Board of Directors of the Company has granted a waiver of the Related Tenant Limit (as such term is defined in the Company Charter) to Investor.

  • Related Tenant Lease commencement date, as shown on the Commencement Date Schedule.

  • Upon request of the General Partner, such holder delivering the Series D Exchange Notice shall provide to the General Partner in writing such information as the General Partner may reasonably request to determine whether any portion of the exchange by the delivering holder will result in the violation of the restrictions of Article 5 of the Articles of Incorporation, including the Ownership Limit and the Related Tenant Limit.

  • Upon request of the General Partner, such holder delivering the Series F Exchange Notice shall provide to the General Partner in writing such information as the General Partner may reasonably request to determine whether any portion of the exchange by the delivering holder will result in the violation of the restrictions of Article 5 of the Articles of Incorporation, including the Ownership Limit and the Related Tenant Limit.

  • This includes connections to mainstream and community-based health, behavioral health, income, disability advocacy, criminal justice expungement and other services essential to achieving permanent housing stability.• Property Related Tenant Services (PRTS) providing individualized housing services to both clients and property owners.

  • This Request for Qualifications (RFQ) is issued by the Sacramento County Department of Human Assistance (DHA) seeking qualified agencies to provide Case Management (CMS) and Property Related Tenant Services (PRTS) as described in this RFQ.


More Definitions of Related Tenant

Related Tenant shall have the meaning assigned in Appendix A hereto.
Sample 1

Related to Related Tenant

  • Subtenant means any Person entitled to occupy, use, or possess any Premises under a Sublease.

  • this Tenant Work Letter means the relevant portion of Sections 1 through 6 of this Tenant Work Letter.

  • Ground Lessee means the Owner Lessor as lessee of the Ground Interest under the Facility Site Lease.

  • Subleased Premises means approximately -18;961 rentable square feet on the 141h floor of the Building, as more specifically depicted on Exhibit A attached hereto and made a part hereof. The Subleased Premises include all of the Leased Premises identified in the Prime Lease.

  • Anchor Tenant means the primary customer occupying a site.

  • Leased space means a self−service storage unit or a space located within a self−service storage facility that a lessee is enti- tled to use for the storage of personal property on a self−service basis pursuant to a rental agreement and that is not rented or pro- vided to the lessee in conjunction with property for residential use by the lessee.

  • Ground Lessor means each lessor that has executed a Ground Lease (collectively, the “Ground Lessors”).

  • Sublessee means any Person for so long, but only so long, as such Person is in possession of the Airframe and/or any Engine pursuant to the terms of a Sublease which is then in effect pursuant to Section 7(b)(x) of the Lease.

  • Tenant Party means any of the following persons: Tenant; any assignees claiming by, through, or under Tenant; any subtenants claiming by, through, or under Tenant; and any of their respective agents, contractors, employees, licensees, guests and invitees.

  • Tenant means any Person leasing, subleasing or otherwise occupying any portion of the Property under a Lease or other occupancy agreement.

  • the Tenant means the party(ies) named on the tenancy agreement as the tenant of The Property.

  • Tenant Work All work installed or furnished to the Premises by Tenant in connection with Tenant’s initial occupancy pursuant to Rider 2 and the Workletter.

  • Landlord Agreement means an agreement substantially in the form provided by Lender to Borrower or such other form as Lender may agree to accept.

  • Tenant Parties means Tenant, any affiliate of Tenant, any permitted subtenant or any other permitted occupant of the Premises, and each of their respective direct or indirect partners, officers, shareholders, directors, members, trustees, beneficiaries, servants, employees, principals, contractors, licensees, agents, invitees or representatives.

  • Work space means that portion of the court’s facilities dedicated to each court reporter, including but not limited to actual space in the courtroom and any designated office space.

  • Mobile home space means a parcel of land for rent which has been designed to accommodate a mobile home and provide the required sewer and utility connections.

  • Sublandlord means the holder of sublandlord’s interest under this Sublease. In the event of any assignment or transfer of the Sublandlord’s interest under this Sublease, which assignment or transfer may occur at any time during the Term in Sublandlord’s sole discretion, Sublandlord shall be and hereby is entirely relieved of all covenants and obligations of Sublandlord hereunder accruing subsequent to the date of the transfer and it shall be deemed and construed, without further agreement between the parties hereto, that any transferee has assumed and shall carry out all covenants and obligations thereafter to be performed by Sublandlord hereunder. Sublandlord may transfer and deliver the then existing Letter of Credit to the transferee of Sublandlord’s interest under this Sublease, and thereupon Sublandlord shall be discharged from any further liability with respect thereto. In addition, Sublandlord shall comply with all of its obligations as “Tenant” under the Master Lease except to the extent that any such obligation is the obligation of Subtenant pursuant to the terms of this Sublease. Notwithstanding any other term or provision of this Sublease, the liability of Subtenant to Sublandlord for any default in Subtenant’s obligations under this Sublease shall be limited to actual, direct damages, and under no circumstances shall Sublandlord, its partners, members, shareholders, directors, agents, officers, employees, contractors, sublessees, successors and/or assigns be entitled to recover from Subtenant (or otherwise be indemnified by Subtenant) for lost revenues, lost profit or other consequential, special or punitive damages arising in connection with this Sublease for any reason, except for any breach by Subtenant under Section 12 of the Master Lease. Notwithstanding any other term or provision of this Sublease, no personal liability shall at any time be asserted or enforceable against Subtenant’s shareholders, directors, officers, or partners on account of any of Subtenant’s obligations or actions under this Sublease.

  • Tenant Inducement Costs shall not include loss of income resulting from any free rental period, it being understood and agreed that Seller shall bear the loss resulting from any free rental period until the Closing Date and that Purchaser shall bear such loss from and after the Closing Date.

  • Landlord’s Work means the work of constructing the Tenant Improvements.

  • Sublessor means one who conveys real property by sublease."

  • Space Lease The space or occupancy lease pursuant to which any Borrower holds a leasehold interest in the related Mortgaged Property, together with any estoppels or other agreements executed and delivered by the lessor in favor of the lender under the related Mortgage Loan(s).

  • Landlord Work means the work, if any, that Landlord is obligated to perform in the Premises pursuant to a separate agreement (the “Work Letter”), if any, attached to this Lease as Exhibit C.

  • Master Tenant means any entity approved by HUD now or hereafter leasing the Healthcare Facility pursuant to a Master Lease.

  • Landlord Delay means any actual delay in the completion of the Improvements as a result of Landlord’s breach or material default under this Third Amendment (including, without limitation, any breach of representation or warranty); any delays relating to any of the matters specified in Section 5.3 of Exhibit B; any failure to respond to any items required to be furnished or approved by Landlord within a time period expressly set forth in this Third Amendment or the Lease (unless a deemed approval is specified, in which case no Landlord Delay shall be assessed); Landlord’s failure to allow contractors access to the Building or Premises as scheduled in advance with the Building’s property manager or Landlord’s request for material changes in the fmal Plans and Specifications after Landlord’s approval thereof (unless such request was caused by an error or omission by Tenant), provided, however, that notwithstanding the foregoing, no Landlord Delay shall be deemed to have occurred unless and until Tenant has delivered to Landlord a factually correct written notice (the “Landlord Delay Notice”), specifying the bona fide action or inaction which Tenant contends constitutes the Landlord Delay. If such action or inaction is not cured by Landlord within two (2) business days of Landlord’s receipt of such Landlord Delay Notice, then the Landlord Delay shall be deemed to have occurred as of the expiration of such two (2) business day period. A delay in construction of the Improvements due to a Tenant Delay (as defined in Exhibit B, attached to and part of the Original Lease), any Force Majeure event or a delay by any governmental authority (including but not limited to the City of Los Angeles) shall not be deemed a Landlord Delay. Any Landlord Delay Notice shall be sent to the notice address set forth in the Lease with copies to (a) to the property manager at the management office of the Building; and to (b) Xxxxxxx Xxxxxx Management LLC, 000 Xxxxxxxx Xxxxxxxxx, Xxxxx 000, Xxxxx Xxxxxx, Xxxxxxxxxx 00000, Attention: Leasing Legal Department Manager.

  • Prior Occupancy means Owner’s use of all or parts of the Project before Substantial Completion, as more fully set forth in Section 6.08 A.

  • Building Square Footage or "BSF" means the square footage of assessable internal living space of a Unit, exclusive of any carports, walkways, garages, overhangs, patios, enclosed patios, detached accessory structure, other structures not used as living space, or any other square footage excluded under Government Code Section 65995 as determined by reference to the Building Permit for such Unit.