Completion Milestones definition

Completion Milestones means, for each of the phases of the Project identified in the table below, the date for such phase set forth in the table below, as extended for delays resulting from Force Majeure of which Developer promptly notifies Owner: Begin basement level concrete pours July 29, 2015 Begin framing residential units February 24, 2016 Delivery of first residential unit September 9, 2016 All residential units May 22, 2017
Sample 1

Examples of Completion Milestones in a sentence

  • All time limits for Interim Completion, Milestones, Substantial Completion, and Final Completion as stated in the Contract Documents are of the essence of the Contract.

  • Interim Completion Milestones (x points total; x points NB and x points SB).

  • The real growth of these finance companies aroused mainly due to inability of the commercial banks to compete for attracting deposits through interest rate.

  • Unless otherwise specified, the activity “Bid Opening” shall be the only activity without a predecessor, “Contract Completion” and each Contract Milestone shall be the only activities without successors.The use of activity constraints is limited to the use of Start-No-Earlier-Than and Finish- No-Later-Than, for access restraints and Completion Milestone(s).

  • Substantial Completion of the Project (or those portions of the Project substantially complete as per the Completion Milestones shall be deemed to have occurred when all of the following have occurred to the satisfaction of the MBTA: a.

  • Activity Constraints are limited to the use of Start-No-Earlier-Than and Finish-No-Later-Than, for access restraints and Completion Milestone(s) or Phase(s).

  • The use of activity constraints is limited to the use of Start-No-Earlier-Than and Finish-No-Later-Than, for access restraints and Completion Milestone(s).

  • Interim Completion Milestones (30 points total for Table SCD-2b).

  • In order for these activities to occur, the General Contractor is expected to have completed the concurrently listed Completion Milestones.

  • The Trade Subcontractor is to include any and all costs required to meet the Completion Milestones as noted below.

Related to Completion Milestones

  • Project Milestones means the project milestones set forth in Schedule-G;

  • Project Milestone means the project milestone set forth in Schedule-J;

  • Milestone 2 means achievement of annual Net Sales of at least $35,000,000 during any Calendar Year ending on or before December 31, 2024.

  • Milestones means control points in the project that help to chart progress. Milestones may correspond to the completion of a key deliverable, allowing the next phase of the work to begin. They may also be needed at intermediary points so that, if problems have arisen, corrective measures can be taken. A milestone may be a critical decision point in the project where, for example, the consortium must decide which of several technologies to adopt for further development.

  • Milestone Schedule means Seller’s milestone schedule, the form of which is attached to this Agreement as Exhibit Q.

  • Performance Milestone means an act or event specified in section 5.1 and described in section 9 of the EPLA.

  • Milestone 1 means achievement of annual Net Sales of at least $20,000,000 during the Calendar Year ending on December 31, 2021.

  • Milestone Date means the date set against the relevant Milestone in the Implementation Plan;

  • Development Milestone Event has the meaning set forth in Section 7.1.

  • Milestone Dates means the dates for completion of specified Project activities as contained in the Project Schedule.

  • Milestone Events has the meaning set forth in Section 3.3 (Milestone Payments).

  • Completion Schedule means the fulfilment of the Related Services by the Supplier in accordance with the terms and conditions set forth in the Contract;

  • Milestone means an event or task described in the Implementation Plan which, if applicable, must be completed by the relevant Milestone Date;

  • Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.

  • Project Completion Schedule means the progressive Project Milestones set forth in Schedule-J for completion of the Project Highway on or before the Scheduled Completion Date;

  • project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;

  • Milestone Event has the meaning set forth in Section 8.4.

  • Development Milestone Payment shall have the meaning set forth in Section 9.2(a).

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Project Completion means completion of the Redevelopment in accordance with this Agreement to the state where the whole of the Morley Shopping Centre, as so redeveloped, is capable of occupation for its intended purpose;

  • Substantial Completion Date means the date on which Substantial Completion occurs.

  • Final Completion Date means the date on which Final Completion occurs.

  • Completion Period means the period starting from the date of issue of "Order" and required to complete the work in all respect.

  • Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity

  • Completion Notice means a notice issued by the Developer in accordance with clause 6.1.