Force Majeure Termination definition

Force Majeure Termination means termination of this Agreement by either party under Section 17.4 on account of a Force Majeure Event;
Sample 1Sample 2Sample 3
Force Majeure Termination. Sum is as defined in Clause 117.2 (Amount);
Sample 1
Force Majeure Termination means those circumstances where either party has terminated the Development Agreement pursuant to clause 18.2(h) of the Development Agreement; 2 Exhibit 10.85 “Nalmefene Finished Product” has the meaning given to it in Recital (A); “Opiant Fault Termination” means those circumstances where Aesica terminates the Development Agreement pursuant to any of clauses 18.2(a) – 18.2(g) of the Development Agreement (inclusive); “Opiant No Fault Termination” means those circumstances where Opiant terminates the Development Agreement pursuant to clause 18.1 of the Development Agreement; “Quarter” means each three (3) month period starting on 1 January, 1 April, 1 July and 1 October in each calendar year; “Service Fees” means the amount of its labour costs per Quarter that Aesica has allocated to the project, as set out in the tenth row of the table set out at Schedule 1 (as such table may be updated from time to time by the Parties in accordance with clause 7); “Supply Agreement” has the meaning given to it in Recital (B); “Tooling” means the tooling required to be purchased by Aesica for the purposes of supporting the commercial manufacture of the Nalmefene Finished Product; “Tooling Fees” means the amounts to be paid by Aesica on Tooling as set out in the first row of the table set out at Schedule 1 (as such table may be updated from time to time by the Parties in accordance with clause 7); “Trigger Date” means the following:
Sample 1

Examples of Force Majeure Termination in a sentence

  • Subject to the sections in this Contract concerning Force Majeure, Termination and Open Market Purchases, the Contract shall bind the Client Agency to order the Goods or Services from the Contractor, and to pay for the accepted Goods or Services in accordance with Exhibit B.

  • Subject to the sections in this Contract concerning Force Majeure, Termination, Cancellation Expiration and Open Market Purchases, the Contract shall bind the Client Agency to order the Goods or Services from the Contractor, and to pay for the accepted Goods or Services in accordance with Exhibit B.

  • Subject to the sections in these terms and conditions concerning Force Majeure, Termination, Cancellation and Expiration and Open Market Purchases, the Contract shall bind the State to order the Systems and any associated services from the Contractor, and to pay for the accepted Systems and any associated services at the Contract prices.

  • Termination; Force Majeure Termination by Either Party for Material Breach 6.1 If one Party is in material breach of any of its obligations under the Contract, the other Party can give it written notice that within thirty (30) days of receiving such notice the breach must be remedied (if such breach is capable of remedy).

  • Subject to the Sections in this Contract concerning Force Majeure, Termination and Open Market Purchases, this Contract shall bind the Client Agency to order the Deliverables from the Contractor, and to pay for the accepted Deliverables in accordance with Exhibit B.

  • Subject to the sections in this Contract concerning Force Majeure, Termination and Open Market Purchases, the Contract shall bind the CGA to order the Goods or Services from the Contractor, and to pay for the accepted Goods or Services in accordance with Attachment B.

  • Subject to the sections in this Contract concerning Force Majeure, Termination and Open Market Purchases, the Contract shall bind the Client Agency to order the Goods or Services from the Contractor, and to pay for the accepted Goods or Services in accordance with Exhibit B1, B2 and B3.

  • Subject to the sections in this Contract concerning Force Majeure, Termination and Open Market Purchases, the Contract shall bind the Agency to order the Goods or Services from the Contractor, and to pay for the accepted Goods or Services in accordance with Exhibit B.

  • Subject to the sections in this Contract concerning Force Majeure, Termination and Open Market Purchases, the Contract shall bind the Client Agency to order the Goods or Services from the Contractor, and to pay for the accepted Goods or Services in accordance with Exhibit B.7. Contract Amendments.

  • Force Majeure Termination: If an event of Force Majeure continues beyond a period of thirty (30) days, the Parties shall meet in good faith to consult, if no such solution is found, either Party shall be entitled to terminate the obligations of the Parties under the Contract which are affected by such Force Majeure by giving written notice of not less than seven (7) days to the other Party.


More Definitions of Force Majeure Termination

Force Majeure Termination has the meaning ascribed thereto in Section 16.7(a).
Sample 1
Force Majeure Termination has the meaning as set out in Section P1;
Sample 1
Force Majeure Termination means those circumstances where either party has terminated the Development Agreement pursuant to clause 18.2(h) of the Development Agreement; Exhibit 10.85
Sample 1
Force Majeure Termination has the meaning given in Section 19.
Sample 1
Force Majeure Termination has the meaning set forth in Section 6.6 (b).
Sample 1
Force Majeure Termination means those circumstances where either party has terminated the Development Agreement pursuant to clause 18.2(h) of the Development Agreement;
Sample 1

Related to Force Majeure Termination

  • Force Majeure Period has the meaning specified in Section 13.1.

  • Force Majeure Event means an event, or a series of related events, that is outside the reasonable control of the party affected (including failures of the internet or any public telecommunications network, hacker attacks, denial of service attacks, virus or other malicious software attacks or infections, power failures, industrial disputes affecting any third party, changes to the law, disasters, explosions, fires, floods, riots, terrorist attacks and wars);

  • Force Majeure Delay means with respect to the Servicer, any cause or event which is beyond the control and not due to the negligence of the Servicer, which delays, prevents or prohibits such Person’s delivery of the reports required to be delivered or the performance of any other duty or obligation of the Servicer under the Indenture, as the case may be, including, without limitation, computer, electrical and mechanical failures, acts of God or the elements and fire; provided, that no such cause or event shall be deemed to be a Force Majeure Delay unless the Servicer shall have given the Indenture Trustee written notice thereof as soon as practicable after the beginning of such delay.

  • Force Majeure means an event beyond the control of the supplier and not involving the supplier’s fault or negligence and not foreseeable. Such events may include, but is not restricted to, acts of the purchaser in its sovereign capacity, wars or revolutions, fires, floods, epidemics, quarantine restrictions and freight embargoes.

  • Force Majeure Notice means a notice to be given by the Affected Party to the other party stating that a Force Majeure Event has occurred;

  • Force Majeure Delays means any actual delay in the construction of the Tenant Improvements, which is beyond the reasonable control of Landlord or Tenant, as the case may be, as described in Paragraph 33 of the Lease.

  • Force Majeure Exception means any failure or delay in the performance of the Issuer's reporting obligation pursuant to Section 2.4 arising out of or caused, directly or indirectly, by circumstances beyond its reasonable control, including, without limitation, acts of God; earthquakes; flood; terrorism; wars and other military disturbances; sabotage; epidemics; riots; loss or malfunctions of utilities, computer (hardware or software) or communication services; accidents; acts of civil or military authority and governmental action. The Issuer shall use commercially reasonable efforts to commence performance of its obligations during any of the foregoing circumstances.

  • Force Majeure Events means acts of war, domestic and/or international terrorism, civil riots or rebellions, quarantines, embargoes and other similar unusual governmental actions, extraordinary elements of nature or acts of God.

  • Force Majeure Failure has the meaning set forth in Section 8.1(d).

  • Event of Force Majeure means one of the following events:

  • Relevant Force Majeure Event means a Force Majeure Event in relation to which an Affected Party is claiming relief under this Clause 17; and

  • Force Majeure Report means a report to be given by the Affected Party to the other party following the giving of a Force Majeure Notice;

  • Network Termination Point (NTP) means the physical point at which a subscriber is provided with access to a public communications network; in the case of networks involving switching or routing, the NTP is identified by means of a specific network address, which may be linked to a subscriber number or name;

  • Partial Termination has the meaning set forth in the Section 6.3(a).

  • Potential Termination Event means an event which, with the giving of notice and/or the lapse of time, would constitute a Termination Event.

  • Unavoidable Delay means an event which delays Closing which is a strike, fire, explosion, flood, act of God, civil insurrection, act of war, act of terrorism or pandemic, plus any period of delay directly caused by the event, which are beyond the reasonable control of the Vendor and are not caused or contributed to by the fault of the Vendor. “Unavoidable Delay Period” means the number of days between the Purchaser’s receipt of written notice of the commencement of the Unavoidable Delay, as required by paragraph 5(b), and the date on which the Unavoidable Delay concludes.

  • Excusable Delay means a delay due to acts of God, governmental restrictions, stays, judgments, orders, decrees, enemy actions, civil commotion, fire, casualty, strikes, work stoppages, shortages of labor or materials or other causes beyond the reasonable control of Borrower, but lack of funds in and of itself shall not be deemed a cause beyond the control of Borrower.

  • Terminating Party As defined in Section 7.1(f).

  • Third Party Terminating Carrier means a Telecommunications Carrier to which traffic is terminated when CLEC originates traffic that is sent through AT&T-TSP’s network, i.e., CLEC is using AT&T-TSP’s Transit Traffic Service.

  • Unavoidable Delays means delays due to any of the following, and only the following, (provided that such delay is beyond Construction Manager’s reasonable control): war, insurrection, civil commotion, strikes, slowdowns, lock outs, riots, flood, earthquakes, fires, casualties, acts of God, acts of a public enemy, acts of terrorism, epidemics, quarantine restrictions, freight embargoes, lack of transportation, governmental moratoriums, unusually severe or abnormal weather conditions, failure of utilities, or a court order which causes a delay (unless resulting from a wrongful act of Construction Manager). In no event shall the application to Construction Manager of any applicable law, regulation, rule or other governmental requirement constitute an Unavoidable Delay. Contractor shall use reasonable good faith efforts to notify Owner not later than five (5) days after Construction Manager knows of the occurrence of an Unavoidable Delay. An extension of time for an Unavoidable Delay shall only be for the period of the Unavoidable Delay, which period shall commence to run from the time of the commencement of the cause of the Unavoidable Delay.

  • Normal Termination means termination of employment or service with the Company and Affiliates:

  • Catastrophic disability means a physical and not a psychological

  • Automatic Termination shall have the meaning set forth in Section 2.3.2.

  • Excusable Delays means delays due to acts of terrorism, acts of war or civil insurrection, strikes, riots, floods, earthquakes, fires, tornadoes, casualties, acts of God, labor disputes, governmental restrictions or priorities, embargoes, national or regional material shortages, failure to obtain regulatory approval from any Federal or State regulatory body, unforeseen site conditions, extraordinary rainfall or snowfall, or any other condition or circumstances beyond the reasonable or foreseeable control of the applicable Party using reasonable diligence to overcome which prevents such Party from performing its specific duties or obligation hereunder in a timely manner; provided, however, Excusable Delay does not include lack of financing, unanticipated or unexpected increases in the costs of construction, or errors in business judgment by a Party; and provided further that Excusable Delay shall only extend the time of performance for the period of such Excusable Delay, which shall begin on the date which the event of Excusable Delay first occurs and extend until the date which the event which has caused the Excusable Delay has been corrected or performed, or reasonably should have been corrected or performed.

  • Major disaster means any natural catastrophe (including any hurricane, tornado, storm, high water, winddriven water, tidal wave, tsunami, earthquake, volcanic eruption, landslide, mudslide, snowstorm, or drought), or, regardless of cause, any fire, flood, or explosion, in any part of the United States, which in the determination of the President causes damage of sufficient severity and magnitude to warrant major disaster assistance under this Act to supplement the efforts and available resources of States, local governments, and disaster relief organizations in alleviating the damage, loss, hardship, or suffering caused thereby.

  • Complete Termination means a termination of the Fund's Rule 12b-1 plan for B-2 Shares involving the cessation of payments of the Distribution Fees, and the cessation of payments of distribution fees pursuant to every other Rule 12b-1 plan of the Fund for every existing or future B-Class-of-Shares (as hereinafter defined) and the Fund's discontinuance of the offering of every existing or future B-Class-of-Shares, which conditions shall be deemed satisfied when they are first complied with hereafter and so long thereafter as they are complied with prior to the earlier of (i) the date upon which all of the B-2 Shares which are Distributor Shares pursuant to Schedule I hereto shall have been redeemed or converted or (ii) May 31, 2005. For purposes of this Section 14.5, the term B-Class-of-Shares means each of the B-1 Class of Shares of the Fund, the B-2 Class of Shares of the Fund and each other class of shares of the Fund hereafter issued which would be treated as Shares under Schedule I hereto or which has substantially similar economic characteristics to the B-1 or B-2 Classes of Shares taking into account the total sales charge, CDSC or other similar charges borne directly or indirectly by the holder of the shares of such class. The parties agree that the existing C Class of Shares of the Fund does not have substantially similar economic characteristics to the B-1 or B-2 Classes of Shares taking into account the total sales charge, CDSC or other similar charges borne directly or indirectly by the holder of such shares. For purposes of clarity the parties to this agreement hereby state that they intend that a new installment load class of shares which may be authorized by amendments to Rule 6(c)-10 under the 1940 Act will be considered to be a B-Class-of-Shares if it has economic characteristics substantially similar to the economic characteristics of the existing B-1 or B-2 Classes of Shares taking into account the total sale charge, CDSC or other similar charges borne directly or indirectly by the holder of such shares and will not be considered to be a B-Class-of-Shares if it has economic characteristics substantially similar to the economic characteristics of the existing C Class of shares of the Fund taking into account the total sales charge, CDSC or other similar charges borne directly or indirectly by the holder of such shares.