Preliminary Cost Estimates The Engineer shall develop a preliminary cost estimate using the Average Low Bid Unit Price. The Engineer shall estimate the total project cost including preliminary engineering, final engineering, right-of-way (ROW) acquisition, environmental compliance and mitigation, construction, utility relocation, and construction engineering inspection (CEI).
Preliminary Cost Estimate Consulting Engineer/Architect shall furnish City an estimate of probable Construction Cost based on the preliminary design. Consulting Engineer/Architect's estimate of probable Construction Cost is to be made on the basis of Consulting Engineer/Architect's experience and qualifications and represent Consulting Engineer/Architect's best judgment as an experienced and qualified design professional, familiar with the construction industry.
Preliminary Schedule A preliminary schedule of construction indicating the starting and completion dates of the various stages of the Work, including any information and following any form as may be specified in the Specifications. Once approved by District, this shall become the Construction Schedule. This schedule shall include and identify all tasks that are on the Project’s critical path with a specific determination of the start and completion of each critical path task as well as all Contract milestones and each milestone’s completion date(s) as may be required by the District.
Construction Schedules 10.1 Within seven (7) days of the University’s issuance of a purchase order, the Contractor shall submit to the Project Coordinator three (3) copies of a Construction Schedule for this Project. The Schedule shall be in bar chart form and shall include all aspects of the work, the interrelationship of the various trades and the critical path of the job. The schedule shall include a timeline for the submission, review and approval of shop drawings for critical path items and delivery and installation dates for those same critical path, or long lead time items, (such as electrical transformers and elevator). The Schedule shall coincide with the Contractor’s approved Schedule of Values. The Schedule shall indicate a completion date in advance of the date established for Substantial Completion. The Schedule shall be acceptable to the Architect/Engineer and the Project Coordinator. It shall be revised and reissued at the beginning of every month for the duration of the project. This monthly update progress Schedule shall include a summary comparison of the original schedule and the latest updated schedule (previous month) showing all activity description and dates. These comparison schedules shall be in the form of a summary bar chart, an activity listing report and actual to target comparisons. The reports may include critical activities, float time, duration of each activity, dates of each activity and the network logic (including successors and predecessors of each activity). Included with the written report and electronic copy of the schedule submission noting the above referenced requirements. Failure to provide the Architect/Engineer, or the Project Coordinator with an acceptable, revised Schedule, within seven (7) days of the receipt of a written request, may result in the withholding of the Contractor’s monthly progress payments until such a Schedule is received.
Cost Estimates If this Agreement pertains to the design of a public works project, CONSULTANT shall submit estimates of probable construction costs at each phase of design submittal. If the total estimated construction cost at any submittal exceeds ten percent (10%) of CITY’s stated construction budget, CONSULTANT shall make recommendations to CITY for aligning the PROJECT design with the budget, incorporate CITY approved recommendations, and revise the design to meet the Project budget, at no additional cost to CITY.
Wage Schedules The Parties shall, upon completing a wage adjustment calculation, forthwith prepare, publish, post and distribute a wage schedule resulting therefrom. The final determination of the wage schedules shall be issued no later than the 7th day of March or September, for the May and November adjustments, respectively.
Third Schedule MINERAL LEASE Lease No Goldfield(s) XXXXXXXXX THE SECOND by the Grace of God of the United Kingdom, Australia and Her other Realms and Territories Queen, Head of the Commonwealth, Defender of the Faith: TO ALL TO WHOM THESE PRESENTS shall come GREETINGS: KNOW YE that WHEREAS by an Agreement made the day of 1968 between the State of Western Australia of the one part and HAMERSLEY IRON PTY. LIMITED (hereinafter called “the Company” which expression will include the successors and assigns of the company including where the context so admits the assignees of the Company under the said Agreement) of the other part the said State agreed to grant to the Company a mineral lease of portion or portions of the lands referred to in the said Agreement as “the mining areas” AND WHEREAS the said Agreement was ratified by the Act 196 which said Act (inter alia) authorized the grant of a mineral lease to the Company NOW WE in consideration of the rents and royalties reserved by and of the provisions of the said Agreement and in pursuance of the said Act DO BY THESE PRESENTS GRANT AND DEMISE unto the Company subject to the said provisions ALL THOSE pieces and parcels of land situated in the Goldfield(s) containing approximately acres and (subject to such corrections as may be necessary to accord with survey when made) being the land shaded pink on the plan in the Schedule hereto and all those mines, veins, seams, lodes and deposits of iron ore in on or under the said land (hereinafter called “the said mine”) together with all rights, liberties, easements, advantages and appurtenances thereto belonging or appertaining to a lessee of a mineral lease under the Mining Xxx 0000 including all amendments thereof for the time being in force and all regulations made thereunder for the time being in force (which Act and regulations are hereinafter referred to as “the Mining Act”) or to which the Company is entitled under the said Agreement TO HOLD the said land and mine and all and singular the premises hereby demised for the full term of twenty-one years from the day of 19 with the right to renew the same from time to time for further periods each of twenty-one years as provided in but subject to the said Agreement for the purposes but upon and subject to the terms covenants and conditions set out in the said Agreement and to the Mining Act (as modified Third Schedule by the said Agreement) YIELDING and paying therefor the rent and royalties as set out in the said Agreement. AND WE do hereby declare that this lease is subject to the observance and performance by the Company of the following covenants and conditions, that is to say: —
Second Schedule Second Schedule THIS AGREEMENT under seal made the twenty-seventh day of October One thousand nine hundred and sixty-four BETWEEN THE HONOURABLE XXXXX XXXXX, M.L.A. Premier and Treasurer of the State of Western Australia acting for and on behalf of the said State and instrumentalities thereof from time to time (hereinafter called “the State”) of the one part and HAMERSLEY IRON PTY. LIMITED a company incorporated under the Companies Xxx 0000 of the State of Victoria and having its registered office and principal place of business in that State at 00 Xxxxxxx Xxxxxx Melbourne and its registered office in the State of Western Australia at 37 Saint George’s Terrace Perth (hereinafter called “the Company” which expression will include the successors and assigns of the Company including where the context so admits the assignees and appointees of the Company under clause 20 of the agreement hereinafter referred to) of the other part.
Construction Cost Estimate At 50% completion of the contract documents, the design team will present and submit copies of the project plans and manual. The Construction Administrator will prepare and issue the fourth of five construction cost estimates. The estimate shall be derived from actual takeoffs, subcontractor and vendor input, and material and labor cost data. All quantitative systems information shall be provided in detail.
Clauses and Schedules Any reference in this Agreement to a Clause or a sub-clause or a Schedule is, unless otherwise stated, to a clause or a sub-clause hereof or a schedule hereto.
