THE AFFORDABLE HOUSING PROJECT Sample Clauses

THE AFFORDABLE HOUSING PROJECT. 3.1. The Grant Recipient shall procure the carrying out and completion of the Works
Sample 1Sample 2Sample 3See All (5)
AutoNDA by SimpleDocs
THE AFFORDABLE HOUSING PROJECT. The Grant Recipient shall procure the carrying out and completion of the Works in a proper and workmanlike manner; in compliance with this Agreement, which includes without limitation, the Specification, any Statutory Requirement and Consents and shall give all notices required by the Statutory Requirements; diligently and in a timely fashion, using reasonable endeavours to achieve Practical Completion on or before the Longstop Date. The Grant Recipient agrees to enter into a Nominations Agreement in substantially the form set out in Schedule 6 attached hereto before Practical Completion. The Grant Recipient shall be responsible for and be liable for the design of the units funded. Through this agreement such liability shall not, for the avoidance of doubt, be reduced, obviated, diminished or avoided by the fact that any part of the design was carried out by the Council or otherwise. The Grant Recipient shall develop and finalise the design and specification of the Affordable Housing units. In relation to the design of the units the Grant Recipient warrants that: it has used, and will continue to use, the degree of skill and care in the design of the affordable housing units that would reasonably be expected of a competent professional designer experienced in carrying out design activities of a similar nature, scope and complexity to those comprised in the Works; the Grant Recipient’s design complies with the Consents and Statutory Requirements (as applicable); and the Grant Recipient’s design complies with, and wherever possible exceeds, the minimum requirements set out in local, regional and national guidance on the standards and quality for Affordable Housing Units. The Council expressly acknowledges that the Grant Recipient’s maximum liability under this Agreement (whether pursuant to Clause 8 or otherwise) shall not, in any circumstance, exceed the sum paid to it by the Council under this Agreement.
Sample 1

Related to THE AFFORDABLE HOUSING PROJECT

  • Affordable Housing The Owner covenants with the Council as follows:-

  • Project 3.01. The Recipient declares its commitment to the objectives of the Project. To this end, the Recipient shall carry out the Project in accordance with the provisions of Article IV of the General Conditions.

  • Projects The Annexes attached hereto describe the specific projects and the policy reforms and other activities related thereto (each, a “Project”) that the Government will carry out, or cause to be carried out, in furtherance of this Compact to achieve the Objectives and the Compact Goal.

  • EQUAL HOUSING OPPORTUNITY The Property is offered in compliance with Federal, State, and local anti-discrimination laws.

  • PROFESSIONAL DEVELOPMENT AND EDUCATIONAL IMPROVEMENT A. The Board agrees to implement the following:

  • Fair Housing The Agency is committed to compliance with all laws as well as the philosophy of fair housing for all people. The Agency will present the Property to all prospective Buyers in compliance with local, State, and Federal Fair Housing laws against discrimination on the basis of race, color, religion, sex, national origin, handicap, age, marital status and/or familial status, children, or other prohibited factors.

  • Department of Housing and Urban Development This includes a HUD produced video titled “The Basics of the Fair Housing Act” which can be accessed via YouTube at xxxxx://xxx.xxxxxxx.xxx/watch?v=egXPe7HT7tc. Relief for Complainant

  • The Project The Project is the total construction of which the Work performed under the Contract Documents may be the whole or a part.

  • Development of the Property Except as modified by this Agreement, the Development and the Property will be developed in accordance with all applicable local, state, and federal regulations, including but not limited to the City’s ordinances and the zoning regulations applicable to the Property, and such amendments to City ordinances and regulations that that may be applied to the Development and the Property under Chapter 245, Texas Local Government Code, and good engineering practices (the “Applicable Regulations”). If there is a conflict between the Applicable Regulations and the Development Standards, the Development Standards shall control.

  • Rehabilitation Program The company agrees to the implementation of an agreed worker’s compensation rehabilitation policy. The operation of this policy shall be reviewed on a regular basis. The parties commit to ensuring that the rehabilitation of injured workers is an accepted practice, and that suitable duties are provided when available. No employee will be terminated whilst on workers compensation during the first 12 months without prior consultation with the union. The parties agree that the person responsible for the management of rehabilitation cases must be adequately trained to do the job. If such a person is not available within the company, then the services of an agreed building industry rehabilitation coordination service will be used. The parties to this Agreement shall ensure that any employee who sustains a work related injury, illness or disease, will be afforded every assistance in utilising a rehabilitation program aimed at returning that employee to meaningful employment within the industry.

Time is Money Join Law Insider Premium to draft better contracts faster.